REGIONAL INSTITUTE OF MEDICAL SCIENCES IMPHAL ...

More documents

Recommendations

Info

REGIONAL INSTITUTE OF MEDICAL SCIENCES IMPHAL CONSTRUCTION OF OPD & NURSING COLLEGE UNDER PHASE - II FOR RIMS AT IMPHAL Volume – I PREQUALIFICATION Tender No : RIMS/HSCC/2010/01(P-I) dated _______ April 2010 HSCC (INDIA) LMITED Plot – 6(A), Block – E, Sector 1, NOIDA – UP – 201301 Phone : +91 120 2542436-40 Fax : +91 120 2542447 Website : http://www.hsccltd.co.in
Package No. Regional Institute of Medical Sciences, Imphal Ministry of Health & Family Welfare Government of India REGIONAL INSTITUTE OF MEDICAL SCIENCES IMPHAL No. RIMS/HSCC/2010/01 Ist April , 2010 INVITATION FOR BIDS Director, Regional Institute of Medical Sciences, Imphal intends to invite bids from eligible contractors/firms for the following works : Name & Description of work Estimated Completion Date of Last date of Cost (Rs.) period of issue of Bid submission work documents (months) including rainy season 1. Construction of OPD, Nursing College including internal and external services Plumbing, Electrical, Firefighting & HVAC etc., for Regional Institute of Medical Sciences at Imphal, Manipur 2 Construction of Academic Block, Library Block & Guest House including internal and external services Plumbing, Electrical, Firefighting & HVAC etc., for Regional Institute of Medical Sciences at Imphal, Manipur Rs.39 Crores Rs.30 Crores 30 months (Thirty months) 30 months (Thirty months) From 0900 hrs of 01-04-2010 till 1500 hrs on 20-04-2010 From 0900 hrs of 01-04-2010 till 1500 hrs on 20-04-2010 Till 1500 hrs on 21-04-2010 Till 1500 hrs on 21-04-2010 The pre-qualification document (Volume-I), General Conditions of Contract (Volume-II), Instructions to Bidders and Specific Conditions of Contract (Volume-III) have been made available at HSCC website http://www.hsccltd.co.in and RIMS, Imphal website www.rims.edu.in. The interested applicants/firms may download and check their eligibility for the work. Applicants are also advised to keep on checking the website regularly for amendments/clarification, if any. Interested applicants/firms may also see the complete set of Bid Documents which have been kept at dispatch counter of HSCC Corporate Office, E6(A) ,Sector-1,Noida. Interested contractors/firms may purchase the Tender document in person from the office of HSCC (India) Limited, Noida on any working day as mentioned above on written request mentioning the name & description of work against a non-refundable fee of Rs.10,000/- for each package through cash/demand draft in favour of HSCC (India) Ltd., Noida payable at Noida. Interested applicants/firms may like to attend the pre bid meeting which is scheduled to be held at HSCC, Noida office on 15-04-2010 from 14 00 hrs onwards. The tender documents should be submitted, complete in all respects, on or before due date and time as mentioned above at HSCC Corporate Office at Noida. Director/ HSCC reserves the right to accept or reject any application without assigning any reason thereof or incurring any liability whatsoever. Prospective bidders are advised to regularly scan through HSCC website as corrigendum/amendment etc., if any , will be notified on the HSCC website and separate advertisement will not be made for this. Director Regional Institute of Medical Sciences Imphal HSCC/RIMS/2010/01- PI Page - 1
Page 1: Package No Ministry of Health & Fam
Page 5 and 6: Regional Institute of Medical Scien
Page 21 and 22: INDEX GENERAL CONDITIONS OF CONTRAC
Page 23 and 24: -----------------------------------
Page 25 and 26: -----------------------------------
Page 27 and 28: -----------------------------------
Page 29 and 30: 1.1 Definitions GENERAL CONDITIONS
Page 31 and 32: otherwise agreed by the Engineer an
Page 33 and 34: (a) The Engineer's Representative s
Page 35 and 36: (b) the purchase of materials which
Page 37 and 38: 7.1 Supplementary Drawings and Inst
Page 39 and 40: 10.3 Costs of Securities The cost o
Page 41 and 42: 14.2 Revised Programme HSCC/RIMS/20
Page 43 and 44: accuracy thereof and the Contractor
Page 45 and 46: (iv) pressure waves caused by aircr
Page 47 and 48: (b) loss or damage to any property
Page 49 and 50: when required, produce to the Consu
Page 51 and 52: shall immediately be reported by th
Page 53 and 54:
or ancillary to the Works. 31.2 Fac
Page 55 and 56:
state or the Central Government or
Page 57 and 58:
investigations or enquiry under thi
Page 59 and 60:
36.5 Engineer's Determination Where
Page 61 and 62:
(c) The removal and proper re-execu
Page 63 and 64:
COMMENCEMENT AND DELAYS 41.1 Commen
Page 65 and 66:
the Contractor has (a) (b) within 2
Page 67 and 68:
therein. The Contractor shall be en
Page 69 and 70:
Contract. If, in the opinion of the
Page 71 and 72:
provisional rates or prices to enab
Page 73 and 74:
Notwithstanding any other provision
Page 75 and 76:
54.5 Conditions of Hire Contractor'
Page 77 and 78:
used, in whole or in part, or not a
Page 79 and 80:
such is made in a special item prov
Page 81 and 82:
the receipt of the monthly statemen
Page 83 and 84:
progressively reduced by the amount
Page 85 and 86:
60.13 Final Certificate Within 28 d
Page 87 and 88:
materials which have been deemed to
Page 89 and 90:
with the Contract for any Permanent
Page 91 and 92:
RELEASE FROM PERFORMANCE 66.1 Payme
Page 93 and 94:
of a notice from the Arbitrator, fa
Page 95 and 96:
which payment is to be made, subjec
Page 97 and 98:
ANNEXURE - A PROFORMA OF INDENTURE
Page 99 and 100:
8. That the Contractor hereby charg
Page 101 and 102:
INDEX INSTRUCTION TO BIDDERS ------
Page 103 and 104:
SPECIFIC CONDITIONS OF CONTRACT ---
Page 105 and 106:
-----------------------------------
Page 107 and 108:
-----------------------------------
Page 109 and 110:
(C) SPECIFIC CONDITIONS OF CONTRACT
Page 111 and 112:
INSTRUCTIONS TO BIDDERS A. General
Page 113 and 114:
4.1 The Bidder is advised to acquai
Page 115 and 116:
C. Preparation of Bids 8.0 Language
Page 117 and 118:
) In the case of successful Bidder,
Page 119 and 120:
15.3 All the above three envelopes
Page 121 and 122:
19.4 The Bidder's names, general te
Page 123 and 124:
unsolicited benefits to the Employe
Page 125 and 126:
SPECIFIC CONDITIONS OF CONTRACT The
Page 127 and 128:
e) The responsibility for making th
Page 129 and 130:
36.1.4 Arms and Ammunition The Cont
Page 131 and 132:
36.1.14 The wage record and wage sl
Page 133 and 134:
The increase/decrease in prices sha
Page 135 and 136:
37.0 Taxation The Contractor shall
Page 137 and 138:
conveyance to Site as no workers/ s
Page 139 and 140:
39.2.9 Approval of Samples prior to
Page 141 and 142:
39.7 Metric Units The Contractor sh
Page 143 and 144:
39.8.1.4 The laboratory shall be co
Page 145 and 146:
the contractor to avoid any interru
Page 147 and 148:
Actual measurement of secured advan
Page 149 and 150:
ADDITIONAL SPECIFIC CONDITIONS OF C
Page 151 and 152:
4.4 No material or equipment may be
Page 153 and 154:
8.0 Technical Data 8.1 Deleted 9.0
Page 155 and 156:
for human safety. Complete sets of
Page 157 and 158:
22.0 Control System During the main
Page 159 and 160:
B) RELATING TO ELECTRICAL INSTALLAT
Page 161 and 162:
sets of working electrical drawings
Page 163 and 164:
18.0 Inspection, Testing and Inspec
Page 165 and 166:
c. Location and rating of sockets a
Page 167 and 168:
26.0 Completion Certificate 26.1 On
Page 169 and 170:
(C) SPECIFIC CONDITIONS OF CONTRACT
Page 171 and 172:
d. Schematic control drawings givin
Page 173 and 174:
11.0 Samples and Prototypes The Con
Page 175 and 176:
to use the plant to Air condition s
Page 177 and 178:
24. Handing over & Taking over proc
Page 179 and 180:
provisions of the Contract at the t
Page 181 and 182:
the extent of loss, damage, cost, c
Page 183 and 184:
ANNEXURE - C PROFORMA FOR BID SECUR
Page 185 and 186:
ANNEXURE - D APPENDIX TO TENDER Imp
Page 187 and 188:
damage, costs, charges and expenses
Page 189 and 190:
ANNEXURE - F To PROFORMA FOR ADVANC
Page 191:
Security which the Employer may hav
show all

REGIONAL INSTITUTE OF MEDICAL SCIENCES IMPHAL ...

You also want an ePaper? Increase the reach of your titles

Delete template?

Save as template?