Bharat Sanchar Nigam Limited - WTR - BSNL
Bharat Sanchar Nigam Limited - WTR - BSNL
Bharat Sanchar Nigam Limited - WTR - BSNL
Create successful ePaper yourself
Turn your PDF publications into a flip-book with our unique Google optimized e-Paper software.
BID Price Rs.563/-<br />
Name of the Division DE (TM)...............................................<br />
<strong>Bharat</strong> <strong>Sanchar</strong> <strong>Nigam</strong> <strong>Limited</strong><br />
(A Govt. of India Enterprise)<br />
DE (TM) / CHW / T-16(A) / Patrolling of OFC Route / 2011-2012<br />
Dated at Chhindwara the 21.12.2011<br />
TENDER FOR SECTION WISE PATROLLING<br />
OF OFC ROUTE FOR ONE YEAR<br />
UNDER<br />
D.E.(TRANSMISSION MAINTENANCE), <strong>WTR</strong><br />
Chhindwara and Rewa<br />
FORM NO................ Receipt No/ D/D No...................................Dated..........................<br />
DATE OF ISSUE of the tender form.........................................<br />
Signature of Issuing Authority
BHARAT SANCHAR NIGAM LIMITED<br />
( A Govt. of India Enterprise)<br />
Office of The Divisional Engineer Transmission Maintenance <strong>WTR</strong>, Chhindwara, 480001.<br />
(Telephone No. Office -07162-248800, Mob- 9425001403, FAX-07162-248801)<br />
No. DE (TM) / CHW / T-16(A) / Patrolling of OFC Route / 2011-12 dated at Chhindwara the 21.12.2011<br />
NOTICE INVITING TENDER<br />
Wax / PVC sealed open tenders are invited for " Section wise Patrolling of OFC Route" under<br />
D.E. (TM), Chhindwara and Rewa on behalf of the <strong>Bharat</strong> <strong>Sanchar</strong> <strong>Nigam</strong> <strong>Limited</strong> from the<br />
experienced Contractors. The tenders for each Division is to be submitted separately and on the Bid<br />
envelope the name of the division should be noted clearly. The cost of the tender form, the EMD<br />
and Security Deposit for each division will be separate. The details are as under.<br />
Sl.<br />
No<br />
Work Particulars<br />
3 Section wise<br />
Patrolling of OFC<br />
Route(max 14<br />
sections) as per<br />
work specified in the<br />
tender documents<br />
1 Section wise<br />
Patrolling of OFC<br />
Route (max 14<br />
sections) as per<br />
work specified in the<br />
tender documents.<br />
Name<br />
of the<br />
Divisio<br />
n<br />
DE<br />
(TM)<br />
Chhind<br />
wara<br />
DE<br />
(TM)<br />
Rewa<br />
Estimat<br />
ed cost.<br />
Rs.<br />
7,00,000<br />
9,00,000<br />
Cost of<br />
Tender<br />
Form<br />
Rs<br />
563/-<br />
563/-<br />
EMD<br />
17,500<br />
22,500<br />
Securit<br />
y<br />
Deposit<br />
70,000<br />
90,000<br />
Last date<br />
& Time<br />
of<br />
submissio<br />
n of Bid<br />
13.00 Hrs<br />
of<br />
10.01.12<br />
Time of<br />
opening of<br />
sealed<br />
tender<br />
15.00 hrs<br />
of<br />
10.01.12<br />
Remarks<br />
The tender<br />
will be<br />
opened in the<br />
office of DE<br />
TM<br />
Chhindwara<br />
Tender forms can be down loaded from our web site http://wtr.bsnl.co.in and such form shall be<br />
considered valid for participation. The cost of the tender document shall be submitted by D/D drawn in<br />
favour of Accounts officer % the DGMM <strong>WTR</strong>, Jabalpur or can be obtained on written request on all<br />
working days between 11.00 hours to 13.00 hours up to 10.01.2012 from O/o, DE (TM), Chhindwara<br />
on payment of Rs. 563/- at Cash Counter, A.O. o/o DGMM,<strong>WTR</strong> Jabalpur or by producing a D/D from<br />
any Nationalized bank for Rs 563/-<br />
1. EMD is to be paid in the form of D/D from any Nationalized Bank/or by ACG-67 (The ACG-67<br />
may be received by paying the EMD amount by cash at Cash Counter, A.O. o/o DGMM,<strong>WTR</strong><br />
Jabalpur.<br />
2. The DGMM, <strong>WTR</strong> Jabalpur reserves the right to reject any or all tenders without assigning any<br />
reason thereof, and he is not bound to accept the lowest tender.<br />
3. Any Bid which is not according to the terms and conditions and specifications mentioned in the<br />
tender document is liable to be rejected.<br />
Divisional Engineer<br />
(TM), <strong>WTR</strong> , Chhindwara
SPECIAL INSTRUCTIONS (TO BE FOLLOWED STRICTLY)<br />
The following papers attached with this tender form are to be duly filled and signed by the bidders.<br />
Schedule - I : Annexure A to G.<br />
Schedule - 2 :<br />
2.1 The tender form should be filled legibly in ink only in English / Hindi. Each page of the tender<br />
schedule and Annexure should be signed by the bidder and returned along with tender. All<br />
conditional / incomplete tenders will be rejected. No erasures or overwriting are permitted. If any<br />
corrections are to be made the entry should be clearly scored out by a single line and encircled and<br />
fresh entry should be made. All such corrections should be authenticated under the full signature<br />
of the person signing the tender. Any tender which does not comply with the requirement will be<br />
treated as invalid.<br />
2.2 Incase of partnership concern all the persons should sign the tender documents. Tender may be<br />
required to have documentary evidence in token of their ownership or partnership or authority to<br />
sign on behalf of registered firm.<br />
3.0 Tender: How to address?<br />
3.1 The tender should be submitted in sealed envelope super scribed with the tender name " Section<br />
wise Patrolling of OFC Route " and the Name of the Division (under DE (TM), <strong>WTR</strong><br />
Chhindwara or Rewa) for which the Bidder is submitting the tender. It should be placed only<br />
in the tender box available in the office of DE (TM), <strong>WTR</strong> Chhindwara not later than 13.00 Hrs.<br />
of dated 10.01.2012.<br />
3.2 The Earnest Money Deposit payable to Accounts officer % The DGMM Jabalpur as mentioned in<br />
clause of the EMD can be paid either in the form of D/D in favour of Accounts officer % the<br />
DGMM, <strong>WTR</strong>. Jabalpur or depositing in cash in the office of Accounts Officer <strong>WTR</strong>, Jabalpur<br />
and, the receipt (ACG –67) in original should be attached with the tender form.<br />
4.0 The tender will be opened at 15.00 Hrs of dated 10.01.2012 by the D.E.(TM), <strong>WTR</strong>,<br />
Chhindwara in the presence of Tender Opening Committee constituted by him and before the<br />
available Bidders or their representatives who may desire to be present.<br />
5.0 The bidder will submit schedule-I Annexure and Schedule- II duly filled in sealed cover with<br />
sealing wax & stamped.<br />
6.0 The tender forms will be available in the office of The D.E. (TM) <strong>WTR</strong>, Chhindwara on all the<br />
working hours from 21.12.2011 to 10.01. 2012( Up to 13.00Hrs) after producing a D/D of Rs.<br />
563/- payable to the Accounts officer O/o the DGMM, <strong>WTR</strong>, Jabalpur or depositing Rs. 563/- by<br />
cash in the office of Accounts Officer <strong>WTR</strong>, Jabalpur, and by producing the receipt (ACG –67) in<br />
original. The cost of tender form is not refundable.<br />
7.0 Each page of the tender form should be signed by the bidder.<br />
8.0 During the entire evaluation process if it is observed that the downloaded document is exactly<br />
not as per the original tender document and or it is tempered/changed/altered / modified in any<br />
way the bid will be rejected.
9.0 SUBMISSION OF BIDS<br />
A. Method of preparation and submission of bid:<br />
A.1 Bid for each tender should be submitted in Three envelops placed inside a main cover. These<br />
envelops should contain the following:<br />
Envelope Marked on the Cover Contents of Envelop<br />
First Bid Security 1. The cost of Tender form in the form of D/D payable<br />
to Accounts Officer O/o Dy.G.M.(Trans. Mtce.)<br />
<strong>WTR</strong>. Jabalpur if downloaded from website.<br />
2. EMD<br />
Second Qualifying Bid 1. All Tender Documents except Annexure G and<br />
supporting documents.<br />
Third Financial Bid 1. Annexure G only.<br />
On all envelopes the name “Bid Security”, “Qualifying Bid” or “Financial Bid” for<br />
each division must be clearly mentioned. The name & address of the firm should be clearly<br />
mentioned on the envelops. The three envelops should be properly sealed (with sealing wax/ PVC<br />
tape) on all the openings. These envelopes are to be placed inside an outer envelope and properly<br />
sealed (with sealing wax/ PVC tape on both side and middle openings). The tenders which are<br />
not submitted in above-mentioned manner will be rejected.<br />
A.2 All envelopes (3 inner & 1 outer) must bear the following:<br />
Tender for " Section wise Patrolling of OFC Route) ” Under D.E (TM), Chhindwara or<br />
Rewa” as the case may be.<br />
A.3 The bidder is bound to all terms, conditions & specifications as detailed in the Tender<br />
documents.<br />
A.4 Any tender with conditions other than those specified in the tender documents is liable to be<br />
summarily rejected. No modification by the contractor in any of the conditions will be<br />
permitted after the tender is opened.<br />
A.5 Tenders should be dropped in person in the tender box placed in the office of DE (TM), <strong>WTR</strong>,<br />
Chhindwara before the closing (date & time) of tender as mentioned in the Tender Form. The slit<br />
of the tender box will be sealed immediately after the specified time for receipt of tender. Any<br />
tender presented in person after the sealing of box will not be accepted by the Divisional Engineer<br />
(TM), <strong>WTR</strong> Chhindwara or by any of the subordinates or will not be allowed to be deposited in the<br />
tender box.<br />
A.6 Postponement of Tender opening: Whenever it is considered necessary to postpone the opening<br />
date of tender / Tenders, the decision will be put-up on the notice board at least one day before the<br />
original date of opening. No correspondence in black and white or in other way will be done with<br />
the bidders who have purchased the tender documents. If the date of opening of bids is declared<br />
as holiday, the bids will be opened on the next working date at the same time and venue.
10. LATE BIDS:<br />
Tenders will not be accepted after the specified time of closing of the tender and the same shall be<br />
rejected and returned unopened to the bidder. It is sole responsibility of the bidder that he<br />
should ensure timely submission of tender.<br />
BID OPENING AND EVALUATION:<br />
11. OPENING OF BIDS BY THE DEPARTMENT:<br />
11.1 The Tender Opening Committee shall open the bids in the presence of bidders or their<br />
authorized representatives who choose to attend, on due date and time. The representatives who<br />
have the authority letter dully signed and stamped by the by bidders will be allowed to be<br />
present during the Tender opening. The bidder’s representatives, who are present, shall sign an<br />
attendance register.<br />
11.2 The Bids will be opened in the following manner:<br />
11.2.1 The Tender Opening Committee will count the number of bids and assign serial numbers to<br />
the bids. For example, if 10 tenders have been received the bids will be numbered as1/10, 2/10<br />
etc. All the members will put their initial on the outer envelopes of all the bids with date.<br />
11.2.2 The envelopes containing the tender and not properly sealed, as required vide para-9 above shall<br />
not be opened and shall be rejected.<br />
12. Security Deposit :<br />
The successful bidder will have to deposit the security amount as indicated in NOTICE<br />
INVITING TENDER in the form of Bank Demand Draft / Bank Guarantee to Accounts Officer<br />
O/o DGMM <strong>WTR</strong>. Jabalpur or depositing in cash in the office of Accounts Officer <strong>WTR</strong>,<br />
Jabalpur and, the receipt (ACG –67) in original should be deposited.
SCHEDULE - I<br />
( Schedule - I annexure - A to G).<br />
ANNEXURE – A<br />
To,<br />
The Divisional Engineer<br />
Transmission Maintenance<br />
<strong>WTR</strong>, Chhindwara<br />
Ref. : Your advertisement dated ................................................<br />
1. I / We do hereby take the contract for "Section wise Patrolling of OFC Route” within the<br />
jurisdiction of D.E. (TM), Chhindwara or Rewa, as the case may be, for one year from the date of<br />
entry into the contract in accordance with the terms and conditions.<br />
2. I / We enter into prescribed agreement within one week or being called upon to do so bearing all<br />
expenses in connection there with including charges for stamps etc. if any and the agreement will be<br />
binding on the undersigned. All the pages of the tender form except page No.8 (Agreement) has<br />
been duly filled in and signed.<br />
3. That until such agreement is executed this tender together with your acceptance there off in writing<br />
shall be in contract.<br />
4. Earnest Money: (EMD)<br />
i) I/ We have understood that the D/D for an amount as indicated in NOTICE INVITING<br />
TENDER in the name of the Accounts officer % DGMM <strong>WTR</strong>, C.T.O. Compound,<br />
Jabalpur should be obtained and attached along with Bid security otherwise tender will be<br />
rejected.<br />
ii ) I/We understand that the Earnest Money of the unsuccessful tenders will be refundable<br />
without interest after final acceptance of the tender and execution of the agreement with the<br />
successful bidder. If the bidder withdraws his tender before its final acceptance of<br />
execution of agreement the earnest money deposit shall be forfeited to the <strong>BSNL</strong>. If the<br />
successful bidder fails to make the Security Deposit or fails to enter into the prescribed<br />
agreement within the prescribed time given by the D.E. (TM), Chhindwara, his Earnest<br />
Money deposit will be forfeited to the <strong>BSNL</strong><br />
5. Security Deposit:<br />
If this tender is accepted, I/We agree to submit a Security Deposit of an amount as indicated in<br />
NOTICE INVITING TENDER to the Accounts officer % The DGMM <strong>WTR</strong>, CTO Compound<br />
Jabalpur within 7 day's of the acceptance of the tender in the form of FDR / D/D which will not<br />
carry any interest on this sum.<br />
6. I /We also agree that decision of the DGMM <strong>WTR</strong>, Jabalpur regarding the meaning and effect<br />
of this tender shall be final and legally binding on me/us.<br />
7. I / We understand that the bidder whose rates are accepted will be liable for compensation to be<br />
paid to the department in the event of failure in supply of items in prescribed time limit. Apart<br />
from forfeited the security deposit liquidated damages of 2 % of the total cost of the order will be<br />
imposed on the contractor for each day of delay and will be deducted from the bills payable to the<br />
contractor.<br />
8. I / We have read the terms and conditions mentioned in schedule - II and agree to abide by all<br />
conditions laid down therein.<br />
9. I / We understand that DGMM <strong>WTR</strong>, Jabalpur is not bound to accept the lowest or any other<br />
tender. He can reject the tender without assigning any reasons. The decision of the DGMM <strong>WTR</strong>,<br />
Jabalpur will be final in all cases.<br />
10. I/We understand that the bidder whose rates are accepted will be liable for the expenses,<br />
department may not incur to meet any emergent situation and work will be carried out at the cost of<br />
bidder.
SCHEDULE --I<br />
( ANNEXURE -B )<br />
QUESTIONNAIRE FORMING PART OF TO BE FILLED IN BY THE BIDDER.<br />
*****************************************************************************<br />
1. Full Name of the firm :<br />
( In capital )<br />
2. Firms address :<br />
3. Telephone (Nos. ) Office / Res. :<br />
4. Is the firm proprietary or partnership. :<br />
5. Name (s) of proprietor of partner :<br />
6. Detail description of similar work carried<br />
out in <strong>BSNL</strong> nature & value of work done<br />
for each. :<br />
7. Has the firm been black listed by an<br />
organization if so, attach the details<br />
of the same . :<br />
8. Income tax A/C No / PAN No. Service :<br />
Tax No (Attach Copy)<br />
9. Details of past work experience of<br />
similar nature and year . :<br />
Work done for :<br />
Name of the organization :<br />
Value of the work :<br />
Passport<br />
Size<br />
photograph<br />
of<br />
proprietor<br />
Certification from past employers should be enclosed with support of above.<br />
I hereby certify that the above particulars are verified and correct.<br />
Passport<br />
Size<br />
photograph<br />
of Partner
SCHEDULE - I<br />
To,<br />
Sir,<br />
The D. E. Transmission Maintenance,<br />
<strong>WTR</strong> Chhindwara, M.P.<br />
ANNEXURE - C<br />
1. With reference to your tender notice No...........................................................................…….... ,<br />
I /We hereby offer the rates for " Section wise Patrolling of OFC Route” under D.E.<br />
(TM), <strong>WTR</strong>, Chhindwara / Rewa.<br />
2. I / We also understand that the house keeping work will be subjected to as per the specification.<br />
3. Rates offered by us given in the enclosed Annexure - D statement .<br />
4. All the Rates are quoted including all the charges, Taxes & duties.<br />
5. The Service Tax as applicable will be charged separately.<br />
Witness:<br />
1. Signature<br />
Name<br />
Address<br />
Dated<br />
2. Signature<br />
Name<br />
Address<br />
Dated<br />
Signature of bidder<br />
for / on behalf of<br />
(Name of firm & stamp)
SCHEDULE - I<br />
ANNEXURE - D<br />
TENDER PROFILE<br />
The bidder is requested to submit the following along with the tender form.<br />
1. FINANCIAL STANDING : ( Please submit the prior report )<br />
2. PERFORMANCE CERTIFICATES : ( Please submit the certificate from reputed dealer &<br />
list them )<br />
3. SERVICE NETWORK : ( Please submit the details about R. C. dealers / service<br />
centers offices/dealers/support/staff at Jabalpur<br />
Signature of the Bidder<br />
Note :<br />
THE ABOVE POINTS WILL ALSO BE TAKEN INTO CONSIDERATION DURING<br />
EVALUATION OF THE TENDER AND WEIGHTAGE WILL BE GIVEN FOR ABOVE POINTS.<br />
T0,<br />
ANNEXURE -E<br />
The Divisional Engineer<br />
Transmission Mtce, <strong>WTR</strong>, Chhindwara.<br />
Form No. ……………......................<br />
Date of Issue ..........................<br />
Signature of Issuing authority........................<br />
I………………………………………Son of ……………………………………..<br />
Relative of ………………………………..hereby certify that none of my relative(s) as defined in<br />
the tender document is/are employed in <strong>BSNL</strong> unit as per details given in tender document.. In<br />
case at any stage, it is found that the information given by me is false/ incorrect, <strong>BSNL</strong> shall have<br />
the absolute right to take any action as deemed fit/ without any prior information to me.<br />
Signature of the Bidder : .......................................................<br />
Name in the Block Letters: .......................................................<br />
Address with Seal ...................................................
A G R E E M E N T<br />
(ANNEXURE-F )<br />
1. THIS AGREEMENT made this ................... day of ...........................of year<br />
...................................... between the <strong>Bharat</strong> <strong>Sanchar</strong> <strong>Nigam</strong> <strong>Limited</strong> , herein after called " The <strong>BSNL</strong> "<br />
( Which expression shall unless excluded by or repugnant to the context, includes his successors and<br />
assigns ) of the one part and ............................... a sole proprietary firm / a partnership firm or a company<br />
incorporated under the Indian companies act and having its registered office at<br />
..................................................hereinafter called the "contractor " ( which expression shall unless<br />
excluded by or repugnant to the context, include its successors and assigns ) of the other part .<br />
WHEREAS THE <strong>BSNL</strong> is desirous of appointing the said contractor for " Section wise<br />
Patrolling of OFC Route” within the jurisdiction of The D.E. (TM) <strong>WTR</strong>, Chhindwara / Rewa from<br />
.......……….........to..................................<br />
AND WHEREAS the said contractor has agree to undertake the work of House keeping as per the<br />
terms and conditions herein after contained.<br />
NOW THIS AGREEMENT WITNESSED and it hereby agreed and declared as follows:<br />
The tender notice, Instructions to bidders, conditions of contract, construction<br />
specifications, guide lines to contractor schedule, letter of intent No.....................................................<br />
dated......................... (along with its enclosures) annexed hereto and such other additional particulars,<br />
instructions, drawing as may be found requisites to be given during execution of the work shall be<br />
demand and taken to be an integral part of the contract and send also be demand to be included in the<br />
expression " Contract " or contract document wherever herein used.<br />
In consideration of the payments to be made to the contractor for the works to be executed by him<br />
the contractor hereby convenient with the <strong>BSNL</strong> that the contractor shall in accordance with the contract<br />
documents duly provide, execute, complete the said works and shall perform all other acts, deeds, matters<br />
and things in the contract mentioned or described or which are to be implied there from or may reasonably<br />
necessary for the completion of the said works and at the time and in the manner and subject to the terms<br />
and conditions of stipulations mentioned in the contract.<br />
In consideration of the due provisions, executions and completion of the said works, the <strong>BSNL</strong><br />
hereby agrees with the contractor that the BSML will pay to the contractor the respective amounts for the<br />
work done by contractor under the provisions of the contract.<br />
In Witness where of the parties here to have executed these presents the day and the year first<br />
above written.<br />
1. Signature : Signature and delivered for and<br />
on behalf of <strong>Bharat</strong> <strong>Sanchar</strong> <strong>Nigam</strong> Ltd.<br />
Name :<br />
Designation :<br />
2. Signature :<br />
Name :<br />
Designation :<br />
In the presence of<br />
1. Signature<br />
Name<br />
Designation.<br />
2. Signature<br />
Name<br />
Designation<br />
Signed and Delivered by/for<br />
and on behalf of bidder
INSTRUCTIONS TO BIDDERS<br />
1. The bidder must carefully read all the terms and conditions to bidders detailed below before filling<br />
up the tender schedule and his quotation.<br />
2. Tender in sealed covers should be super scribed " Section wise Patrolling of OFC Route” under<br />
the DE (TM) <strong>WTR</strong>, Chhindwara / Rewa. The name and address of firm / Agency should be<br />
indicate on bottom left hand corner of the envelope.<br />
3. Tenders received in unsealed cover will neither be opened nor considered. Such tender will only be<br />
recorded until a request is received from the bidder at any time for return of any demand draft as<br />
EMD enclosed.<br />
4. Closing of the cover with gum or stapling the cover with stapler or pasting adhesive tape etc. will not<br />
be treated as the same as sealed cover. The cover should bear the seal of the bidder over sealing wax<br />
properly fixed.<br />
5. Complete set of tender document inclusive of notice inviting tender. Instructions to bidders,<br />
conditions of contract specification and tender schedule signed by the bidder or his authorized<br />
representative who is authorized to sign. The tender document should be signed on each page of<br />
tender document as the acceptance of all terms and conditions of tender documents and should be<br />
submitted.<br />
6. Rate should be quoted both in words and figures. The rates quoted in words will be taken as correct<br />
for the purpose of evaluation.<br />
7. Any tender not accompanied by the prescribed E.M.D. (Unless exempted from payment of EMD), is<br />
liable to be rejected.<br />
8. Any tender not strictly according to any of the conditions will not be permitted.<br />
9. Modification by the bidder in any of the conditions will not be permitted.<br />
10. During the execution of Patrolling of OFC Route work it is the sole responsibility of the<br />
Contractor/ Agency to comply all the obligations of Labour Act ; EPF, ESI etc and the<br />
amendments in it from time to time which ever / where ever is applicable, and the Law of<br />
Land.<br />
11. Document to be submitted with the tender: -<br />
(i) Experience / Performance Certificate from the competent authority of doing similar<br />
work at least for Two Years in <strong>BSNL</strong>. An experience certificate (issued by not below<br />
the rank of DE or equivalent) should be submitted.<br />
(ii) The Firm shall have the minimum Turn Over of one third amount of the cost of the<br />
tender in any one financial year in the last three financial years (in any financial year<br />
2007-2008 to 2009-2010).<br />
(iii) <strong>BSNL</strong> Relative Certificate.<br />
(iv) One Copy of complete set of tender document duly signed on each page and also at every<br />
correction or overwriting by the bidder.<br />
(v) E M D in the manner prescribed unless exempted.<br />
(vi) Original power of attorney in case, any person other than bidder himself has signed the<br />
tender document .<br />
(vii) Authorized copy of partnership deed in case of partner ship firm.<br />
(viii) The information about bidder / questionnaire supplied along with the tender document to<br />
be filled in complete in all respect.<br />
(ix) Attested Photocopy of the Registration of Firm.<br />
(x) Photocopy of the PAN Card.
12. Tender may be sent by registered post or deposited in the tender box kept with the D.E. (TM),<br />
<strong>WTR</strong>, Chhindwara.<br />
13. No tender will be received in person by the D.E. or any other staff subordinate to him.<br />
14. Late tenders: The slit of the tender box will be sealed immediately after the specified time for<br />
receipt of tender. Any tender received by post or courier service after the tender box is sealed will<br />
not be opened or considered. Such late tenders will be opened only when a request is made by<br />
bidder for return of any demand draft enclosed as EMD in such of cases the D/D will be returned<br />
in original and other documents will not be returned.<br />
15. The tender schedule is to be read in conjunction with specifications, instructions to bidder,<br />
conditions of contract, notice inviting tender and other parts of the tender document. It is under<br />
stood and agreed that the bidder by careful examination of the document has satisfied himself of<br />
the various terms, conditions and specifications set out therein before giving his tender rates.<br />
16. The DGMM <strong>WTR</strong>, Jabalpur is not bound to accept the lowest or other tender. He can reject the<br />
tender without assigning any reason. The decision of the DGMM <strong>WTR</strong>, Jabalpur will be final in<br />
all the cases.<br />
17. A tender by partner ship firm must be signed separately by each partner and in event of the absence<br />
of any partner it must be signed by a person holding a power of attorney and tender should<br />
accompany such power of attorney and tender should accompany such power of attorney & it<br />
must also disclose that the firm is fully registered under the Indian partnership Act.<br />
18. The contractor shall not assign or sublet the work to any third party and if the contractor assigns or<br />
sublets his contract or attempt to do so or becomes insolvent, D.E. (TM) concerned, there upon<br />
serve a notice rescinding the contract and EMD paid by the contractor shall there upon stand<br />
forfeited.<br />
19. The D.E. (TM) concerned reserves the right to recover departmental claims arising from this<br />
contract from the amount due to the contractor on this work or under any other contract.<br />
20. The <strong>BSNL</strong> reserves the right to reject or consider any tender deficient or incomplete in any of the<br />
requisite matters particulars or formalities or for any reason which shall not be disclosed to the<br />
bidder, without assigning any reason whatsoever.<br />
21. The tender documents are not transferable.<br />
22. The contractor shall take every measure for proper execution of work included in the contact<br />
whether original/ altered according to the indent and measure of the drawings and specifications.<br />
23. Submission of tender will bind the bidder to acceptance of all conditions specified in the tender<br />
document.<br />
24. The DGMM <strong>WTR</strong>, Jabalpur has power to make any alteration, omissions, addition or substitution<br />
from the original specification / drawing in the interest of service of department and the contractor<br />
has to carry out the work in accordance with the revised instructions. Any alteration/addition or<br />
substitution which the contractor may be directed to do in the manner specified above as a part of<br />
the work should be carried out by the contractor on the same conditions and in all respects on<br />
which he agreed to do the main work. If the rates for the additional, altered or substituted work are<br />
not specifically provided in contract, the rates will be decided from the rates for similar class of<br />
work or on the basis of the prevailing market rates.<br />
25 The DGMM <strong>WTR</strong>, Jabalpur has full right to allot the work to any one bidder if similar rates<br />
quoted by the bidders for " Section wise Patrolling of OFC Route "<br />
26. Terms & Conditions :<br />
a) The bidder must have experience of doing similar works at least for Two Years in <strong>BSNL</strong>. .<br />
An experience certificate (issued by not below the rank of DE) should be submitted.<br />
b) The near relatives of all <strong>BSNL</strong> Employees either directly recruited or on deputation are prohibited<br />
units of <strong>BSNL</strong>. The detailed from participation in tender and execution of works in the different<br />
guidelines in this regard are given in the following paragraphs:
i) The near relatives for this purpose are defined as :<br />
a) Member of a Hindu undivided family.<br />
b) They are husband and wife.<br />
c) The one is related to the other in the manner as father, mother, son(s) & son’s wife<br />
(daughter-in-law), Daughter(s) & daughter’s husband (son-in-law), brother’s wife,<br />
sister(s) & sister’s husband brother-in-law).<br />
ii) As per Govt. of India’s CCS Conduct rule 4 no Govt. servant shall in the discharge of<br />
his official duties deal with any matter or sanction any contract to any company or for<br />
any other person, if any member of his family is employed in that company or firm<br />
under that person or if he or any member of his family is interested in such matter or<br />
contract in any other matter.<br />
iii ) The company or firm or any other person is not permitted to tender for work in <strong>BSNL</strong><br />
unit in which his near relative(s) is (are) posted. The unit is defined as<br />
SSA/Circle/Chief Engineer/Chief Arch./ Corporate office for non-executive &<br />
executive Employees.<br />
iv) Bidder should fill-up the <strong>BSNL</strong> relative certificate given in the tender form in<br />
Annexure- F.<br />
27. Earnest Money Deposit :-<br />
a) Earnest money deposit of unsuccessful tender shall be refunded after final acceptance of tender<br />
and within reasonable time, but not later than six months from the date of final acceptance of<br />
tender.<br />
b) The E.M.D. of successful bidder shall be refunded after signing of agreement and deposit of SD.<br />
c) The E.M.D. will not carry any interest for any period whatsoever.<br />
d) E.M.D. will be forfeited by the <strong>BSNL</strong> in the event of the bidder withdrawing his offer before final<br />
acceptance of tender.<br />
28. Security Deposit. :-<br />
a) The person / persons whose tender (s) may be accepted (Herein after called the contractor)<br />
will have to submit a security deposit of an amount as indicated in NOTICE INVITING<br />
TENDER to the Accounts Officer % The DGMM <strong>WTR</strong>, Jabalpur.<br />
b) Security Deposit will not bear any interest for any period whatsoever.<br />
c) Security Deposit shall be liable for appropriation / adjustment against any liquidated damages<br />
for delay in execution of work. If the contractor fails or neglect to perform any of his<br />
obligations under the contract, it shall be lawful for the <strong>BSNL</strong> to forfeit either whole or any<br />
part of the security deposit furnished by the contractor.<br />
d) If the contractor duly performs & completes the contracts in all respect, <strong>BSNL</strong> shall refund<br />
the Security Deposit to the contractor after deducting all costs & other expenses which may<br />
incur for any loss due to any action attributable to the contractor with <strong>BSNL</strong>.<br />
e) Exemption from remitting of security deposit shall be considered under the same conditions<br />
as for exemption of payment of E.M.D.<br />
f) If any bidder withdraws within the validity period or makes any modification in the terms &<br />
conditions of the tender which are not acceptable to the department then the <strong>BSNL</strong> shall<br />
without prejudice to any other right or remedy, be at liberty to forfeit 50 % ( fifty percent ) of<br />
the Security Deposit absolutely.<br />
29. Price validity :- The price quoted should remain firm and valid for any work order, which the<br />
<strong>BSNL</strong> may place within a period of one year from the opening date of tender and until its<br />
complete execution. No variation in price will be allowed within this period for reason<br />
whatsoever.
a) For delay in execution of the work order, liquidated damages at the rate of 0.5 % ( Half percent )<br />
for every day of delay shall be realizable subject to a maximum of 10% ( ten percent ) of the<br />
accepted tender cost. The number of days of delay will be reckoned with the due date of<br />
completion of work. The percentage of liquidated damages will also be work done the cost of the<br />
item of work that is required to be completed on such specified date. On any occasion the<br />
liquidated damages recoverable exceeds 10 % it shall be open to the department to cancel the work<br />
order in respect of the portion of the work remaining incomplete.<br />
b) However, the <strong>BSNL</strong> have discretion to grant extension of time limit for completion of the said<br />
work. If such extension of time limit is granted after any liquidated damages have already become<br />
due realizable, the same shall be recoverable from the contractor. In case the work in whole or<br />
parts of it as required is not completed even in the extended time limit, liquidated damages<br />
realizable amount to the 10%, the <strong>BSNL</strong> may has its option to cancel the work order for the<br />
portion of the work /completion of remaining work. In such cases full amount of Security Deposit<br />
shall be forfeited by <strong>BSNL</strong> in addition to realization of whatever liquidated damages become due.<br />
c) Any amount which become due and recoverable from the contractor on amount of liquidated<br />
damages or on account of any matter relating to this contract, shall also be recoverable from any<br />
sum thereafter may becomes due to the contractor out of this contractor any other contract with<br />
the <strong>BSNL</strong>.<br />
30. The bidder should agree in carry out modifications if any without extra charges.<br />
31. Guarantee :- The contractor shall guarantee that the entire supply work will be done in a<br />
satisfactory manner & free from any defects in all respects He has to give guarantee for quality of<br />
work.<br />
32. If the contractor shall desire an extension of time for completion of the work on the grounds of his<br />
having been unavoidably hindrances in the execution or on any other ground, he shall apply in<br />
writing to the concerned D.E within seven day's of the date of hindrance on account of which he<br />
desires such extension as aforesaid, and <strong>BSNL</strong> shall, if in its opinion (which shall be final ), feels<br />
the grounds reasonable may authorize such extension of time if any, as may be necessary.<br />
33. Price variation :- The <strong>BSNL</strong> shall not be responsible for any escalation in prices of labour or<br />
materials machinery, equipments etc. whatsoever or any increase in duties/leaves/or taxes in<br />
respect there of whatsoever and the tendered rates and the contractor's obligation shall remain<br />
unaffected by such escalation and /or increase.<br />
34. Release of Security Deposit :- The security deposit shall become due for refund/release within<br />
three months from the final completion of work and settlement of the bill.<br />
35. Disputes and Arbitration :- Any dispute arising out of this contract under this notice shall be to<br />
the sole arbitration of DGMM <strong>WTR</strong>, 2nd floor Transmission Building CTO compound, Jabalpur or<br />
an officer nominated or appointed by him on his behalf. His decision shall be final and binding on<br />
both parties.<br />
36. Only those bidders who have sufficient experience of Patrolling of OFC Route Work and<br />
executed the Patrolling of OFC Route work at least for Two Years in <strong>BSNL</strong> and having<br />
certificate regarding successful completion of job, should apply. The Firm shall have the<br />
minimum Turn Over of one third amount of the cost of the tender in any one financial year<br />
in the last three financial years (in any financial year 2007-2008 to 2009-2010).<br />
37. The contractor will have to perform the Route-Patrolling work in the specified sections and at<br />
specified place(s) as per the requisition by the D.E. (TM), concerned.. The D.E. (TM), concerned<br />
has the right of changing the section for Route-Patrolling and his decision will be binding on the<br />
contractor.<br />
38. If the D.E. (TM), concerned considers any personnel employed for Route-Patrolling unsuitable, the<br />
contractor will have to replace the same by another personnel. No incidental expenses will be paid to<br />
the contractor / or its personnel's in any case.
39. It will be the sole responsibility of the contractor to provide the Route-Patrolling services to the<br />
department's satisfaction that all properties remains duly secured / works are executed as per<br />
requirement.<br />
40. The contractor/or its personnel will not cause or permit any nuisance on the site and / or any thing<br />
which will cause unnecessary disturbance or inconvenience to the employees of <strong>BSNL</strong>.<br />
41. Contractor will be responsible for providing all statutory benefits to the Route-Patrolling personnel<br />
employed by him such as W-off, N/Holidays etc. at his own cost and <strong>BSNL</strong> will not entertain any<br />
liability on this account.<br />
42. The Route-Patrolling personnel will be bound to observe all instructions by the D.E. (TM),<br />
concerned and his representatives concerning general discipline.<br />
43. The benefits of provision like bonus, Estt. and provident funds etc. will be the responsibility of<br />
contractor. The D.E. (TM), concerned commitment will be only to the extent to the bills to be paid<br />
to contractor on the rates as agreed to.<br />
44. The D.E. (TM), concerned will not be responsible financially or otherwise for any injury to the<br />
persons employed for Route Patrolling work deployed by the contractor in the course of performing<br />
the duties.<br />
45. The contractor will maintain absolute secrecy with regards all the matters concerning to the care<br />
taking of any aforesaid buildings and also matters that comes to the knowledge of contractor by<br />
virtue of the contract. The DGMM <strong>WTR</strong> Jabalpur may terminate the contract without assigning<br />
any reasons.<br />
46. The Tender for Patrolling of OFC Route is for one year from the date of entering into the<br />
contract however <strong>BSNL</strong> reserves the right to extended the tender up to six months with<br />
mutual consent of the <strong>BSNL</strong> and the Bidder.<br />
47. The Tender cost of the Patrolling of OFC Route is as indicated in NOTICE INVITING<br />
TENDER however <strong>BSNL</strong> reserves the right to extended the tender cost by 50% with mutual<br />
consent of the <strong>BSNL</strong> and the Bidder.<br />
48. <strong>BSNL</strong> reserves the right to have more than one Agency for execution of the said work.<br />
49. If the performance of the Agency is not satisfactory, <strong>BSNL</strong> reserves the right to cancel his<br />
tender. Further he may be debarred / Black listed from <strong>BSNL</strong>.<br />
50. The <strong>BSNL</strong>, where ever required, may terminate the contract by given one month notice<br />
51. The work specification / duties and responsibilities for Route Patrolling are as under :<br />
Section wise Patrolling of OFC route means patrolling of optical fiber cable section<br />
between two OFC stations. Selected OFC route sections will be required for daily patrolling on all<br />
the days of the month. However, the number of sections may vary from time to time depending<br />
upon urgency of the situation. While patrolling the OFC Routes special attention is to be given for<br />
following events.<br />
(A) National Highway Authorities works such as widening of roads, embankment works, culvert<br />
works and tar melting work on the cable routes which may cause damage to the cable.<br />
(B) P.W.D. works as mentioned above.<br />
(C) Water Supply Department works, like trenching on our cable route and as such extreme care is to<br />
be taken
.<br />
(D) Railway Department works, such as construction of over bridges / under bridges etc.<br />
(E) Forest Department works, such as plantation of trees on the cable routes which may cause damage<br />
to the cable .<br />
(F) Electricity Board Works, like trenching on our cable routes, erection of Electricity posts on cable<br />
routes etc.<br />
(G) <strong>BSNL</strong> and other Telecom Operators works, like trenching or other cable work on the <strong>WTR</strong> cable<br />
route.<br />
(H) Putting up of Pandals by social organizations in connections with the visit of VIP, meetings and<br />
functions.<br />
(I) Digging of wells / Pumps sets by private parties near the brim of the Highway.<br />
(J) In all the above instances route patrolling agency, or his representative will contact the officer /<br />
official of the concerned Department / Board on the spots & inform them about the existence of<br />
the <strong>WTR</strong>, O.F. Cable, its importance, the amount of loss that <strong>BSNL</strong> has to face & the heavy<br />
penalties the parties have to pay to the <strong>BSNL</strong> in case they create any fault to the cable. The<br />
patrolling person will also inform the Officer-in-Charge of the section immediately for this<br />
purpose. Within 15 days of signing of the contract, the officer-in-charge of the route will arrange<br />
to provide the contractor, the name, address, telephone No. etc. of the concerned section officerin-charge<br />
of the various departments likely to work along the highway of that section and also the<br />
important telephone numbers of his own / unit officers. If such information, within a fortnight is<br />
not received , the matter is to be brought to the notice of Divisional Engineer in-charge in writing.<br />
(k) These men of the contractor will report to the JTO / SDE about their movements on the road every<br />
day. They should maintain a diary regarding their movement & officers spoken to & submit for<br />
verification at least once every week.<br />
(L) Necessary cycles for this daily patrolling is to be provided by the contractor. They will cover the<br />
cable wherever exposed put soil during the erosion of soil in the rainy season.
ANNEXURE - G<br />
FINANCIAL BID<br />
SCHEDULE FOR QUOTATION OF RATES<br />
""""""""""""""""""""""""""""""""""""""""""""""""""""''<br />
Form No......................... Date of Issue...............................<br />
Signature of issuing authority................................................<br />
The Rates are to be quoted including all the charges, Taxes & duties for "Section wise Patrolling<br />
of OFC Route ” as specified in the tender.<br />
Sl.<br />
No.<br />
1<br />
Categories of work Rate per month<br />
* Section wise Patrolling of OFC Route under D.E. (TM),<br />
....................................as per work specified in the tender<br />
documents.<br />
( Rate per month per section inclusive of all taxes<br />
and duties as applicable for central/ state Govt / local<br />
bodies except service tax. The service Tax will be paid<br />
extra as applicable.)<br />
Rs..........................(Rupees................<br />
...........................................................<br />
...........................................................<br />
...........................................................<br />
......................)<br />
* Section wise Patrolling of OFC route means patrolling of optical fiber cable section between two<br />
OFC stations.<br />
Amount of E M D :<br />
Demand Draft No. :<br />
Drawn by Bank :<br />
Branch :<br />
During the execution of work it is the sole responsibility of the Contractor/ Agency to<br />
comply all the obligations of Labour Act ; EPF, ESI etc and the amendments in it from time to time<br />
which ever / where ever is applicable, and the Law of Land.<br />
The required work of "Section wise Patrolling of OFC Route ” will be started within 7 day's<br />
after placing the order. The rate quoted should be valid for minimum one year from the date of formal<br />
acceptance of the tender. The DGMM <strong>WTR</strong>, Jabalpur reserves the right to accept or reject any or all the<br />
tenders at his discretion without assigning any reason.<br />
Certified that all the terms and conditions included in the tender document are agreed to me.