memorandum for respondent - CISG Database
memorandum for respondent - CISG Database
memorandum for respondent - CISG Database
You also want an ePaper? Increase the reach of your titles
YUMPU automatically turns print PDFs into web optimized ePapers that Google loves.
- 4 - CONTROLS<br />
addition, CONTROLS has not refused to install be<strong>for</strong>e expiration of the additional period of time ending on<br />
9 October 1996 as fixed by Claimant. Moreover, Claimant’s right to declare the contract avoided was<br />
limited according to Art. 51 (1) <strong>CISG</strong>. The delivery and the installation of the control system are two<br />
independent contractual obligations and the delivery of the control system was made in time. Additionally,<br />
Claimant cannot reasonably assert that his right to avoid is extended pursuant to Art. 51 (2) <strong>CISG</strong>, since the<br />
missing installation did not amount to a fundamental breach of contract.<br />
III. Claimant was not authorized to sell the control system pursuant to Art. 88 <strong>CISG</strong>. Claimant had no right<br />
to sell the control system according to Art. 88 (2) <strong>CISG</strong>, since the control system was not subject to rapid<br />
deterioration and the preservation of the control system in the facilities of Claimant would not have<br />
incurred unreasonable expenses. Furthermore, Claimant had no right to sell the control system according to<br />
Art. 88 (1) <strong>CISG</strong>, as there was no unreasonable delay by CONTROLS in taking the control system back and<br />
in paying the costs of preservation. Moreover, Claimant gave no reasonable notice to CONTROLS.<br />
IV. If this Tribunal decides that CONTROLS qualifies under Art. 79 (1) and (2)(a) <strong>CISG</strong> <strong>for</strong> exemption from<br />
paying damages as a result of the delayed installation of the control system, RELIABLE shall be joined to<br />
this arbitration as it was requested by CONTROLS. CONTROLS, Claimant and RELIABLE consent to the<br />
joinder of RELIABLE to the arbitration, since CONTROLS and Claimant have agreed on the joinder of<br />
RELIABLE to the arbitration and CONTROLS and RELIABLE have agreed on the joinder of RELIABLE as well.<br />
Moreover, the joinder of RELIABLE to the arbitration is not prevented by RELIABLE’s non-participation in<br />
the creation of the arbitral tribunal. Furthermore, the fact that CONTROLS and Claimant have agreed on a<br />
“consolidation” does not exclude an implicit agreement on a “joinder”. RELIABLE’s joinder to the<br />
arbitration is reasonable, since the joinder of RELIABLE will not lengthen and complicate the arbitration.<br />
Finally, the working relationship between Claimant and RELIABLE will not be disturbed by RELIABLE’S<br />
joinder.