Download Notice - Chittaranjan Locomotive Works - Indian Railway
Download Notice - Chittaranjan Locomotive Works - Indian Railway
Download Notice - Chittaranjan Locomotive Works - Indian Railway
Create successful ePaper yourself
Turn your PDF publications into a flip-book with our unique Google optimized e-Paper software.
Office of the Dy. Chief Electrical Engineer/M<br />
<strong>Chittaranjan</strong> <strong>Locomotive</strong> works, <strong>Chittaranjan</strong><br />
Telephone-0341<br />
0341-2525542<br />
TENDER NO: EL/CON/274<br />
Name & place of work: -<br />
"Electrification of Type - II Qrs.- 26 Units, Type -III Qrs.<br />
- 12 Units and Type - IV qrs. - 6 units for RPSF staff at<br />
<strong>Chittaranjan</strong>".<br />
Signature of the Tenderer with seal & date Page 1
Issued to ……………………………………………………………………………………..<br />
Of………………………………………………………………………………………………<br />
………………………………………………………………………………………………on<br />
deposit of cost etc. of Rs. …………………………………………………………………..<br />
……………… vide C.R. No. ……………………………………………..date …………..<br />
INDIAN RAILWAYS<br />
<strong>Chittaranjan</strong> <strong>Locomotive</strong> <strong>Works</strong><br />
P.O. <strong>Chittaranjan</strong>, Dist. Burdwan<br />
PREAMBLE AND INSTRUCTIONS TO TENDERER<br />
1. Tender No. EL/CON/274<br />
2. Name & place of work "Electrification of Type - II Qrs.- 26 Units, Type -III Qrs. - 12 Units and<br />
Type - IV qrs. - 6 units for RPSF staff at <strong>Chittaranjan</strong>".<br />
3. Cost of work: Rs. 39,78,096/-(Rupees Thirty nine Lakhs Seventy eight Thousand and ninety six<br />
only)<br />
4. Tender documents consist of following parts: - No of pages<br />
Part-: Preamble and instructions to tenderer<br />
Tender FORM-1<br />
Tenderers credentials FORM-5<br />
I : Regulations of tender<br />
II : Conditions of Tender<br />
III : General & Special conditions of contract<br />
IV : Conditions of price& payment<br />
V : Technical specification& Drawings<br />
VI : Schedule of quantities & rates<br />
Tender documents are not transferable<br />
Signature of the Tenderer with seal & date Page 2
5. Completion period.<br />
The entire work shall be completed within days/months from the date of issue of letter of<br />
acceptance as per following schedule.<br />
i) Submission of Performance Guarantee within 30 days after issue of Letter<br />
of<br />
Acceptance<br />
ii) Completion of work - 06(Six) months from the date of issue of Letter of<br />
Acceptance.<br />
6. Credential of tenderer.<br />
Offers from experienced and competent contractors will be considered (see Form No. 5). The<br />
tenderer will provide satisfactory evidence acceptable to the purchaser regarding experience &<br />
competence.<br />
7. Purchase of Tender Document.<br />
Tender documents can be purchased against payment of Rs 3000/- (Rupees Three thousand) as<br />
applicable as the cost of Tender Form may be deposited with the Chief Cashier /<strong>Chittaranjan</strong><br />
<strong>Locomotive</strong> <strong>Works</strong>/CLW and on production of receipt the Tender can be collected from Dy. Chief<br />
Electrical Engineer (Maint.) central power House/<strong>Chittaranjan</strong> <strong>Locomotive</strong> <strong>Works</strong> during office hours on<br />
any working day in the notified period.<br />
8. Validity of offer.<br />
Tenderer shall keep his offer open for acceptance for a minimum period of 90 days from the date<br />
of opening of the tender.<br />
9. Earnest money.<br />
Tender shall submit along with this tender an amount of Rs.79570/- towards Earnest money in<br />
any of the forms mentioned in Para 2.1 of part II. No interest will be paid on the earnest money.<br />
Offers received without earnest money will be summarily rejected.<br />
10. Sales Tax Clearance Certificate<br />
Tenderer will require to mention VAT Registration No./ Sales Tax Registration No. in the offer.<br />
11. Purchaser not bound to accept any tender.<br />
The purchaser shall not be bound to accept the lowest or any other tender or to assign any reason<br />
for non- acceptance or rejection of a particular tender. The purchaser reserves the right to accept any<br />
tender in respect to the whole or any portion of work specified in the tender paper or to sub divide the<br />
work among different tenderers or to reduce the work or to accept any tender for less than the<br />
tendered quantities without assigning any reason whatsoever.<br />
12. Submission of tender.<br />
The tender, complete in all respect addressed to Dy. Chief Electrical Engineer (Maint) /Central<br />
Power House/CLW/<strong>Chittaranjan</strong> – 713331.Should the aforesaid addressee before 11.30 hrs. on the<br />
notified date. Tender received after this time and date will be rejected. The Tenderer may drop their<br />
tenders duly sealed and superscripted in tender box specially allotted for the purpose and place in the<br />
Signature of the Tenderer with seal & date Page 3
office of said officer mentioned<br />
officer.<br />
above or send the tenders by the registered Post to the address of said<br />
13. Opening of tender.<br />
The tender will be open at 12.00 hrs. on the notified date in the presence of such tenderers who<br />
may like to be present.<br />
14. Clarification.<br />
Should a Tenderer find any discrepancies in or omission from the drawing or any of the tender<br />
documents or should be in doubts as their meaning he should at once notify to the authority inviting<br />
tenders who may send written instructions to all tenderers. It should be understood that every endeavor<br />
has been made to avoid any error which may materially affect the basis of tender and the successful<br />
tenderer should take upon himself and provide for the risk of any error which may subsequently be<br />
discovered and shall make “No Claim” on account thereof.<br />
15. Splitting up of rates.<br />
The rates quoted for the job should be strictly as per the provision made in the schedule. Splitting<br />
up of the job and quoting of rates therefore may result cancellation of the tender.<br />
16. Address to Tenderer.<br />
The tenderer shall state in the tender his postal address and the letter posted to this address shall<br />
deem to have reach the tenderer duly and in time.<br />
17. Contract Agreements:<br />
Successful tender will be required to execute an agreement in the prescribed proforma as at form –<br />
10 by submitting performance Guarantee within 30 days of the date of issue of the letter of acceptance.<br />
18. Security Deposit:<br />
The successful tenderer shall also be required to submit a security deposit in term of clause 3.48 of<br />
Part-III of the contract.<br />
19. <strong>Railway</strong>s Relevant address<br />
<strong>Railway</strong>s relevant addresses for various purposes are as under:<br />
i) General correspondence and submission of tender Dy. Chief Electrical Engineer/Central Power<br />
House/CLW/ CRJ-713331.<br />
ii) Regarding Warranty deposit/Security Deposit:- FA&CAO/<strong>Chittaranjan</strong> <strong>Locomotive</strong><br />
<strong>Works</strong>/<strong>Chittaranjan</strong><br />
Encl: As detailed in para.4<br />
Signature of the Tenderer with seal & date Page 4
FORM –1<br />
<strong>Indian</strong> <strong>Railway</strong>, <strong>Chittaranjan</strong> <strong>Locomotive</strong> <strong>Works</strong>, <strong>Chittaranjan</strong><br />
Tender Form<br />
TENDER<br />
To<br />
The President of India<br />
Acting through the Deputy Chief Electrical Engineer (Maint)<br />
Chittaranajn <strong>Locomotive</strong> <strong>Works</strong>,<br />
<strong>Chittaranjan</strong>.<br />
1. I/We ………………………………………………………………………….. have read the various<br />
conditions to tender attached hereto and hereby agree to abide by the said conditions. I/We also agree to<br />
keep this Tender Open for acceptance fo a period of 90(ninety) days from the date fixed for receiving the<br />
same and in default thereof. I/We will be liable for forfeiture of my/our “security deposit”. I/We offer to do the<br />
works of at the rate quoted in the attached schedule and hereby bind myself/our self to complete the work<br />
within a period of ……………………. Days/months from the date of issue of the letter-communicating<br />
acceptance of my/are tender. I/We also hereby agree to abide by the general. Special & Technical<br />
specifications and additional special conditions of contract and to carry out the work according the<br />
specifications for material and works laid down by the <strong>Railway</strong> for the present contract.<br />
2. The Tenderer whose tender is accepted shall be required to appear at the office of General<br />
Manager, Chief Electrical Engineer, Dy. Chief Electrical Engineer of divisional/district engineer as they may<br />
be in person or if a firm or corporation a duly authorized representative shall so appear and to execute the<br />
contract documents within 15 days after notice that the contract has been awarded to him. Failure to do so<br />
shall constitute a breach of the agreement affected by the acceptance of the tender shall stand forfeited<br />
without prejudice to any other rights or remedies.<br />
3. In the event of any tenderer whose tender is accepted shall refuse to execute the contract<br />
documents as herein before provided the railway may determine that such tender has abandoned the<br />
contract and thereupon his tender and acceptance thereof shall be treated as cancelled and the railway<br />
shall be entitled to forfeit full amount of the earnest money and recover the liquated damages or such<br />
default.<br />
4. Until formal agreement is prepared and executed the acceptance of this tender shall constitute a<br />
binding contract between us as indicated in the letter of acceptance of my/are offer for the works.<br />
*5. I/We produce herewith the Demand Draft/Banker’s Cheque/Fixed Depost receipt<br />
no……………………………… dt. ………………………. For the Rs…………………………… of the<br />
…………………………………………………………………………………….. as deposit of earnest money of<br />
Rs. …………………………………………………………………………..<br />
Signature of the Tenderer with seal & date Page 5
6. I/We have already made the standing earnest money deposit of<br />
Rs……………………………………………………………………………………………. with the <strong>Chittaranjan</strong><br />
<strong>Locomotive</strong> <strong>Works</strong> for my enlistment as an approved contractor in category ……………………………… and<br />
as such no fresh earnest money is being deposited with the tender. I/We further agree and declare that in<br />
case I/We failed to abide by the condition for keeping the offer for 90 days. I/We shall have no objection to<br />
the forfeiture of the security deposit portion of the earnest money amount Rs. …………………………………..<br />
and also in case of my/our default in executing the contract documents within the time limits given in para –II<br />
above. I/We shall beg to no objection to the forfeiture of the full value of earnest money of<br />
Rs…………………….. without prejudice to any rights or remedies of the railways and the said amount may<br />
be released by the President of India also from my/our said lump sum deposit of Rs……………………. As<br />
standing earnest money.<br />
*Strike out and initial the para<br />
which do not concern the Tenderer<br />
( to be filled by the Tenderer)<br />
NAME:<br />
……………………………………………………………………………..<br />
Address: …………………………………………………………………………...<br />
……………………………………………………………………………<br />
…………………………………………………………………………..<br />
Signature of witnesses to the signature of Tenderer(s)<br />
1. …………………………… Name :……………………………………………<br />
Address:…………………………………………..<br />
2……………………………. Name :…………………………………………….<br />
Address: ………………………………………….<br />
Signature of the Tenderer with seal & date Page 6
FORM-5<br />
TENDERER’S CREDENTIAL<br />
Please fill in the questionnaire below:-<br />
1(a) Give details of your previous experience on supply, installation of similar equipment (Give<br />
particulars of order and customer)<br />
(b)<br />
Give particulars of orders under execution by your firm.<br />
2. Give details of technical personnel employed by you and brief, note about their qualification and<br />
experience.<br />
3. Give the name of manufacturers from whom supply is a assured.<br />
Give the name of your Banker’s and their reference.<br />
Note :_ This Form shall be precisely and with full details.<br />
Signature of the Tenderer with seal & date Page 7
<strong>Chittaranjan</strong> <strong>Locomotive</strong> <strong>Works</strong><br />
P.O. <strong>Chittaranjan</strong>, Dist. Burdwan<br />
PART-1<br />
REGULATIONS FOR TENDER<br />
1.1 Tender papers:<br />
The regulations and conditions for Tender, General and special condition of contract,<br />
supplementary condition of contract and specification, along with schedule of requirement<br />
included in part I to VI shall hereafter be collectively referred to as Tender papers.<br />
1.2 Meaning of Terms:<br />
In this regulation for tenders and contracts the following terms shall have the meanings assigned<br />
here under except where the context otherwise requires:-<br />
a) “<strong>Railway</strong>” shall mean the President, Union of India or General Manager or Administrative officer<br />
of <strong>Chittaranjan</strong> <strong>Locomotive</strong> <strong>Works</strong>, <strong>Chittaranjan</strong> or of successor railway authorized to invite<br />
tenders and enter into contract for works on behalf of the President.<br />
b) “Successor <strong>Railway</strong>” shall mean and include such other railway to which for administrative or<br />
other reasons this contract may during its pendency be transferred<br />
c) “General Manager” shall mean the officer in administrative charge of <strong>Chittaranjan</strong> Loco <strong>Works</strong> and<br />
include the General Manager of successor <strong>Railway</strong>.<br />
d) “Chief Electrical Engineer” means the Officer in-charge of the Electrical Work is in <strong>Chittaranjan</strong><br />
<strong>Locomotive</strong> <strong>Works</strong>, <strong>Chittaranjan</strong> and includes Chief Electrical Engineer of successor <strong>Railway</strong>.<br />
e) “Engineer” shall mean the Dy. Chief Electrical Engineer/Con. Or Dy. Chief Electrical<br />
Engineer/Maint.CLW and shall inspector the superior officers of Electrical department at CLW or<br />
successor <strong>Railway</strong><br />
f) “Engineer’s Representative” shall mean the assistant/Sr. Electrical Engineer in direct charge of the<br />
work and shall include any Inspector or supervisor working under him and shall include any<br />
Inspector or supervisor working under him and shall include Engineer representative of successor<br />
railway.<br />
g) “Specification” shall mean the technical specification for materials process and testing of products<br />
referred to in part V of Tender documents as may be revised or superseded by special<br />
specification.<br />
h) “Drawing” shall mean the maps, drawing, plans and prints there of annexed to the contract and<br />
shall include any modification of such drawings as may be issued by the Engineer from time to<br />
time.<br />
Signature of the Tenderer with seal & date Page 8
i) “Period of maintenance” shall mean the specified period of maintenance from the date of<br />
completion of the work as certified by the Engineer.<br />
i) “Month” means any consecutive period of 30 days<br />
j) “Schedule of Requirement” CLW shall mean the schedule of requirement issued under the<br />
authority of Chief Electrical Engineer.<br />
1.3 Singular & Plural<br />
Words importing the singular number shall also include the plural and vice-versa where the<br />
context as requires.<br />
1.4 Interpretations:<br />
This regulation, for tender, shall be read conjunction with conditions of tender general condition<br />
of contract as well as the general and special condition of contract for works which are referred<br />
to herein and shall be subject to modification, addition or supersession by supplementary<br />
condition of contract and/or specification, if any, annexed to tender forms.<br />
1.5 Contractor’s credentials:-<br />
The tenderer must have successfully completed at least a work of:-<br />
New wiring/ Rewiring of office building. Quarters/ Earthing of office buildings or<br />
quarters and HT cable laying and,or HT panel installation/ Provision of HT overhead<br />
conductor.<br />
The Tenderer who will not submit the above credentials such tender may not be considered.<br />
a) Documents to be submitted<br />
(i) Tenderers are required to submit authenticated certificates along with the Tender Form from<br />
Officer(s) of<br />
Government/ Public Sector Undertakings under whom the works have been executed indicating<br />
there in the<br />
name of works executed, value of works/ payment details and period during in which completed.<br />
Such<br />
certificates should have signature and the seal of the Officer(s).<br />
(ii) Tenderers should have valid Electrical Contractor’s License and Supervisor’s Certificate of<br />
competency, copy<br />
of which should be submitted along with tender offer and should have experienced of similar<br />
type of work in<br />
<strong>Railway</strong> or other Govt. undertaking units<br />
(iii) Tenderer should have valid Supervisors certificate of competency. Copy of which should be<br />
submitted along<br />
Signature of the Tenderer with seal & date Page 9
with tender offer.<br />
(iv)<br />
(v)<br />
(vi)<br />
List of Personnel, Organization available on hand and proposed to be engaged for the subject<br />
work.<br />
List of plant and machinery available on hand (own) and proposed to be inducted (own and<br />
hired to be given separately) for the subject work.<br />
List of works completed in last three financial years giving description of work, organization to<br />
whom executed, approximate value of contract at the time of award, date of award and date of<br />
scheduled completion of work. Date of actual start, actual completion and final value of contract<br />
should also be given.<br />
Tender committee would satisfy themselves about the authenticity of the certificates produced<br />
by the tenderer(s) to this effect which may be an attested certificate from the employer /client,<br />
audited balance sheet duly certified by the chartered accountants etc<br />
1.6 Care in submission of tenders:<br />
a) Before submitting a tender, the tenderer will be deemed to have satisfied himself by actual<br />
inspection of the site and locality of the works, that all condition liable to be encountered during<br />
the execution of the works are taken into account and that the rates he enters in the ender forms<br />
are adequate and all inclusive to accord with the provision in clause 3.46 of General and Special<br />
condition of contract Part III for the completion of works to the entire satisfaction of the engineer.<br />
b) When work is tendered to do by a firm or company of contractors, the tender shall be signed by<br />
Individual, legally authorized to enter into commitments on their behalf.<br />
1.7 FORM OF TENDER<br />
a) All the documents to be submitted in connection with this tender should be signed in English or<br />
in Hindi and in ink.<br />
b) The tender shall be submitted in the prescribed form annexed hereto. The rate wherever quoted,<br />
must be clearly written in figure and in words in the rate quoted, no fraction is permitted. The<br />
rate quoted must be firm, precise and unconditional.<br />
c) Dimension, weight etc. shall be quoted ‘IN MATRIC SYSTEM.<br />
d) The tender not submitted along with the following documents will be summarily rejected. Each<br />
copy of the tender shall consist of the following:<br />
1) Tender Form.<br />
2) Details of contract for similar works executed, if any.<br />
3) Any other technical information, the tenderer may wish to furnish.<br />
4) Deposit receipt/cash receipt/Demand drafts for the earnest money in original.<br />
5) Current Income Tax and sales tax clearance certificate.<br />
6) Contractor’s license no. and copy of license issued by State Govt. Director of Electrical.<br />
7) Valid supervisor certificate of competency and declaration by the supervisor that he is<br />
on the role of tenderer.<br />
8) Banker’s certificate in respect of financial capability to execute the work.<br />
Signature of the Tenderer with seal & date Page 10
e) Any clarification required by the tender may be obtained from the Engineer/CLW.<br />
1.8 NOTE<br />
i) The tender paper duly signed in ink by the tenderer on each and every page in token of<br />
his having studied the same carefully shall be submitted.<br />
ii) Deviation from the tender paper will not normally be agreed to.<br />
iii) The tenderer shall indicate the schedule of time for completion of work, with reference<br />
to the date of issue of the acceptance letter regarding placement of contract.<br />
iv) If any item is excluded by the tenderer submitting this tender the tender is likely to be<br />
rejected.<br />
v) The tender documents are not transferable.<br />
PART – II<br />
CONDITION OF TENDER<br />
2.1 Manner of Deposit of Earnest money:<br />
The total sum of earnest money as indicated in “Instruction to tenderers” constitutes the earnest<br />
money for the tender. The deposit of earnest money may be made in cash or in any of the<br />
following forms;<br />
i) Deposit Receipt, Pay Order, Demand Draft, banker’s cheque of STATE BANK OF INDIA including<br />
national bank.<br />
ii)<br />
iii)<br />
The bank concerned lodges with the Reserve Bank of India requisite securities namely cash<br />
deposits of Govt. securities in respect of the guarantees executed by it and Reserve Bank of India<br />
advice the <strong>Railway</strong> that the bond may be accepted.<br />
Govt. securities (Stock certificate, Bearer Bonds, promissory notes, cash certificate) will not be<br />
accepted.<br />
Pursuant to Rly. Bd.’s letter No. 88/CE-1/CT/1(Vol.II) dated 6.8.96 Standing Earnest<br />
Money/Earnest Money in the form of Guarantee Bonds; Government Securities (Stock<br />
Certificates, Bearers Bonds, Promissory notes, Cash Certificates) will not be accepted. In case the<br />
tenderer withdraw his offer within validity date of his offer or failure to undertake the contract<br />
after acceptance of his tender the full amount of Earnest Money deposited will be forfeited.<br />
Signature of the Tenderer with seal & date Page 11
2.2 Authority in whose favour the deposit of earnest money, security deposit and Performance<br />
guarantee shall be made.<br />
a) “Deposit receipt” /”Pay order”/”Demand Draft”/Banker’s Cheque” towards deposit of earnest<br />
money for the tender should be drawn in favour of the FINANCIAL ADVISER & CHIEFACCOUNT<br />
OFFICER, CHITTARANJAN LOCOMOTIVE WORKS, CHITTARANJAN.<br />
b) Deposit of earnest money in cash should be made to the Asstt. Chief Cashier, CLW at <strong>Chittaranjan</strong><br />
but before making the deposit, an authority slip should be obtained from the Office of Electrical<br />
Engineer/CLW/CHITTARANAJN. It should be clearly noted that without the authority slip the<br />
deposit of earnest money in cash shall not be accepted by the Asstt. Chief Cashier.<br />
(c) The performance guarantee in the form of irrevocable bank guarantees amounting to 5% of the<br />
contract value. The performance guarantee should be furnished by the successful contractor<br />
after the letter of acceptance has been issued, but before signing of the agreement and should<br />
be valid up to expiry of the maintenance period of 12 months + a claim period of further 6/12<br />
months as applicable and details mentioned in clause 4.10 of Part- IV.<br />
The total amount of earnest money notified in the tender shall constitute as the initial<br />
security deposit for keeping the offer open for the period specified in the “tender”. It shall be<br />
understood that the tender documents have been issued to tender and tender and tender has<br />
been permitted to tender for the works/supply in consideration of the stipulation on his part that<br />
after submitting his tender the tender will not be resilient from his offer of modify the terms and<br />
conditions thereof in a manner not acceptable to the <strong>Railway</strong>. Should the tenderer failed to<br />
observe or comply with the foregoing stipulation, the initial security deposit mentioned herein<br />
above shall be forfeited to the railway.<br />
(d)<br />
(e)<br />
(f)<br />
If the tenderer whose tender has been accepted does not execute the contract agreement within<br />
15 days(fifteen) after receipt of notice issued by the <strong>Railway</strong> that the contract has been awarded<br />
to him OR does not commence the work after receipt of order to that effect, the full value of the<br />
earnest money with the tender shall without prejudice to any rights, remedies available, be<br />
forfeited to the <strong>Railway</strong>.<br />
The contractor should collect the proforma of security deposit for the purpose from the office of<br />
Engineer for correct execution and submission.<br />
The earnest money of the unsuccessful tenderer, as herein before provided, shall be refunded to<br />
the un successful tender as early as possible.<br />
2.3 RIGHT OF RAILWAY TO DEAL WITH TENDERS<br />
i) It shall not be obligatory for the <strong>Railway</strong> to accept the lowest tender and no tenderer shall<br />
demand any explanation for the cause of rejection of his tender. The <strong>Railway</strong> reserves the right<br />
to accept any tender in respect of the whole or any portion of the work specified in the tender<br />
paper or to sub divides the work among the different tenderers to reduce the work or to accept<br />
any tender for less than the tenderer quantities without assigning any reason whatsoever.<br />
ii)<br />
If the tenderer deliberately gives wrong information in his tender or create circumstances for<br />
acceptance of his tender the <strong>Railway</strong> reserve the right to reject such tender at any stage.<br />
Signature of the Tenderer with seal & date Page 12
iii)<br />
If a tenderer expires after the submission of his tender or after the acceptance of his tender, the<br />
<strong>Railway</strong> shall deem such tender as cancelled. If partners of a firm expire after the submission of<br />
the tender or after the acceptance of the tender, the <strong>Railway</strong> shall deem such tender as<br />
cancelled unless the firm retain its character.<br />
2.4 Application of contract act 1872:<br />
The contract act is normally guided by the following:<br />
i) <strong>Indian</strong> contract act 1872<br />
ii)<br />
General conditions of contract, regulation act instructions for tenders and standards Forms of<br />
contract 1989.<br />
In case of conflict between CLW “Electrical department” condition of contract and provision of<br />
general condition of contract 1989 as mentioned above on any point or in respect of any terms<br />
and conditions, the general condition of contract 1989 shall prevail.<br />
2.5 Submission of CREDENTIAL:<br />
Attested copies of documents testifying to the tenderer previous experience and financial status<br />
should be sent with the tender and the original produce when desired by the <strong>Railway</strong>.<br />
2.6 Submission of Tenders.<br />
Tenders must be enclosed in sealed covers, super scribed.“Tenders for<br />
…………………………………………………………….. must be sent by registered post to the address of the<br />
Engineer, <strong>Chittaranjan</strong> <strong>Locomotive</strong> <strong>Works</strong>, <strong>Chittaranjan</strong> –713331, so as to reach not later than<br />
11.30 hrs. on the stipulated date or deposited in special box provided for the purpose in the<br />
Office of the Engineer, <strong>Chittaranjan</strong> <strong>Locomotive</strong> <strong>Works</strong>, <strong>Chittaranjan</strong> – 711331. This will be sealed<br />
at 11.30 hrs. on the stipulated date.<br />
2.7 Non-compliance<br />
Non-compliance with any of the conditions set forth herein above is liable to result in tender<br />
being rejected.<br />
2.8 Authority for Acceptancy<br />
The authority for the acceptance of the tender will rest with the General Manager, <strong>Chittaranjan</strong><br />
<strong>Locomotive</strong> <strong>Works</strong>, <strong>Chittaranjan</strong>-713331, or any subordinate officer authorized by him.<br />
2.9 Execution of Agreement.<br />
The successful tenderer shall be required to execute an agreement with President of India acting<br />
through the Senior/Deputy Chief Electrical Engineer/CLW within 30 days or receipt of acceptance<br />
letter and payment security deposit, as indicated in clause 3.48 of Pt.III contract for carrying out<br />
the work according to general and special conditions for contract supplementary condition of<br />
contract and specification.<br />
2.10 Period of validity of offer.<br />
The tenderer shall keep the offer open for a minimum period of 90 days from the date of opening<br />
of the tender, within which period the tenderer can not withdraw his offer subject to the period<br />
being extended further, if required by mutual agreement from time to time.<br />
2.11 Negotiation.<br />
Signature of the Tenderer with seal & date Page 13
Should the <strong>Railway</strong> decide to negotiate, with the view, to bring down the rates, the tenderer<br />
called for negotiation should furnish the following form of declaration before commencement of<br />
negotiations. “I/We …………………………….. do declare that in the event of failure of contemplated<br />
negotiation relating to tender number……………………………………….. opened on ………………………….<br />
My original tender shall remain open for acceptance on its original items and conditions up to 90<br />
days from the date of negotiation”<br />
2.12 Employment of retired <strong>Railway</strong> officials by the tenderer.<br />
Should a tenderer be a retired engineer of the gazetted rank, or any other gazetted officer,<br />
working before his retirement, whether in the executive or administrative capacity, or whether<br />
holding a pension able post, or now in the electrical department of any of the railways owned an<br />
administered by the President of India for the time being, or should a tenderer, being partnership<br />
firm, have as one of its partners a retired engineer or a retired gazetted officer as foresaid, or<br />
should a tender being an incorporated company have any such retired engineer, or a retired<br />
officer as one of its Director, or should tender, have in his employment, any retired engineer, or<br />
retired gazetted officer as foresaid, the full information as to the date or retirement of such<br />
engineer or gazetted officer from the said service and in cases where such engineer or officer had<br />
not retired from government service at least two years prior to the date of submission of the<br />
tender as to whether permission for taking such contract, or if the contractor be a<br />
partnership firm or an incorporated company to become a partner or director as the case may be<br />
or to make employment under the contractor has been obtained by the tenderer or the engineer<br />
or the officer as the case may be from the President of India or any officer duly authorized by him<br />
in this behalf shall be clearly stated in writing at the time of submitting the tender. Tenderers<br />
without<br />
the information above referred to or a statement to the effect that no such retired engineer or<br />
retired gazetted officer is so associated with the tenderer as the case may be shall be rejected.<br />
2.13 <strong>Railway</strong> official as tenderer’s relatives.<br />
Should a tenderer or contractor being an individual on the list of approved contractors have<br />
relative employed in gazetted capacity in ………………………………………………………………………….<br />
…………………………………………………………………………………………………………………Electrical department of<br />
the <strong>Chittaranjan</strong> <strong>Locomotive</strong> <strong>Works</strong>, <strong>Chittaranjan</strong> or in the case of a partnership firm or company<br />
incorporated under the <strong>Indian</strong> company Law should partner or a relative of the partner or a share<br />
holder or the relative of the share holder being employed in gazetted capacity in the ……………<br />
……………………………………………………………………………………….Electrical department, <strong>Chittaranjan</strong><br />
<strong>Locomotive</strong> <strong>Works</strong>, <strong>Chittaranjan</strong>, the authority, inviting tenders shall be informed of the fact at<br />
the time of submission of tenders, failing which the tender may be rejected or if such fact<br />
subsequently comes to light, the contract may be rescinded in accordance with the provision in<br />
the general condition of the contract.<br />
2.14 Errors, omissions and discrepancies in Tender Document Tenderer’s Risk.<br />
Signature of the Tenderer with seal & date Page 14
Should the tender find this discrepancies in, or omissions from the drawings or any of the tender<br />
forms or should he be in doubt as to their meaning, he should at once notify the authority,<br />
inviting tenders, who may send written instructions to all tenders. It shall be understood that<br />
every endeavour has been made to avoid errors which can materially affect the basis of the<br />
tender and successful tenderer shall take upon himself and provide for the risk of any error<br />
which may subsequently be discovered and shall make no subsequent claim on account thereof.<br />
2.15 Rate to cover Taxes and etc.<br />
For any job which involves supply of materials by the Contractor at his own cost the rate quoted<br />
shall be inclusive of all taxes, charges, octroi and etc. complete. Nothing extra is payable by the<br />
<strong>Railway</strong> over and above the rate quoted for the job.<br />
PART-III<br />
GENERAL AND SPECIAL CONDITIONS OF CONTRACT<br />
3.1 Execution Correlation and Intent of Contract Documents<br />
The contract documents shall be signed in sufficient number of copies by the <strong>Railway</strong> and the<br />
contractor. The contract documents are complementary and what is called for by any one shall be<br />
as binding as if called for by all; the intention of the documents is to include all labor and<br />
materials, equipment and transportation charges necessary for the proper execution of the works.<br />
Signature of the Tenderer with seal & date Page 15
Materials or work not covered by or properly inferable from any heading or class of the<br />
specifications shall not be supplied by the <strong>Railway</strong> to the contractors unless distinctly specified in<br />
the contract documents.<br />
3.2 Service of notice on contractor<br />
The contractor shall furnish to the Engineer the name, designation and address of his authorized<br />
agent and all complaints, notices, communications, and references shall be deemed to have been<br />
duly given to the contractor, if delivered to the contractor or his authorized agent. In the case of<br />
contract by partners, any change in the constitution of the firm shall be forthwith notified by the<br />
Contractor to the Engineer.<br />
3.3 Allotment of <strong>Railway</strong> Land for Labour Camp Go down etc.<br />
Suitable sites of <strong>Railway</strong> land, if available, may be allotted to the Contractor free of charges for<br />
the erection of temporary labour camps, godowns etc. but the Contractor should be prepared to<br />
remove all these structures and make good the land thus allotted to the <strong>Railway</strong>, on receipt of<br />
two weeks’ notice in writing should any necessity arises for utilization of such land for any other<br />
purpose of <strong>Railway</strong>, without claiming any compensation thereof. If the Contractor fails to remove<br />
such camps & structures within two weeks of service of notice, the <strong>Railway</strong> will be at liberty to<br />
have these structures and camps demolished without being liable for shortages and/or damages<br />
to Contractor’s property if there be any and the site cleared by any other agency and to recover<br />
the expenditure incurred therein from any dues of the Contractor outstanding with the <strong>Railway</strong>.<br />
3.4 Supply of Electric Power by the <strong>Railway</strong><br />
Electric connections at 400/300 V required at the site for the purpose of execution of the works<br />
may be provided by the <strong>Railway</strong> from the nearest available poles. All charges for the installation<br />
of Electric connections from the poles to the sites of the works including Boards, switches, meters<br />
etc. and also the charges for Electric current consumption at the rates as may be fixed by the<br />
<strong>Railway</strong> from time to time shall be borne by the Contractor.<br />
3.5 Accommodation<br />
The Contractor shall at his own expense make adequate arrangements for the housings for his<br />
staff and workmen directly or through petty Contractors or sub-constructor employed on the<br />
work and for temporary croche (Bal Mandir) where 50 or more women are employed at a time.<br />
Suitable sites on <strong>Railway</strong> land, if available, may be allotted to the Contractor for the erection of<br />
labour camps.<br />
3.6 Treatment of Contractor’s staff in <strong>Railway</strong> Hospitals<br />
The Contractor and his staff, other than labourers and their families requiring medical aid from<br />
the <strong>Railway</strong> Hospitals and dispensaries will be treated as private parties and charged accordingly.<br />
3.7 Contractor’s Liability to obtain Security Permits<br />
<strong>Chittaranjan</strong> is a protected area entry into this is restricted by issue of Security Permit which is<br />
controlled by the Senior Security Commissioner (RPF)/CLW/<strong>Chittaranjan</strong>. The Contractor should<br />
therefore, arrange to obtain Security Permits of his own as well as his Labours, Supervisors,<br />
Engineer etc. well in advance and they should observe all Rules & Regulations formulated by the<br />
<strong>Railway</strong> from time to time in this respect. The Security Permits are also required for the<br />
materials, machines, and other accessories if any.<br />
3.8 Operation of vehicles on CLW Roads & other places<br />
In connection with operation of vehicles for transport of materials, the Contractor should<br />
observe all Rules & Regulations for running the vehicles, formulated by the provincial<br />
Government and the <strong>Railway</strong> from time to time. Speed restrictions should be carefully observed<br />
on roads.<br />
Signature of the Tenderer with seal & date Page 16
The <strong>Railway</strong> reserve the right to deduct cost of damages to roads, structures & any other assets<br />
caused by the Contractor. Administration’s decision in respect of recovery of the amount of cost<br />
of such damages shall be final and binding on the Contractor.<br />
3.9 Acceptance of issue of note for supply of <strong>Railway</strong> materials.<br />
The Contractor shall accept the issue notes for the materials supplied to him by the <strong>Railway</strong><br />
immediately on supply.<br />
3.10 Settlement of discrepancy in the issue of <strong>Railway</strong> materials.<br />
Any discrepancy or dispute that may arise regarding the quantity or quality of the materials<br />
supplied by the <strong>Railway</strong> should be settled in the course of the 10 days, all arrears cleared and unconditional<br />
receipts given and/or taken.<br />
3.11 Contractor’s responsibility for safe custody of <strong>Railway</strong>’s materials<br />
The Contractor shall be responsible for the safe custody of all Government materials issued to<br />
him and shall duly account for them. He shall take adequate precautions against their loss,<br />
destruction, damage and/or deterioration from whatever cause.<br />
3.12 Causing damages to <strong>Railway</strong>’s equipment, machines, Private Life and Property etc. by the<br />
Contractor.<br />
Any damage caused to equipment, machines and other assets during the period of work shall be<br />
made good by the Contractor to the extent determined by the <strong>Railway</strong>, failing which, the <strong>Railway</strong><br />
will be at liberty to realize such costs from the Contractor in any manner whatsoever.<br />
3.13 Supply of materials by <strong>Railway</strong><br />
Unless otherwise stated in the description of job provided in the “Schedules for the works, all<br />
rates quoted must be inclusive of supply of all materials required for proper execution of the<br />
works as per the specifications. Where the <strong>Railway</strong> is liable under the contract for supply of any<br />
materials for the works, the materials shall be supplied by the <strong>Railway</strong> to the contractor at the<br />
<strong>Railway</strong>’s Godown/store yard free of cost and the contractor shall transport the materials by the<br />
<strong>Railway</strong> shall be made for the calculated requirements only and in a progressive manner keeping<br />
in view of the progress of the works made by the Contractor.”<br />
3.14 Assistance to the Contractor.<br />
The Contractor shall not, accept to the extent specified/agreed to by the <strong>Railway</strong> in the<br />
acceptance of the tender, be entitled to assistance either in the procurement of raw materials,<br />
labour or transport facilities required for the fulfillment of the contract.<br />
3.15 Contractor to execute work with diligence and expedition.<br />
The Contractor shall execute the work with the diligence and expedition, should he refuse or<br />
neglect to comply with any reasonable orders given to him in writing by the <strong>Railway</strong> in<br />
connection with work, or contravene the provisions of the contract, the <strong>Railway</strong> shall be at<br />
liberty to give 07 days’ notice followed by 48 hrs. notice in writing to the contractor requiring him<br />
to make good the neglect or contravention complained of and should the Contractor fail to<br />
comply, with the requisitions made in the notice within 07 days from that date, it should be<br />
lawful for the <strong>Railway</strong> to take the work wholly or in part out of the Contractors hand without any<br />
further reference and get the work or any part there of as the case may be, completed by the<br />
<strong>Railway</strong> or other agencies at the expenses of the Contractor without prejudice to any other rights<br />
or remedies of the <strong>Railway</strong> in this regard.<br />
3.16 Rates for extra items of works.<br />
Any item of work carried out by the Contractor on the instructions of the Engineer which is not<br />
included in the accepted schedule of rates shall be executed at the rates agreed upon between<br />
the Engineer and the Contractor before the execution of such items of works. The Contractor<br />
shall be bound to notify the Engineer atleast 07 days before the necessity arises for the execution<br />
Signature of the Tenderer with seal & date Page 17
of such item of work that the accepted schedule of rates does not include. The rates payable for<br />
such items shall be decided at the meeting to be held between the Engineer and the Contractor<br />
in as short a period as possible after the need for the special item has come to the notice. In case<br />
the Contractor fails to attend the meeting after being notified to do so or in the event of no<br />
settlement being arrived at, the <strong>Railway</strong> shall be entitled to execute the extra works by the<br />
means and the Contractor shall have no claim for loss or damage that may result from such<br />
procedure, provided that if the Contractor shall commence work or incur any expenditure in<br />
regard thereto before the rates shall be determined as lastly hereon to fore mentioned, then and<br />
in such a case the Contractor shall only be entitled to be paid in respect of the works carried out<br />
or expenditure incurred by him prior to the date of rates as aforesaid according to the rates as<br />
shall be fixed by the Engineer.<br />
However, if the Contractor is not satisfied with the decisions of the Engineer in the respect, he<br />
may appeal to the Chief Electrical Engineer within 20 days of getting the decisions of the<br />
Engineers supported by the analysis of rates claimed. The Chief Engineer’s decisions after hearing<br />
both the parties in the matter shall be final and binding on the Contractor and the <strong>Railway</strong>s.<br />
3.17 Time to be the essence of contract.<br />
The time fixed for completion of the works including the extension of time if any shall be deemed<br />
to be of “the essence of the contract” and if the Contractor shall fail to complete the works<br />
within the time prescribed, the <strong>Railway</strong> shall, if satisfied that the works can be completed by the<br />
Contractor within a reasonably short time, thereafter be entitled without prejudice to any other<br />
right or remedy available on that behalf to recover by way ascertained and liquidated damages a<br />
sum equivalent to one half of one percent of the contract value of the works for each week or<br />
part of week the contractor is in default and allow the contractor such further extension of time<br />
as the Engineer may decide.<br />
3.18 Instructions of Engineers Representative<br />
Any instructions or approval given by the Engineer’s representative to the Contractor in<br />
connection with the works shall bind the Contractor as though it had been given by the Engineer<br />
provided always as follows:<br />
a) Failure of the Engineer’s representative to disapprove and work or materials shall not<br />
prejudice the power of the Engineer thereafter to disapprove such work or materials and to<br />
order the removal or breaking up thereof.<br />
b) If the Contractor shall be dissatisfied by reason of any decision of the Engineer’s<br />
representative, he shall be entitle to refer the matter to the Engineer who shall thereupon<br />
confirm or modify such decision.<br />
3.19 Meaning and intent of specification and drawings.<br />
If any ambiguity arises as to the meaning and intent of any portion of the specification and<br />
drawings or as to execution or quality of any work or material or as to measurements of the works,<br />
the decision of the Engineer thereof shall be final subject to appeal (within 10 days of such<br />
decisions being intimated to the contractor) to the Chief Electrical Engineer/Deputy Chief<br />
Electrical Engineer (Maint).<br />
3.20 Provision of efficient competent staff/Engineer.<br />
The contractor shall place and keep on the works at all time efficient and competent staff to give<br />
the necessary direction to his workmen and to see that they execute their work in sound and proper<br />
manner and shall employ only such supervisors, engineer workmen and labourers, in or about<br />
execution of any of the works as are careful and skilled in their various trades and callings. The<br />
contractor shall at once remove from the works any agents, permitted sub-contractor, supervisor,<br />
Engineer and if and whenever required by the Engineer, he shall submit a correct return showing<br />
Signature of the Tenderer with seal & date Page 18
the names of all staff and workmen employed by him. In the event of the Engineer being of the<br />
opinion that the Contractor is not employing on the works a sufficient number of staff and<br />
workmen as is necessary for the proper completion of the works within the time prescribed, the<br />
Contractor shall forthwith on receiving intimation to this effect take on the additional number of<br />
staff and labour specified by the Engineer within seven days of being so required and failure on<br />
the part of the Contractor to comply with such instructions will entitle the <strong>Railway</strong> to rescind the<br />
Contract under Clause 3.52 of these conditions.<br />
3.21 Facilities for inspection.<br />
The Contractor shall afford the Engineer and the Engineer’s representative every facility for<br />
entering in and upon every portion of the work at all hours for the purposes of inspection or<br />
otherwise and shall provide all labours, materials, plants, appliances etc. required for the<br />
purpose.<br />
3.22 Tools, Plant and Materials supplied by <strong>Railway</strong>.<br />
The Contractor shall take reasonable care of all tools, plant and materials or other property<br />
belonging to the <strong>Railway</strong> and committed to his charge for the purpose of the works and shall be<br />
responsible for all damage or loss caused by him, his agents, permitted Sub-Contractor or his<br />
workmen or others while they are in his charge. The Contractor shall sign accountable receipt for<br />
tools, plant and materials made over to him by the Engineer and on completion of the works<br />
shall hand over the unused balance of the same to the Engineers in good order and repair free,<br />
wear and tear expected and shall be responsible for any failure to account for the same or any<br />
damage done thereto.<br />
3.23 Hire or <strong>Railway</strong> Plant.<br />
The <strong>Railway</strong> may give on hire, if available; to the Contractor such plant and machinery as may be<br />
required for the execution of the works on such terms and conditions which should be agreed to<br />
by the <strong>Railway</strong> and the Contractor before-hand through a separate agreement.<br />
3.24 Handing over of works.<br />
The Contractor shall be bound to hand over the works executed under the Contract to the<br />
<strong>Railway</strong>, complete in all respects, to the satisfaction of the Engineer. The Engineer shall<br />
determine the date on which the work is considered to have been completed, in support of<br />
which his certificate shall be regarded as sufficient evidence for all purposes. The Engineer shall<br />
determine from time to time the date on which any particular section of the work shall have<br />
been completed and the contractor shall be bound to observe any such determination of the<br />
Engineer.<br />
3.25 Power of Modification to contract.<br />
The Engineer on behalf of the <strong>Railway</strong> shall be entitled by order in writing to enlarge or extend,<br />
diminish or reduce the works or make any alterations in their design, character, position, site<br />
quantities, dimensions or the method of their execution or in the combination and use materials<br />
for the execution thereof and to other any additional works to be done or any works not to be<br />
done the Contractor will not entitled to any compensation for the actual for the actual amount of<br />
work done and for approved materials furnished against a specific order.<br />
3.26 Measurement certificates and payments, quantity in schedules annexed to contract.<br />
The quantities set out in the accepted schedule of rates with items of works quantified are the<br />
estimated quantities of the works and they shall not be taken as the actual and correct quantities<br />
of the works to be executed by contractor in fulfillment of his obligations under the contract.<br />
3.27 Measurement of works.<br />
Signature of the Tenderer with seal & date Page 19
The Contractor shall be paid for the works at the rates in the accepted schedule of rates and for<br />
extra works at rates determined under clause 3.16 on the measurements taken by the Engineer’s<br />
representative in accordance with the rules.<br />
3.28 Maintenance of works.<br />
The Contractor shall at all times during the progress/and continuance of the works and also for<br />
the period of 12 months after completion of work be responsible for all and every part of the<br />
works and shall make good from time to time any damage or defect that may during the above<br />
period arise in or be discovered or be in any way connected the works.<br />
3.29 Certificate of completion of works.<br />
As soon as in the opinion of the Engineer the works shall have been substantially completed and<br />
shall have satisfactorily passed any final test of tests that may be prescribed, the Engineer shall<br />
issue a certificate of completion in respect of the works and the period of maintenance of works<br />
shall commence from the date of such certificate, provided that the Engineer may issue such a<br />
certificate with respect to any part of the works before the completion of the whole of the works<br />
or with respect to any substantial part of the works which has been both completed to the<br />
satisfaction of the Engineer and occupied or used by the <strong>Railway</strong> and when any such certificate is<br />
given in respect of a part of the works and such part shall be considered as completed and the<br />
period of maintenance of such part shall commence from the date of such certificate.<br />
3.30 With-holding of payment for non production of I.T.C.C. & S.T.C.C. DELETED<br />
3.31 Observance of official secret act.<br />
All drawings supplied to the contract by the <strong>Railway</strong> are confidential and the same must be<br />
strictly confined to the contractor’s own use (except so far as confidential disclosure to Sub-<br />
Contractors, suppliers is necessary) and to the purpose of the contract. They should have to<br />
strictly abide by the I.E. Act at every step wherever required.<br />
3.32 Recovery of advance Income Tax.<br />
Advance Income Tax will be recovered from each bill drawn in favour of the Contractor at the rate<br />
of prevailing percent and surcharge thereon of the amount billed for payment to the Contractor and<br />
the amount recovered will be credited to concerned Income Tax Authority. The recovery of<br />
advance Income Tax shall however not be made if the Contractor produces orders of the<br />
Competent Authority of the Income Tax Deptt. that advance Income Tax is not recoverable from<br />
the Contractor’s bills.<br />
3.33 Submission of programme for execution of the work.<br />
Within thirty days after he has been instructed to take up the work, the Contractor shall submit to<br />
the Engineer for his approval detailed programme showing the sequence of items and activity of<br />
work and its expected date of completion, procedure and method in which he proposes to carry out<br />
the works or wherever required by the Engineer.<br />
3.34 Claim on account of variations in prices for labour & materials<br />
No claim will be entertained by the <strong>Railway</strong> for any fluctuation of market rates in respect of labour<br />
& material and the rates accepted and entered into the Agreement shall hold good irrespective of<br />
any fluctuation of labour and/ or materials cost (for works costing below Rs. 50 lakhs)<br />
Price Variation Clause as per Rly. Bd’s Circular No. 85/WI/CT/7. Pt.-I, New Delhi Dt. 18/19-<br />
4-2006 (with latest amendment) shall be applicable” (for works costing above Rs. 50 lakhs)<br />
3.35 Contractor to arrange tools, plants etc.<br />
3.35 Contractor to arrange tools, plants etc.<br />
All tools & plants and other accessories for the proper execution of the works shall have to be<br />
found and arranged by the Contractor at his own costs.<br />
3.36 Acceptance of materials statement by the Contractor<br />
Signature of the Tenderer with seal & date Page 20
On completion of the work, material statement for Rly. Materials if issued to Contractor, should<br />
be reconciled and finally accepted by the Contractor within 7 days of signing of final<br />
measurements, failing which the <strong>Railway</strong> would be at liberty to pass the bill with the material<br />
statement made out by it as final and no claims or disputes on this account will be entertained<br />
thereafter.<br />
3.37 Documents to be produced by the successful tenderer<br />
Within seven days of receipt of the letter of acceptance the successful tenderer shall produce<br />
before the Engineer/CLW/<strong>Chittaranjan</strong> the following documents:<br />
If the successful Tenderer is an individual carrying on business in a name other than his own, a<br />
duly sworn affidavit (with 3 attested copies) declaration that he is the sole proprietor of the<br />
business.<br />
If a partner firm three attested copies of Deed of partnership and certificate showing that the<br />
firm has been registered with the Registrar of firms.<br />
If a limited liability company, a copy of memorandum and Articles of Association showing the<br />
names of the Directors of the company who are authorized to sign on behalf of the company.<br />
Where the proprietors, partners or directors will not themselves attend to the work but some<br />
other person would do so, a proper power of attorney should be given authorizing. The<br />
constituted attorney to sign the contracts, variations thereof, supplementary agreements,<br />
Measurements, bills, “NO CLAIM” certificates & etc and every change in the Power of Attorney or<br />
withdrawal thereof should be immediately noticed to the Engineer, <strong>Chittaranjan</strong> <strong>Locomotive</strong><br />
<strong>Works</strong>/<strong>Chittaranjan</strong>.<br />
If a limited liability company, a copy of memorandum and Articles of Association showing the<br />
names of the Directors of the company who are authorized to sign on behalf of the company.<br />
Where the proprietors, partners or directors will not themselves attend to the work but some<br />
other person would do so, a proper power of attorney should be given authorizing. The<br />
constituted attorney to sign the contracts, variations thereof, supplementary agreements,<br />
Measurements, bills, “NO CLAIM” certificates & etc and every change in the Power of Attorney or<br />
withdrawal thereof should be immediately noticed to the Engineer, <strong>Chittaranjan</strong> <strong>Locomotive</strong><br />
<strong>Works</strong>/<strong>Chittaranjan</strong>.<br />
3.38 Limitation of <strong>Railway</strong>s Liability to accept change in Power of Attorney<br />
The <strong>Railway</strong> will not be bound by any power of Attorney granted by the Tenderer or any changes<br />
in the composition of the firm made subsequent to the execution of the contract. It may<br />
however, recognize such power of Attorney and changes after obtaining proper legal advice, the<br />
cost of which will be chargeable to the Contractor.<br />
3.39 Indemnification by the Contractor<br />
Where a workman employed by the <strong>Railway</strong> has recovered compensation from the <strong>Railway</strong> in<br />
respect of injury caused under circumstances which create a legal liability of the Contractor to<br />
pay damages in respect thereof, the Contractor shall indemnify the <strong>Railway</strong> in respect thereof<br />
and the <strong>Railway</strong> shall be entitled to deduct from any money due or to become due (Whether<br />
under this contract or any other contract) all money paid or payable by the <strong>Railway</strong> by way of<br />
compensation as aforesaid or the cost of expenses in connection with the claim thereto and the<br />
Contractor shall abide by the decision of the <strong>Railway</strong> as to the sum payable by the Contractor<br />
under the provision of this clause.<br />
3.40 Materials of approved quality to be used.<br />
Signature of the Tenderer with seal & date Page 21
All materials to be used by the Contractor on the work shall be approved quality. The successful<br />
Tenderer shall obtain the approval of site Engineer or his authorized representative for use of all<br />
such materials/equipments not listed in annexure of Pt.-V or whose preferred makes are not<br />
mentioned in the technical specification Pt. V before using them in execution of the work.<br />
3.41 Acceptance of works.<br />
When the execution of any work is completed in all respects, the <strong>Railway</strong> shall be informed in<br />
writing by the Contractor and the <strong>Railway</strong> will arrange to get them inspected and tested at the<br />
cost of the Contractor. On being found satisfactory, the work shall be accepted such acceptance<br />
being communicated in writing to the Contractor.<br />
3.42 <strong>Works</strong> to be finally taken over.<br />
The work shall not be deemed to have been finally taken over by CLW on the above mentioned<br />
acceptance vide clause No.3.41. The Contractor shall be liable for replacement of any defective<br />
material or work whether arising from faulty design, material, workmanship or otherwise, free of<br />
cost during warranty period of 12(twelve) months.<br />
3.43 Contractor’s liability.<br />
The Contractor will be relieved of the liability arising under this contract wherever and to the<br />
extent to which the fulfillment of any obligation under the contract is prevented; frustrated or<br />
impeded by reason of any statutory rules, regulations orders or requisition issued by the<br />
Government Department or other competent authority. The <strong>Railway</strong> will however, not be liable for<br />
any compensation to the Contractor, in any such eventuality.<br />
3.44 Cessations of <strong>Railway</strong>s liability<br />
The <strong>Railway</strong> shall not be liable to the Contractor for any matter arising out of or in connection<br />
with the contract or the execution of the works unless the Contractor shall have made a claim in<br />
writing in respect thereof before the expiry of warranty period.<br />
3.45 Antilarval clause.<br />
The Contractor shall be responsible for anti larval work at his cost during progress of works as<br />
may be prescribed by the Engineer on the advice of the <strong>Railway</strong> Medical authority and where use<br />
of insecticides is involved, it shall be done in accordance with the provision of the act and rules in<br />
this behalf at the cost of the Contractor, who shall also be solely responsible for any acts or<br />
omissions under the provisions of the aforesaid rules.<br />
3.46 Price of stores shall include all rates, Taxes etc.<br />
Save and except as specifically, stated and/or provided for in the tender papers and/or these<br />
special conditions of Contract, the prices for stores etc. are also to include all rates, Taxes, levies,<br />
impositions and outgoings whatsoever and the <strong>Railway</strong> shall have no liability for any of these<br />
charges. The rate of sales tax etc. charged may be indicated. <strong>Railway</strong> is entitled to reduction of<br />
sales tax charge etc. against the submission of ‘D’ form and the tenderer should quote rates<br />
accordingly.<br />
3.47 Provision of payment of wages<br />
The Contractor shall comply with the provisions of the payment of wages Act, 1936 and the rules<br />
made there under in respect of employees directly or through petty Contractors or Sub-<br />
Contractors employed by him in the works.<br />
3.48(a) Security Deposit to be held against the contract<br />
(1) The Earnest money deposited by the successful tenderer with his tender will be retained by the<br />
<strong>Railway</strong>s as part of security for the due and faithful fulfillment of the contract by the contractor.<br />
The balance to make up the security deposit for which are given below., may be deposited by the<br />
Contractor in cash or may be recovered by percentage deduction from the contractor’s “ On<br />
Account” bills. Provided also that in case of defaulting contractor the railway may retain any<br />
Signature of the Tenderer with seal & date Page 22
amount due for payment to the Contractor on the pending “On Account bills”, so that the<br />
amounts so retained may not exceed 10% of the total value of the contract.<br />
(2) Unless otherwise specified in the special conditions, if any, the security deposit/rate of<br />
recovery/mode of recovery shall be as under:-<br />
(a)<br />
(b)<br />
Security deposit for each work should be 5% of the contract value,<br />
The rate of recovery should be @ 10% of the bill amount till the full security deposit is recovered,<br />
Security deposits will be recovered only from the running bills of the contract and no other mode<br />
of collecting SD such as SD in the form of instruments like BG, FD etc. shall be accepted<br />
towards security deposit.<br />
The Security deposit, however, shall be released only after the expiry of the maintenance period<br />
and after passing of the final bill passed on “No Claim” certificate issued by an officer not below<br />
the rank of JAG.<br />
No interest will be payable upon the earnest money and security deposit or amounts payable to<br />
the contractor under the contract, but Government securities deposited in terms of sub-clause<br />
(1) of the clause will be payable with interest accrued thereon.<br />
3.48(b) Performance Guarantee. (P.G) as per <strong>Railway</strong> Board Letter No.2007/CE.I/CT/18 Pt.XII dated<br />
31/12/2010, clause no. 16(4)<br />
The procedure for obtaining performance guarantee is outlined below<br />
(I)The successful bidder shall have to submit a performance Guarantee (PG) within 30 (thirty)<br />
days from the date of issue of Letter of Acceptance (LOA) . Extension of time for submission of<br />
PG beyond 30 (thirty) days and up to 60 days from the date of issue of LOA may be given by<br />
the Authority who is competent to sign the contract agreement. However, a penal interest of<br />
15% per annum shall be charged for the delay beyond 30 (thirty) days, i.e. from 31th day after<br />
the date of issue of LOA. In case the contract fails to submit the requisite PG even after 60<br />
days from the date of issue of LOA, the contract shall be terminated duly forfeiting EMD and<br />
other dues, if any payable against that contract. The failed contractor shall be debarred from<br />
participating in re- tender for that work.<br />
(II) The successful bidder shall submit the performance guarantee (PG) in any of the following<br />
forms, amounting to 5% of the contract value :-<br />
(i) A deposit of cash.<br />
(ii) Irrevocable bank guarantee.<br />
(iii) Government Securities including State Loan Bonds at 5% below the market value,<br />
(iv) Deposit Receipts, Pay Orders, Demand Drafts and Guarantee Bonds. These forms of<br />
Performance Guarantee could be either of the State Bank of India or of any of the<br />
Nationalized Banks.<br />
(v) Guarantee Bonds executed or Deposits Receipts tendered by all Scheduled Banks;<br />
(vi) A Deposit in the Post Office Saving Bank;<br />
Signature of the Tenderer with seal & date Page 23
(vii) A Deposit in the National Savings Certificate;<br />
(viii) Twelve years National Defence Certificates;<br />
(ix) Ten years Defence Deposits;<br />
(x) National Defence Bonds;<br />
(xi) Unit Trust Certificates at 5% below market value or at the face value whichever is less.<br />
Also, FDR in favour of FA& CAO/ CLW/ <strong>Chittaranjan</strong> (free from any encumbrance) may be<br />
accepted.<br />
NOTE: The instruments as listed above will also be acceptable for Guarantees in case of<br />
Mobilization advance.<br />
(III) The performance guarantee shall be furnished by the successful contractor after the Letter of<br />
Acceptance has been issued, but before signing of the agreement. This PG shall be valid up to the<br />
stipulated date of completion plus 60 days beyond that. In case, the time for completion of works<br />
gets extended, the contractor shall get the validity of Performance Guarantee extended to cover<br />
such extended time for completion of work plus 60 days.<br />
(IV) The value of PG to be submitted by the contractor will not changed for variation up to 25% (<br />
either increase or decrease). In case during the course of execution, value of the contract<br />
increases by more than 25 % of the original contract value , and additional PG amounting to 5 % (<br />
five percent) for the excess value over the original contract value shall be deposited by the<br />
contractor.<br />
(V)<br />
The Performance guarantee shall be released after the physical completion of the work based on<br />
the “Completion Certificate” issued by the competent authority stating that the contractor has<br />
completed the work in all respects satisfactorily. The security deposit, however, shall be released<br />
only after the expiry of the maintenance period and after passing the final bill based on “No<br />
Claim Certificate”.<br />
(VI)<br />
Wherever the contracts are rescinded, the security deposit shall be forfeited and the<br />
performance guarantee shall be encashed .The balance work shall be got done independently<br />
without risk and cost of the failed contractor. The failed contractor shall be debarred from<br />
participating in the tender for executing the balance work. If the failed contractor is a JV or a<br />
partnership firm, then every member/partner of such a firm shall be debarred from participating<br />
in the tender for the balance work either in his/her individual capacity or as a partner or any<br />
other JV/partnership firm.<br />
(VII) The Engineer shall not make a claim under the Performance Guarantee except for amounts to<br />
which the President of India is entitled under the contract (not withstanding and/ or without<br />
prejudice to any other provisions in the contract agreement).<br />
i) Failure by the contractor to extend the validity of the Performance Guarantee as described<br />
herein above, in which event the Engineer may claim the full amount of the performance<br />
guarantee.<br />
ii) Failure by the contractor to pay President of India any amount due, either as agreed by the<br />
contractor or determined under any of the clauses/ conditions of the agreement, within 30 days<br />
of the service of notice to this effect by Engineer.<br />
iii) The contract being determined or rescinded under provision of the GCC the Performance<br />
Guarantee shall be<br />
forfeited in full and shall be absolutely at the disposal of the President of India.<br />
Signature of the Tenderer with seal & date Page 24
3.49 Application & provision of contract labour (Regulation & Abolition) Act 1970 and the Central,<br />
Rules 1971.<br />
a) The Contractor shall comply with the provision of the contract labour (Regulation & Abolition)<br />
Act 1970 and the contract labour (Regulation & Abolition) General Rules, 1971 as modified from<br />
time to time wherever applicable and shall also indemnify the <strong>Railway</strong> from and against any<br />
claims under the aforesaid Act and the Rules.<br />
b) The Contractor shall obtain a valid license under the aforesaid Act as modified from time to time<br />
before the commencement of the work. Any failure to fulfill this requirement shall attract the<br />
penal provisions of the contract arising out of the resultant non-execution of the work.<br />
c) The Contractor shall pay to labour employed by him directly or through Sub-Contractors the<br />
wages as per provisions of the aforesaid Act and the Rules wherever applicable. The Contractor<br />
shall not withstanding the provisions of the contract to contrary, cause to be paid wages to<br />
labour indirectly engaged on the work including any engaged by his Sub-Contractors in<br />
connection with the said work, as if the labour had been immediately employed by him.<br />
d) In respect of all labour directly or indirectly employed in the work for performance of the<br />
Contractor’s part of the contract, the contractor shall comply with or cause to be complied with<br />
the provisions of the aforesaid Act and the Rule wherever applicable.<br />
e) In every case in which, by virtue of the provisions of the aforesaid Act & the Rules, the <strong>Railway</strong> is<br />
obliged to pay an amount of wages to a workman employed by the Contractor or his Sub-<br />
Contractor in execution of the work or to incur any expenditure in providing welfare and health<br />
amenities required to be provided under the aforesaid Act and the Rules or to incur any<br />
expenditure on account of the contingent liability of the <strong>Railway</strong> due to the Contractor’s failure<br />
to fulfill his statutory obligations under the aforesaid Act or the<br />
Rules, the <strong>Railway</strong> will recover from the Contractor, the amount of wages so paid or the amount<br />
of expenditure so incurred, and without prejudice to the rights of the <strong>Railway</strong> under Section 20,<br />
Sub-Section(2) and section 22 Sub-Section (4) of the aforesaid Act, the <strong>Railway</strong> shall be at liberty<br />
to recover such amount or part thereof by deducting if from the Security Deposit and or from any<br />
sum due by the <strong>Railway</strong> to the Contractor whether under the Contractor or otherwise. The<br />
<strong>Railway</strong> shall not be bound to contest any claim made against it under Sub-Section (1) of Section<br />
20 and Sub-Section 4 of the section 21 of the aforesaid Act except on the written request of the<br />
contractor and upon his giving to the <strong>Railway</strong> full security for all costs for which the <strong>Railway</strong><br />
might become liable in contesting such claim. The decision of the railway regarding the amount<br />
actually recoverable from the contractor as stated above shall be final and binding on the<br />
Contractor.<br />
(f) For the purpose of the aforesaid Act & Rules the principal Employer shall be the Engineer of the<br />
works.3.50 Signing of “NO CLAIM” CertificateThe Contractor shall not be entitled to make any<br />
claim whatsoever against the <strong>Railway</strong> under or by virtue of or arising out of this contract, nor<br />
shall the <strong>Railway</strong> entertain or consider any such claim, if made by the contractor, after he shall<br />
have signed a<br />
“NO CLAIM” certificate in favour of the <strong>Railway</strong>, in such from as shall be required by the <strong>Railway</strong><br />
after the works are finally measured up. The Contractor shall be debarred from the correctness<br />
of the items covered by “NO CLAIM” certificate or demanding a reference to arbitration in<br />
respect thereof.<br />
3.51 RIGHT OF RAILWAY TO DETERMINATE CONTRACT<br />
(1) The <strong>Railway</strong> shall be entitled to determine and terminate the contract anytime should, in the<br />
<strong>Railway</strong>’s opinion, the cessation of work become necessary owing to paucity of funds or from any<br />
Signature of the Tenderer with seal & date Page 25
other cause whatsoever, in which case the value of approved materials at site and of work done<br />
to the date by the Contractor will be paid for in full at the rates specified in the contract. <strong>Notice</strong><br />
in writing from the <strong>Railway</strong> of such determination and the reason therefore shall be conclusive<br />
evidence thereof.<br />
(2) PAYMENT TO DETERMINATE CONTRACT BY RAILWAY.<br />
Should the contract be determined under sub-clause(1) of this clause and the Contractor claims<br />
payment for expenditure incurred by him in the expectation of completing the whole of the<br />
works, the <strong>Railway</strong> shall admit and consider such claims as are deemed reasonable and are<br />
supported by vouchers to the satisfaction of the Engineer.<br />
The Contractor shall have no claim to any payment or compensation or otherwise howsoever on<br />
account of any profit or advantage which he might have derived in consequence from the<br />
execution of the work in full but which he did not derive in consequence of determination of<br />
contract. The <strong>Railway</strong>s decision on the necessary and propriety of such expenditure shall be final<br />
and conclusive.<br />
DETERMINATION OF CONTRACT OWING TO DEFAULT IN THE CONTRACT<br />
3.52 (1) If the Contractor should-<br />
(i) become bankrupt or insolvents, or<br />
(ii) make an arrangement with or assignment in favour of his creditors or agree to carry out<br />
the contract under a committee or Inspection of his creditors, or<br />
(iii) being a company or corporation, go into liquidation (other than a voluntary liquidation<br />
for the purpose of amalgamation or reconstruction)<br />
(iv) have an execution levied on his goods or property on the works or<br />
(v) Abandon the contract, or<br />
(vi) Persistently disregard the instruction of the Engineer, or contravenes any provision of<br />
the contract, or<br />
(vii) Fail to adhere to agreed programme of work by margin of 10 percent of the stipulated<br />
period, or<br />
(viii) fail to remove materials from the site or to pull down and replace work after receiving<br />
from the Engineer notice to the effect that the said materials or works have been<br />
condemned or rejected under Clauses 3.3 & 3.20 of these conditions, or<br />
(ix) fail to take steps to employ competent or additional staff and labour as required under<br />
clause 3.20 of these conditions, or<br />
(x) fail to afford the Engineer or Engineer’s representative proper facilities for inspecting<br />
the works or any part thereof as required under Clause 3.21 of these conditions, or<br />
(xi) promise, offer or give any bribe, commission, gift or advantage either himself or through<br />
his partner<br />
or servant to any officer or employee of the <strong>Railway</strong> or to any person on his of on their<br />
behalf in relation to the execution of this or any other contract with the <strong>Railway</strong>, then<br />
and in any of the said causes, the Engineer on behalf of the <strong>Railway</strong>, may serve the<br />
Contractor with a notice in writing to that effect and if the Contractor does not within 7<br />
days after the delivery to him of such notice proceed to make good his default in so far as<br />
the same is capable of being made good and carry on the work or comply with such<br />
directions as aforesaid to the entire satisfaction of the Engineer, the <strong>Railway</strong> shall be<br />
entitled after giving 48 hours notice in writing under the hand of the Engineer to remove<br />
the Contractor from the whole or any portion to portions (as may be specified in such<br />
notice) of the works without thereby avoiding the contract or realizing the Contractor<br />
Signature of the Tenderer with seal & date Page 26
from any of his obligations or liabilities under the contract and adopt any or several<br />
following courses:-<br />
a) to rescind the contract, of which rescission notice in writing to the Contractor under the hand of<br />
the Engineer shall be conclusive evidence, in which case the security deposit of the Contractor<br />
shall stand forfeited to the <strong>Railway</strong> without prejudice to the <strong>Railway</strong>’s right or recover from the<br />
Contractor any amount by which the cost of completing the works by any other agency shall<br />
exceed the value of the contract:<br />
b) to carry out the works, or any part thereof by the employment of the required labour and<br />
materials, the costs of which shall include lead, lift, freight supervision and all indental charges and<br />
to debit the Contractor with such cost, the amount of which as certified by the Engineer shall be<br />
final and binding upon the Contractor, and to credit the Contractor with value of the works done<br />
as if the works had been carried out by the Contractor under the terms of the contract, and the<br />
certificate of the Engineer in respect of the amount to be credited to the Contractor shall be final<br />
and binding upon the Contractor.<br />
c) to measure up the work executed by the Contractor and to get the remaining work completed by<br />
another Contractor at the risk and expense of the Contractor in all respects in which case any<br />
expenses that may be incurred if the works had been carried out by him under the terms of the<br />
contract, the amount of which excess as certified by the Engineer shall be final and binding upon<br />
the Contractor, shall be borne and paid by the Contractor and may be deducted from any moneys<br />
due to him by the <strong>Railway</strong> under the contract or otherwise of from his Security Deposit. Provided<br />
always that in any case in which any of the powers conferred upon the <strong>Railway</strong> by Sub-Clause(1) of<br />
Clause 60 thereof shall have become exercisable and the same shall be not exercised the nonexercise<br />
thereof shall not constitute a waiver of any of the conditions hereof and such powers shall<br />
not withstanding be exercisable in the event of any future case of default by the Contractor which is<br />
liability for past and future shall remain unaffected.<br />
xii) At any time after the tender relating to the contract has been signed and submitted by the<br />
Contractor, being a partnership firm, admit as one of its partners of employ under it or<br />
being an incorporated company elect or nominate or allow to act as one of its directors or employ<br />
under it in any capacity whatsoever any retired Engineer of the Gazetted Officer working before his<br />
retirement whether in the executive or administrative capacity or whether holding pensionable post<br />
or not in the Engineering department of any of the <strong>Railway</strong>s for the time being owned and<br />
administered by the President of India before the expiry of two years from the date of retirement<br />
from the said servile of such Engineer or officer unless such Engineer or Officer has obtained<br />
permission from the President of India or any officer duly authorized by him in this behalf to<br />
become a partner or a director or to take employment under the contractor, as the case may be ,or<br />
B. Fail to give at the time of submitting the said tendera)<br />
the correct information as to the date of retirement of such retired Engineer or retired officer from<br />
the said service or as to whether any such retired Engineer of retired officer was under employment<br />
of the Contractor at the time of submitting the said tender, or<br />
b) the correct information as to such Engineers or officers obtaining permission to take employment<br />
under the Contractor, or<br />
c) being a partnership firm, the correct information as to whether any of its directors was such a<br />
retired Engineer or a Gazetted Officer or<br />
d) being in incorporated company correct information as to whether any of its partners was such a<br />
retired Engineer or a retired officer, or<br />
e) being such a retired Engineer or retired officer suppress and not disclose at the time of submitting<br />
the said tender the fact of his being such a retired Engineer or a retired officer or makes at the time<br />
of submitting the said tender, a wrong statement in relation to his obtaining permission to take the<br />
contract of if the Contractor be a partnership or an incorporated company to be a partner or director<br />
of such firm or company as the case may be or to seek employment under the Contractor, then and<br />
in any of the said cases the Engineer on behalf of the contractor<br />
Signature of the Tenderer with seal & date Page 27
f) <strong>Railway</strong>, may serve the Contractor with a notice in writing to that effect and if the Contractor does<br />
not within seven days after the delivery to him of such notice proceed to make good his default in<br />
so far as the same is capable of being made good and carry on the work or comply with such<br />
directions as aforesaid to the entire satisfaction of the Engineer, the <strong>Railway</strong> shall be entitled after<br />
giving 48 hours notice in writing under the hand of the Engineer to rescind the contract as a whole<br />
or in part or parts (as may be specified in such notice) as adopt either or both of the following<br />
courses.<br />
2) RIGHT OF THE RAILWAY AFTER RECESION OF CONTRACT OWING TO DEFAULT<br />
OF<br />
CONTRACT<br />
In the event of any or several of the courses referred to in sub-clause (1) of this clause, being<br />
adopted,<br />
a) The Contractor shall have no claim to compensation for any loss sustained by him by reason of his<br />
having purchased or procured any materials or entered into any commitments or made any<br />
advances on account of or with a view to the execution of the works or to the performance of the<br />
contract and the Contractor shall not be entitled to recover or be paid any sum for any work thereto<br />
for actually performed under the contract unless and until the Engineer shall have certified the<br />
performance of such work and the value payable in respect thereof and the Contractor shall only be<br />
entitled to be paid, the value so certified.<br />
b) Engineer or the Engineer’s representative shall be entitled to take the possession of any materials,<br />
tools, implements, machinery and buildings, on the works or on the property on which these are<br />
being or ought to have been executed and to retain and employ the same in the further execution of<br />
the works or any part thereof until the completion of the works without the Contractor being<br />
entitled to any compensation for the use and employment thereof or for wear and tear or destruction<br />
thereof.<br />
c) The Engineer, shall, as soon as may be practicable after removal of the Contractor, fix and<br />
determine ex-parte or by or after reference to the parties or after such investigation or enquiries as<br />
he may consider fit to make or institute and shall certify that amount (if any) had at the time of<br />
rescission of the contract been reasonably earned by or would reasonability accrue to the Contractor<br />
and what was the value of any unused or partially used materials, any constrainable plant and any<br />
temporary works upon the site. The legitimate amount due to the contractor after making necessary<br />
deductions and certified by the engineer should be released expeditiously.<br />
3.52 Execution of Contract Documents.<br />
i) The Tenderer whose tender is accepted shall be required to appear at the office of the General<br />
manager, Chief Electrical Engineer, Deputy Chief Electrical Engineer or Senior Electrical<br />
Engineer, as the case may be in person or if firm or corporation, a duly authorized<br />
representative shall so appear, and to execute the contract documents within seven days after<br />
notice that the contract has been awarded to him. Failure to do so shall constitute a breach of<br />
the agreement effected by the acceptance of the tender in which case the full value of the<br />
Earnest Money accompanying the tender shall stand forfeited without prejudice to many other<br />
rights or remedies.<br />
ii) The cost of stamping the Agreement shall be borne by the Contractor.<br />
iii) In the event of any Tenderer shoes tender is accepted shall refuse to execute the contract<br />
documents as here<br />
in before provided, the <strong>Railway</strong> may determine that such Tenderer abandoned thereof shall be<br />
treated as<br />
cancelled and the railway shall be entitled to forfeit the full amount of the Earnest Money had to<br />
recover the<br />
liquidated damages for such default.<br />
3.54 Arbitration matters finally determined by the <strong>Railway</strong>s.<br />
All disputes or differences of any kind whatsoever arising out of or in connection with contract,<br />
whether during the progress or work or after their completion and whether before or after the<br />
determination of the contract, shall be referred by the contractor to the <strong>Railway</strong> and <strong>Railway</strong> shall<br />
Signature of the Tenderer with seal & date Page 28
within a reasonable time after their presentation can notify decisions there on in writing but such<br />
maters which are contained in G.C.C.8A.18.22(5) 39, 43(2), 45(A) 55, 55(A) 5(57) 57A, 61(1),<br />
61(2)and 62(1) or any matters decision of which is specially provided for by these conditions will<br />
be treated as exceptional matters and the decision made by the <strong>Railway</strong> authorities shall be final<br />
and binding upon the contractors.<br />
3.55 Demand for Arbitration.<br />
3.55.1(i)<br />
3.55.1(ii)<br />
If any or any matter in question, dispute of differences on any account or as to the with<br />
holding by the <strong>Railway</strong> for his entitlement, if the <strong>Railway</strong> fails to make a decision within<br />
120 days, then in any such case but except in any of the exceptional cases referred to in<br />
clause 63, the contractor may after 120 days of submission of his disputed claim can ask in<br />
writing within 180 days to the effect that this dispute may be referred to arbitration.<br />
Subjects in Arbitration demand will contain mater in question, dispute of difference and also<br />
the amount claimed. Only specified matter may be referred to Arbitration not the others.<br />
3.55.1(ii)(A) Arbitration proceeding will be effected from such date by which written and legal demand<br />
has been received by the <strong>Railway</strong>s.<br />
3.55.1(ii)(B) The claimant will submit his claim with supporting documents and also state the remedy for<br />
each claim within 30 days from the date of appointment of arbitrator.<br />
3.55.1(ii)(C) Until the Tribunal permit the extension of the time the <strong>Railway</strong> will submit its defence<br />
statement and counter claims within 60 days from the date of receipt of the copy from<br />
tribunal.<br />
3.55.1(iii)<br />
3.55.1(iv)<br />
During proceeding no new claims will be added from either of the parties. However, with the<br />
permission of Tribunal modification of supplement call be added.<br />
If contractor’s failed to respond in writing after receiving the information with effect that<br />
final bill is ready for payment within 90 days then it will be presumed that he/they have<br />
waived their claim and under this contract the <strong>Railway</strong> will be free from all liabilities with<br />
regard to the claim.<br />
3.55.2 Obligation during pendency of Arbitration.<br />
During proceeding of arbitration the work under contract, will continue under the order is<br />
given from engineer and no payment will be withheld by the <strong>Railway</strong> for any dues payable<br />
but Arbitration Tribunal will be right to consider and give decision whether to continue the<br />
work during arbitration proceeding or not.<br />
3.55.3(A)(i) In such cases where full amount of claim in question does not exceed Rs. 10,00,000( Rupees<br />
Ten lakhs only) one Arbitrator will be appointed who will be either General Manger or any<br />
gazetted officer nominated by General Manager, but no less than the rank of Jr.<br />
Administrative Grade will be appointed within 60 days from the date of receipt of written<br />
valid demand for arbitration by the <strong>Railway</strong>s.<br />
3.55.3(A)(ii) The cases which are not covered under clause 64(3)A for arbitration there will be a panel<br />
three gazetted officer and will be not below the rank of Jr. Administrative Grade jfor this<br />
purpose <strong>Railway</strong> will send name of three gazetted officers from one or more department to<br />
the contractor who suggest any two name from the panel to be appointed. The General<br />
Manager will appoint at least one as contractor nominee. Thus appointed out of three<br />
arbitrators with consent of presiding arbitrators and rest arbitrators will be appointed from<br />
the above panel or our of the panel. At the time of indicating the name of arbitrators, it is<br />
essential to ensure that at least one arbitrators should be from Accounts department. For the<br />
purpose of appointing arbitrators officers from Accounts department selection grade will be<br />
treated as equivalent to Sr. Administrative grade of the other department.<br />
3.55.3A(iii)<br />
As per above, if one or more arbitrators appointed refused to act as arbitrator or withdraw his<br />
name or vacates the post or for any other reasons unable to perform his duty or dies or does<br />
not work within stipulated time or delays then General Manager can appoint new Arbitrator<br />
in place of him/them with same procedure as followed earlier. Thus newly constituted<br />
Tribunal can work with its own conscious in the same manner as earlier Tribunal worked<br />
and begin the work from the stage from where it was left by the earlier Tribunal.<br />
3.55.3A(iv)<br />
The Arbitration Tribunal will have the power to ask for any affidavit or other evidence as<br />
deemed necessary by the Tribunal from the parties and it will be duty of the party to discuss<br />
or to make discussion which will enable Arbitrators it take decision for award.<br />
Signature of the Tenderer with seal & date Page 29
3.55.3A(v)<br />
3.55.3B(i)<br />
3.55.3B(ii)<br />
3.55.3B(iii)<br />
the<br />
Under the above sub-clause (i) (ii) and (iii) at the time of appointing arbitrator, it will be kept<br />
in mind that appointee will be not from them who has an opportunity to dispose the case<br />
concern to the questioned contractor who as a <strong>Railway</strong> employee in course of discharging his<br />
duties have expressed his views on any disputes, proceeding taken by arbitration tribunal or<br />
award made by such tribunal will not be invalid on the ground that one or more arbitrator<br />
have expressed his/ their views for disposal of any dispute in course discharging his/ their<br />
duties.<br />
The Arbitration award will consist of item, amount and reasons on which it is based.<br />
To rectify the errors in the parties award, any error, calculation, typing, clerical mistakes<br />
or errors of similar nature and to clarify any point of award it is to be applied within 30<br />
days from the receipt of the award.<br />
Any party with regard to claims presented in the arbitration proceedings but omitted in<br />
arbitration award can apply to the tribunal for additional award.<br />
3.55.4 In case of such Tribunals which is constituted by three members any rules or award will<br />
be given on the basis of majority of the Tribunal members. In case of lack of such<br />
majority of opinion of presiding arbitrator will be effective.<br />
3.55.5 Where Arbitration awards for payment of any amount the interest on full or partly<br />
amount will not be<br />
payable for any amount award in arbitration.<br />
3.55.6 The cost of arbitrator will be borne by the concerned parties. The cost include inter alia<br />
fee of the Arbitrator in prescribed rates as decided by <strong>Railway</strong> Administration from time<br />
to time.<br />
3.55.7 The above terms and conditions are made under the arbitration and conciliation ordinance<br />
1996 and will be effective to all arbitration proceedings.<br />
PART-IV<br />
4.1 Scope<br />
CONDITIONS OF PRICE AND PAYMENT<br />
Signature of the Tenderer with seal & date Page 30
This chapter deals with prices to be paid for supply and/or erection including testing,<br />
commissioning of various items of work or for supplies, and other amounts payable in accordance<br />
with accepted schedules of prices and rates and terms and conditions of payment mentioned<br />
herein.<br />
4.2 This is a composite works contract. The total prices for the completed items of work are the actual<br />
prices payable to the Contractor as per the terms and conditions of the contract<br />
4.3 Schedule of prices.<br />
Unit prices<br />
i) The unit prices of various items of work shall be included in the schedule of prices attached in<br />
Part-VI.<br />
ii) The unit prices quoted by the Tenderer and accepted by the purchaser shall hold good till the<br />
completion of the work and no additional individual claim will be admissible on account of<br />
fluctuation in market rates.<br />
iii) Minor changes in basic designs shall not affect the unit prices so long as such changes are<br />
mutually agreed to by the purchaser and the Contractor.<br />
iv) All unit prices shall be inclusive of all cost of materials, labour, transportation, handling, storage,<br />
erection, testing and commissioning, taxes, duties. For material supplied by the purchaser only<br />
erection charges will be payable for execution of work in accordance with specification and<br />
approved drawings.<br />
4.4 Unit prices for supply<br />
i) The unit prices quoted by the Tenderer shall include the cost of material including all incidental<br />
charges like, freights, transport, loading, unloading, handling, of materials, lifting descent<br />
insurance premium, Bankers charges for Bank Guarantee, Indemnity Bond cost of stamp etc. i.e.<br />
cost of all incidental charges ex-works to site of work<br />
ii) The unit prices stated above are also inclusive of Excise Duty and other Central and local taxes, if<br />
legality applicable but exclusive of octroi entry as octroi entry charges are exempted on <strong>Railway</strong><br />
materials, necessary exemption certificate for octroi/entry will be furnished to Contractor by the<br />
Purchaser.<br />
iii) While quoting the rates by the Tenderers the concessional rates of taxes/duties as admissible on<br />
<strong>Railway</strong> materials need to be taken into account. Necessary declaration form, if required will be<br />
furnished by the purchaser to the Contractor.<br />
4.5 Unit prices for erection<br />
The prices for erection shall include costs of erection testing commissioning etc. to the extent<br />
indicated and also cover all costs of administration of the contract. Banker/s charge for guarantee,<br />
cost of storage, loading, unloading and handling of materials. The unit prices for erection shall<br />
include cost of works or adjustment necessary to be done by the Contractor during or after the tests<br />
carried out by the purchaser.<br />
4.6 Payment and recovery terms<br />
Subject to any deduction or recoveries which the purchaser may be entitled to make under the<br />
contract, the payment to the Contractor shall be governed as per the following clauses:<br />
4.7 The Contractor shall be entitled to be paid from time to time by way of “On Account” payment up<br />
to 100 % only for such works as in the opinion of the Engineer he has executed in terms of the<br />
contract. On Account payment will be made on satisfactory erection duly certified by Engineer’s<br />
representative not below the Gazetted rank and as recorded in Measurement Book.<br />
4.8 a) On Account payment on materials will be made on the extent of 100% of the total prices of such<br />
material included in the schedules. On receipt of the materials in good condition at site. All<br />
invoices shall be accompanied by following:<br />
Signature of the Tenderer with seal & date Page 31
i) Manufacturers test certificates wherever applicable<br />
ii) Inspection Certificate granted by purchaser’s representative<br />
iii) Certificate of receipt of materials at the work site duly accepted by purchasers.<br />
iv) Certificate that the stores have been insured. Whenever applicable<br />
v) Execution of Indemnity Bond/Bank Guarantee<br />
vi) Detailed entries for supply being made in Measurement Book<br />
b) On Account payment to the extent of 100% of the total unit price of erection/laying of such<br />
material included in<br />
the schedule will be made on satisfactory erection duly certified by purchaser<br />
Engineer/Representative not<br />
below the Gazetted Rank and as recorded in the Measurement Book.<br />
4.9 Limit for On Account Payment:<br />
The limit for On Account payment shall not in any case exceed 100% value of works contract.<br />
4.10 Maintenance of work after completion:<br />
Subject to the conditions as detailed below; balance payment shall be made on commissioning of<br />
the complete work adjusting all the dues if any.<br />
Nature of work<br />
Period of Maintenance<br />
after certified date of<br />
completion<br />
Amount to the retained by the <strong>Railway</strong><br />
towards maintenance<br />
a<br />
Commissioning of all new<br />
installations and also<br />
work of addition and<br />
alteration to the existing<br />
assets.<br />
12(Twelve)<br />
Months<br />
The entire amount of Security deposit held<br />
against the contract as per Clause-3.48 of “<br />
General & Special condition of contract”<br />
4.11 Recoveries from the Contractor<br />
All recoveries for the cost of material supplied and service rendered by the purchaser to the<br />
Contractor covering 100 % On Account payment and supply and erection, testing and<br />
commissioning.<br />
4.12 Without prejudice to any other rights or remedies, recovery for any loss of equipment/materials<br />
supplied free of cost to the Contractor shall be effected through the ‘On Account bills/final bills at<br />
the discretion of the Engineer. The rate of recovery of such equipment/material shall be determined<br />
by the purchaser whose decision shall be final and binding.<br />
4.13 Income Tax shall be recovered from the source as per extent rules.<br />
4.14 Statutory variation in Taxes and Duties<br />
(i)<br />
The statutory variation of Sales Tax and Excise Duties either from the date of opening of the<br />
tender or from the date of letter of Acceptance of tender to the date of delivery of materials<br />
equipments at site, if legally payable shall be applicable for both upward and down revision of<br />
levies rates etc. of such taxes and duties. Any additional payment and/or less payment due to<br />
statutory variation of taxes and duties as the case may be either will be reimbursed to the<br />
Contractor or credit will have to be offered to the purchaser. Additional payment and/or credit as<br />
the case may be, on this account will be made/adjusted while make final payment.<br />
Signature of the Tenderer with seal & date Page 32
(ii) The claim for reimbursement of additional payment to the Contractor or the credit offered by the<br />
Contractor on Account of statutory variation in taxes duties under this clause shall be subject to<br />
production of the requisite documents.<br />
4.15 Final settlement and refund of Warranty Deposit<br />
4.15(i) On issue of the certificate for final acceptance, provided all the dues payable by the Contractor to<br />
the purchaser have been duly paid or otherwise made good by the Contractor, the Warranty Deposit<br />
will be refunded to the Contractor on production and surrender of the relative original receipt<br />
granted by the purchase in case it was paid<br />
in cash and where the Warranty Deposit is in the form of Bank Guarantee it will be released. The<br />
release of the<br />
Warranty Deposit will terminate the contract.<br />
4.15(ii) The Security Deposit shall however, be liable to the forfeited in case of any breach by the<br />
Contractor of any of<br />
rights<br />
the conditions of the contract or for not completion of the full contract without prejudice to other<br />
and<br />
remedies of the purchaser whether specifically provided for herein or otherwise.<br />
4.16 Post Payment Audit<br />
It is an agreed term of the contract that the purchaser reserves to itself the right to carry out a post<br />
payment audit and or technical examination of the works and the final bill, including all<br />
supporting vouchers, abstracts etc. and to make a claim on the contractor for the refund of any<br />
excess amount paid to him if as result of such examination any over payment to him is discovered<br />
to have been made in respect of any work one or alleged to have been done by him under the<br />
contract.<br />
4.17 Measurement<br />
Payment for field work shall be made in accordance with approved designs and drawings and<br />
measured in relevant units, except where provided for otherwise. In case the dimensions of the<br />
work are more than those shown in approved designs and drawings, the Contractor will not be<br />
entitled to any extra payment unless the dimensions are increased on account of physical<br />
impossibility of carrying out the work in accordance with approved drawings and designs, subject<br />
to approval by the purchaser before execution. In case the dimensions of work are less than those<br />
shown in the approved designs and drawings and the work is accepted without being rejected.<br />
Payment will be made as per work actually done at mutually acceptable rates.<br />
The measurement will be made generally in accordance with the specifications, standard<br />
engineering practice.<br />
4.18 Measurement of work<br />
The Contractor shall be made for the works at accepted schedule of rates on the measurements<br />
taken by the Engineer of the Engineer’s representative in accordance with the rules prescribed for<br />
the purpose.<br />
i) The quantity for items, the units for which it is prevalent accepted schedule of rates in MKS<br />
system in 10 or 100, the linear measurement shall be recorded corrected to nearest centimeters<br />
(Cm). The air and the cubic contents shall be calculated in square meters and in cubic meters<br />
corrected up to two places of decimals respectively.<br />
ii)<br />
Such measurements will be taken of the work in progress from time to time and at such intervals<br />
as in the opinion of the Engineer, shall be proper having regard to the progress of work. The date<br />
and time on which the measurements are to be made shall be communicated. The Contractor who<br />
shall be present at the site and shall sign the results of the measurements (which shall also be<br />
signed by the Engineer or the Engineer’s representative) recorded in the official measurement<br />
book as an acknowledgement of his acceptance of the accuracy of the measurement. In the event<br />
of failure, on the part of the Contractor to attend, the work may be measured in his absence and<br />
such measurement shall not withstanding such absence be binding upon the Contractor whether or<br />
not he shall have signed the measurement book provided always that any objection made by him<br />
to any measurement shall be duly investigated and considered in the manner set out below.<br />
a) It shall be open to the Contractor to take specific objection to any recorded measurement or<br />
classification on any ground within 7(seven) days from the date of measurement. Any re-<br />
Signature of the Tenderer with seal & date Page 33
measurement taken by the Engineer or the Engineer’s representative in the presence of the<br />
Contractor or in his absence after due notice has been given to him consequence of the objection<br />
made by the Contractor shall be final and binding on the Contractor and no claim whatsoever shall<br />
hereafter be entertained regarding the accuracy and classification of the measurement.<br />
b) If any objection raised by the Contractor is found by the Engineer to be incorrect the Contractor<br />
shall be<br />
liable to pay the actual expenses incurred in the measurements.<br />
Signature of the Tenderer with seal & date Page 34
CENTRAL POWER HOUSE<br />
OFFICE OF THE DEPUTY CHIEF ELECTRICAL ENGINEER (MAINTENANCE)<br />
CLW/ CHITTARANJAN<br />
Schedule of quantities and rates<br />
Tender No. : EL-CON-274 - WC<br />
Name of work : - "Electrification of Type - II Qrs.- 26 Units, Type -III Qrs. - 12 Units and Type - IV<br />
qrs. - 6 units for RPSF staff at <strong>Chittaranjan</strong>".<br />
Description Qty. Unit Unit rate in Rs<br />
Sl.no. Supply Erection<br />
A-I POWER SUPPLY & STREET LIGHT FOR TYPE - II<br />
(D/S QUARTERS 26 UNITS) , TYPE-III (D/S<br />
QUARTERS 12 UNITS) & TYPE - IV (S/S QRS. - 6<br />
UNITS).<br />
1 Procurement of XLPE insulated and PVC sheathed<br />
stranded Aluminium conductor 1100 Volt grade Steel<br />
strip/ Round wire armoured cable as per IS: 7098<br />
(Pt.-I).<br />
a) 4 Core 400 Sq. mm. cable 100 M CLW Supply<br />
b) 2 Core 120 Sq. mm. cable 1300 M CLW Supply<br />
c) 2 Core 25 Sq. mm. cable 1400 M CLW Supply<br />
2 Digging of earth for formation of kachcha trench of<br />
size 0.6 m deep x 0.6 m width including dressing of<br />
soil, supply of bricks (F.P.S. bricks class designation<br />
7.5), Brick walling, brick covering at the top, sand<br />
filling (Ordinary sand) of the trench 150 mm. thick ,<br />
covering the trench with excavated soil, ramming and<br />
removal of extra soil from the site . The trench shall<br />
be as per Drg. No. CLW/E/ . Laying of cable as per<br />
following sizes :-<br />
a) 1 Run of 4 Core 400 Sq. mm. cable 80 M<br />
b) 1 Run of 2 Core 120 Sq. mm. cable + 1 Run of 2<br />
Core 25 Sq. mm. cable through the same trench<br />
915 M<br />
c) 1 Run of 2 Core 120 Sq. mm. cable 235 M<br />
d) 1 Run of 2 Core 25 Sq. mm. 310 M<br />
Signature of the Tenderer with seal & date Page 35
Description Qty. Unit Unit rate in Rs<br />
Sl.no.<br />
3 Digging of earth for formation of kachcha trench of<br />
size 0.45 m deep x 0.3 m width including dressing of<br />
soil, supply of G.I. pipe ( medium gauge), including<br />
laying of cable , covering the trench with the<br />
excavated soil , dressing up of soil and removal of<br />
extra soil from the site (without bricks and sand).<br />
a 1 Run of 120 sq. mm. cable through 50 mm. dia. G.I.<br />
pipe.<br />
20 M<br />
Supply<br />
b<br />
2 Runs of 50 mm. dia. G.I. pipe for 2 runs of 120 sq.<br />
mm. cable.<br />
23 M<br />
c 1 Run of 40 mm. dia. GI Pipe (Medium Gauge) for 4<br />
runs of 6 Sq. mm. cable.<br />
225 M<br />
4 Breaking of cemented floor and finished with cement<br />
sand plaster 13mm. thick, smooth cement plaster .<br />
The trench shall be 150mm. Deep X 200 mm. wide.<br />
After laying of G.I. pipe and cable the trench shall be<br />
covered with P.C.C (1:3:6) and after that finished<br />
with cement sand plaster 13mm. thick, smooth<br />
cement plaster 3mm. Thick.( Laying of G.I. pipe and<br />
cable has been shown seperately).<br />
25 M<br />
a 2 Runs of G.I. pipe 50 mm. dia.(Medium Gauge) for 2<br />
runs of 2 core 120 Sq. mm. cable + 1 run of 40 mm.<br />
dia. conduit Pipe for 4 runs of 1 core 6 Sq. mm.<br />
cable.<br />
5 M<br />
b 1 Run of G.I. pipe 50 mm. dia. for 1 run of 2 core 120<br />
Sq. mm. cable +1 run of 40 mm. dia. conduit pipe for<br />
4 runs of 1 core 6 Sq. mm. cable.<br />
15 M<br />
c 1 Run of G.I. pipe 50 mm. dia. for 1 run of 2 core 120<br />
Sq. mm. cable +2 runs of 40 mm. dia. G.I. pipe for 4<br />
runs of 1 core 6 Sq. mm. cable .<br />
5 M<br />
Signature of the Tenderer with seal & date Page 36
Description Qty. Unit Unit rate in Rs<br />
Sl.no. Supply Erection<br />
5 Breaking of cemented floor and finished with cement<br />
sand plaster 13mm. thick, smooth cement plaster .<br />
The trench shall be 150mm. Deep X 100 mm. wide.<br />
After laying of G.I. pipe and cable the trench shall be<br />
covered with P.C.C (1:3:6) and after that finished<br />
with cement sand plaster 13mm. thick, smooth<br />
cement plaster 3mm. thick including supply and<br />
laying of G.I. pipe 40 mm. dia. and laying of 4 runs of<br />
PVC insulated copper cable 6 Sq. mm. along with 4<br />
runs of 0.75 sq. mm. copper earth continuity<br />
conductor.<br />
52 M<br />
6 2 Pairs consisting of 4 runs of 6.0 Sq. mm. cable run<br />
through G.I. pipe 25 mm. dia.(Medium gauge) as per<br />
IS: along the wall including supply and erection of<br />
G.I. pipe 25 mm. dia. including Tee’s, bends, sockets<br />
, elbows and fixing saddles with base and<br />
necessary fixing hardwares and erection, connection,<br />
testing and commissioning of 4 runs of above copper<br />
earth continuity conductor cable. Make : TATA,<br />
JINDAL, BANSAL, SAIL (for Type -IV Qrs.)<br />
30 M<br />
7 Laying of 1 run of 2 core 120 Sq. mm. cable through<br />
G.I. pipe 50 mm. dia. (Medium Gauge) including<br />
supply of G.I. pipe, M.S fixing clamps and hardwares.<br />
8 Laying of 1 run of 2 core 120 Sq. mm. cable through<br />
G.I. pipe 50 mm. dia. (Medium Gauge) including<br />
boring of road and supply of G.I. pipe.<br />
16 M<br />
25 M<br />
9 Laying of 4 Core 400 Sq. mm. Al. conductor XLPE<br />
cable 1.1 KV grade through 150 mm. dia. G.I. pipe (<br />
Medium Gauge) including supply of M.S. fixing<br />
clamps and hardwares.<br />
12 M<br />
Signature of the Tenderer with seal & date Page 37
10 Laying of 4 Core 400 Sq. mm. Al. conductor XLPE<br />
cable 1.1 KV grade along the pole with M.S. fixing<br />
clamps made up of 25 X 6 mm. thick with fixing<br />
hardwares.<br />
8 M<br />
11 Laying of 1 run of 2 core 25 Sq. mm. cable along the<br />
pole including supply of M.S fixing clamps and<br />
hardwares.<br />
10 M<br />
Description Qty. Unit Unit rate in Rs<br />
Sl.no. Supply Erection<br />
12 Laying of 2 runs of 2 core 25 Sq. mm. cable through<br />
G.I. pipe 65 mm. dia. (Medium Gauge) including<br />
supply of G.I. pipe, M.S fixing clamps and hardwares<br />
(for Street light pole)<br />
40 M<br />
13 Laying of 1 run of 2 core 25 Sq. mm. cable through<br />
G.I. pipe 40 mm. dia. (Medium Gauge) including<br />
supply of G.I. pipe, M.S fixing clamps and hardwares.<br />
14 Laying of 1 run of 2 core 25 Sq. mm. cable through<br />
G.I. pipe 40 mm. dia. (Medium Gauge) including<br />
boring of road and supply of G.I. pipe.<br />
50 M<br />
20 M<br />
15 End connection of the cable with crimping type Al.<br />
cable lugs and compression type brass cable glands<br />
for following sizes of cable<br />
a) 4 Core 400 Sq. mm. 1.1 KV grade XLPE Al<br />
conductor armoured cable<br />
b) 2 Core 120 Sq. mm. 1.1 KV grade XLPE Al<br />
conductor armoured cable<br />
c) 2 Core 25 Sq. mm. 1.1 KV grade XLPE Al conductor<br />
armoured cable<br />
d) 1 core 6 Sq. mm. Copper cable with crimping type<br />
bimetalic cable lugs.<br />
e) 1 core 2.5 Sq. mm. Copper cable with crimping type<br />
bimetalic cable lugs (for street light fittings).<br />
4 Each End<br />
12 Each End<br />
51 Each End<br />
112 Each<br />
100 Each<br />
Signature of the Tenderer with seal & date Page 38
16 Supply and fixing of M.S. angle 25 X 25 X 4 mm., 1<br />
M long route marker 90 mm. dia , 8 mm. thick and<br />
rivetted by 02 Nos. rivet. The route marker shall be<br />
made up of Cast Iron and marked as L.T. cable. The<br />
route marker shall be fixed with concrete base of 1<br />
M. height X 150 mm. dia. as per Drg. No.<br />
CLW/E/1973.<br />
80 Each<br />
17 Digging of earth pit in semi rocky soil and earthing<br />
complete with G.I. perforated pipe 50mm. Dia.<br />
(Medium gauge) with salt, charcoal, nuts, bolts and<br />
washers etc. For Street pole earthing as per<br />
Technical Specn. & Drg. No. CLW/E/1978<br />
9 Each<br />
18 Supply, erection, connection, testing and<br />
45 M<br />
commissioning of 8 SWG G.I. wire run along the<br />
pole.<br />
Description Qty. Unit Unit rate in Rs<br />
Sl.no. Supply Erection<br />
19 Supply of hollow tubular pole 6 M. long (Havells<br />
Model No. LHMP01106099)<br />
25 Each<br />
20 Foundation of Steel tubular pole 6M. long including<br />
cement, sand and stone chips (1:2:4) with 04 nos.<br />
pockets for 10 mm. J type foundation bolts, cement<br />
sand plaster 12mm. thick (1:3) on the surface of<br />
walls and tops including erection of pole as per Drg.<br />
No. CLW/E/ . The foundation shall have provision for<br />
installation of Bus bar box provided with M.S fixing<br />
clamps and hardwares.<br />
21 Supply, installation, connection, testing and<br />
commissioning of Street light fitting SGP 438/CDM-<br />
TT 150 Watt complete with all accessories and<br />
lamps CDM-TT 150 Watt (Philips Model No. SGP<br />
438/CDM-TT 150 watt<br />
25 Each<br />
25 Each<br />
22 Supply of G.I. pipe 38 mm. dia. , 8ft. long (Heavy<br />
gauge) and bending at 95º or as per actual site<br />
condition at 3 ft. of the total pipe length including<br />
supply and fitment of clamps and bolts (02 Sets) for<br />
new G.I. bend pipe, 38 mm. dia. as per<br />
drawing.Make : TATA, BANSAL, JINDAL<br />
25 Each Set<br />
Signature of the Tenderer with seal & date Page 39
B-I<br />
Internal wiring and Electrical equipments, fittings and<br />
accessories and Earthing of quarters for Type-II(D/s)<br />
- 26 units, Type - III (D/S) - 12 Units and Type - IV - 6<br />
Units Quarters<br />
1 Supply of PVC insulated and unsheathed single core,<br />
stranded bright annealed copper conductor fire<br />
retardant building wires of 1100 volts grade<br />
unarmoured cable as per IS : 694-1990. of following<br />
sizes.( Make:- Polycab/Plaza/<br />
Finolex/R.R.Kable/Havell’s/ RETCO<br />
/Anchor/MESCAB ( as per CEE's approved list.)<br />
a) 6.0 sq.mm. 2600 M<br />
b) 4.0 Sq. mm. 4200 M<br />
c) 2.5 Sq.mm 1620 M<br />
Description Qty. Unit Unit rate in Rs<br />
Sl.no. Supply Erection<br />
d) 1.5 Sq. mm. 6300 M<br />
e) 0.75 Sq.mm. 8400 M<br />
f) Procurement of PVC insulated flexible twin twisted<br />
copper conductor cable size 24/0.20 mm., 650 volt<br />
grade as per IS: 694- 1990 for fan and light fittings .<br />
Make:- Polycab/ Plaza/ Finolex/ R.R. Kable/<br />
Havell’s/RETCO/Anchor/ MESCAB( as per CEE's<br />
approved list.)<br />
400 M<br />
Signature of the Tenderer with seal & date Page 40
2 1 pair consisting of 2 runs of 6.0 Sq. mm. cable run<br />
through rigid PVC conduit (Heavy gauge) as per IS:<br />
9537 including supply and erection of PVC rigid<br />
conduit 25 mm. dia. including Tee’s, bends, sockets ,<br />
elbows and fixing saddles with base and necessary<br />
fixing hardwares and erection, connection, testing<br />
and commissioning of 2 runs of above copper<br />
conductor cable. Make :- PVC conduit pipe-<br />
Polycab/ Plaza<br />
625 M<br />
3 2 runs of 4.0 Sq. mm. cable run through rigid PVC<br />
casing and capping including supply and erection of<br />
PVC casing capping 20mm. x 12mm. deep with<br />
necessary fixing hardwares and erection, connection,<br />
testing and commissioning of 2 runs of above PVC<br />
insulated copper conductor cable along with single<br />
run of PVC insulated copper earth continuity<br />
conductor size 0.75 sq. mm. from i) DB to switch<br />
board and switch board to sub switch board and DB<br />
to Power plug for Type - IV Qrs. and D.B. to switch<br />
board and switch board to sub switch board ,<br />
Mainswitch board to switch board and switch board<br />
to sub switch board (Make: - PVC Casing &<br />
Capping- Polycab/ Plaza )<br />
4 2 runs of 2.5Sq. mm. cable run through rigid PVC<br />
casing and capping including supply and erection of<br />
PVC casing capping 20mm. x 12mm. deep with<br />
necessary fixing hardwares and erection, connection,<br />
testing and commissioning of 2 runs of above copper<br />
conductor cable along with single run of PVC<br />
insulated copper earth continuity conductor size 0.75<br />
sq. mm. switch board to sub switch board for Type-<br />
III & Type - IV Qrs.<br />
2100 M<br />
560 M<br />
Description Qty. Unit Unit rate in Rs<br />
Sl.no. Supply Erection<br />
Signature of the Tenderer with seal & date Page 41
5 2 runs of 1.5 Sq. mm. cable run through rigid PVC<br />
casing and capping size 20mm. x 12mm. deep<br />
including supply and erection of PVC casing capping<br />
with necessary fixing hardwares and erection,<br />
connection, testing and commissioning of 2 runs of<br />
above copper conductor cable along with single run<br />
of PVC insulated copper earth continuity conductor<br />
size 0.75 sq. mm. from switch board to light, fan, 6A<br />
wall socket points as follows:-Make: - PVC Casing &<br />
capping - Polycab/ Plaza )Type-II (14 Points)- 60M x<br />
26 Units = 1560M, Type-III (14 Points)- 85M x 12<br />
Units = 1020M, Type-IV (21Points)-95M x 6 Units<br />
=570M,<br />
3150 M<br />
6 2 runs of 2.5 Sq. mm. cable run through hollow<br />
tubular pole for street light fitting along with single<br />
run of PVC insulated copper earth continuity wire<br />
0.75 sq. mm.<br />
250 M<br />
7 SWITCH BOARD :<br />
Supply and erection of Hard wood switch board,<br />
double hinged type , free from knots and other<br />
defects and provided with locking arrangement with<br />
Hylam top cover as per follows:-<br />
a) 380x300x85 mm with 5 mm. thick Hylam top cover<br />
Switch Board for Type-II(1 N0. X26 units) + Ty. III – 1<br />
No. X 12 Units + Ty. -IV - 1 No. X 6 Units= 44 Nos.<br />
44 Each<br />
b) 200x150x50 mm with 3 mm. thick Hylam top cover<br />
Switch Board for Ty -II + Ty.III + Type IV<br />
174 Each<br />
c) 150x100x50 mm with 3 mm. thick Hylam top cover<br />
Switch Board for Type - II + Ty.III + Type – IV<br />
174 Each<br />
B-II<br />
ELECTRICAL FITTINGS & ACCESSORIES<br />
Signature of the Tenderer with seal & date Page 42
Description Qty. Unit Unit rate in Rs<br />
Sl.no. Supply Erection<br />
1 Supply, installation, connection , testing and<br />
commissioning of Bus bar box made up of Thermo<br />
plastic box dust proof, water tight, acid resistant,<br />
corrosion proof, insulated and shock proof, fire<br />
retardant, self extinguishing, Halogen & silica free<br />
non toxic material with internally embedded gasket<br />
(PU) Size 390 X 950 X 235 mm. with Al Busbar for<br />
single phase and neutral suitable for 100 A rating.<br />
The box shall be provided with 100A, HRC fuse<br />
base unit 2 nos & HRC fuse 100A rating ,<br />
transparent lead and complete with insulators and all<br />
other accessories for bus bars.<br />
1 Each<br />
2 Supply, installation, connection , testing and<br />
commissioning of Bus bar box made up of Thermo<br />
plastic box dust proof, water tight, acid resistant,<br />
corrosion proof, insulated and shock proof, fire<br />
retardant, self extinguishing, Halogen & silica free<br />
non toxic material with internally embedded gasket<br />
(PU) Size 390 X 950 X 235 mm. with Al Busbar for<br />
single phase and neutral suitable for 200 A rating.<br />
The box shall be provided with 200A, HRC fuse<br />
base unit 2 nos & HRC fuse 200A rating ,<br />
transparent lead and complete with insulators and all<br />
other accessories for bus bars.<br />
3 Supply, installation, connection , testing and<br />
commissioning of Bus bar box made up of Thermo<br />
plastic box Size 300 X 300 X 170 mm. with Al.<br />
Busbar for single phase and neutral suitable for 63 A<br />
rating. The box shall be provided with insulators and<br />
all other accessories for bus bars.<br />
5 Each<br />
25 Each<br />
Signature of the Tenderer with seal & date Page 43
4 Supply of KV Thermo plastic box with<br />
transparent lid, box Size 168x253x115 mm.<br />
including supply of 1 No. 1 ø,AC Electronic<br />
Energy meter with LCD display, 230 volt, 50<br />
Hz. Rating 10-40A.Energy Meter with<br />
mounting plate complete with all<br />
accessories.(Make : HENSEL's Cat. No. KG<br />
9002) & Installation and connection at both<br />
ends of new energy meter and thermoplastic<br />
box as mentioned above with fixing hardwares<br />
and accessories .<br />
6 Each<br />
Description Qty. Unit Unit rate in Rs<br />
Sl.no. Supply Erection<br />
5 Supply of KV Thermo plastic box with<br />
transparent lid, box Size 300 x 600 x 170 mm.<br />
with mounting plate including supply of 1Ø<br />
Electronic Energy Meter with LCD display, 230<br />
Volts, 50Hz., Rating 5 -20A, 4 Nos. for Type-II<br />
& and 4 Nos. Porcelain fuse base unit 16A with<br />
6 Each<br />
fuse rating 10A complete with all<br />
accessories.(Box Make : HENSEL's Cat. No.<br />
Mi 0400 or similar) & Installation and<br />
connection at both ends of new energy meter<br />
and thermoplastic box as mentioned above with<br />
fixing hardwares and accessories.<br />
6 Supply of KV Thermo plastic box with<br />
transparent lid, box Size 300 x 600 x 170 mm.<br />
with mounting plate including supply of 1Ø<br />
Electronic Energy Meter with LCD display, 230<br />
Volts, 50Hz., Rating 10 - 40A, 4Nos. ( for<br />
Type-III & Type -II) and 4 Nos. Porcelain fuse<br />
base unit 32A with fuse rating 32A complete<br />
with all accessories.(Box Make : HENSEL's<br />
Cat. No. Mi 0400 or similar) & Installation and<br />
connection at both ends of new energy meter<br />
and thermoplastic box as mentioned above with<br />
fixing hardwares and accessories.<br />
2 Each<br />
Signature of the Tenderer with seal & date Page 44
7 Supply of KV Thermo plastic box with<br />
transparent lid, box Size 300 x 600 x 170 mm.<br />
with mounting plate including supply of 1Ø<br />
Electronic Energy Meter with LCD display, 230<br />
Volts, 50Hz., Rating 5 -20A,2Nos. for Type-II<br />
and 2 Nos. Porcelain fuse base unit 16A with<br />
fuse rating 10A complete with all<br />
accessories.(Box Make : HENSEL's Cat. No.<br />
Mi 0400 or similar) & Installation and<br />
connection at both ends of new energy meter<br />
and thermoplastic box as mentioned above with<br />
fixing hardwares and accessories.<br />
1 Each<br />
Description Qty. Unit Unit rate in Rs<br />
Sl.no. Supply Erection<br />
8 Supply of KV Thermo plastic box with<br />
transparent lid, box Size 300 x 600 x 170 mm.<br />
with mounting plate including supply of 1Ø<br />
Electronic Energy Meter with LCD display, 230<br />
Volts, 50Hz., Rating 10-40A, 2Nos. for Type-<br />
III and 2 Nos. Porcelain fuse base unit 32A<br />
with fuse rating 32A complete with all<br />
accessories.(Box Make : HENSEL's Cat. No.<br />
Mi 0400 or similar) & Installation and<br />
connection at both ends of new energy meter<br />
and thermoplastic box as mentioned above with<br />
fixing hardwares and accessories.<br />
1 Each<br />
9 Supply, erection, connection, testing and<br />
commissioning of following electrical fittings and<br />
accessories with fixing hardwares.<br />
a) SP MCB,10A 230Volts Type- II Qrs.-26 units (<br />
Make: Havell's, MDS Legrand, C&S, G.E,<br />
Crompton Greaves, ABB, Siemens & approved<br />
list of CEE/CLW)<br />
b) SP MCB,32A, 230 Volts for Type- III- 12 Units<br />
( Make: Havell's, MDS Legrand, C&S, G.E,<br />
Crompton Greaves, ABB, Siemens & approved<br />
list of CEE/CLW)<br />
26 Each<br />
18 Each<br />
Signature of the Tenderer with seal & date Page 45
c) Sheet steel main switch Double Pole, AC, 230 volts<br />
16 A with rewireable type porcelain fuse base unit. –<br />
Type -II-26 Units &Type-III- 12Units . Make: Havell's,<br />
C&s, BCH, L&T, Siemens, G.E<br />
26 Each<br />
d) Sheet steel main switch Double Pole, AC,415 volts<br />
32 A with rewireable type porcelain fuse base unit. –<br />
Type -III-12 Units x 1 No. Make: Havell's, C&s, BCH,<br />
L&T, Siemens, G.E<br />
18 Each<br />
Description Qty. Unit Unit rate in Rs<br />
Sl.no. Supply Erection<br />
e) Sheet steel MCB operated Distribution Board,<br />
comprising of 32A, SP&N single phase, 230 volts as<br />
incoming and 6 way Comprising of 4 Nos. SP, MCB<br />
,6 Amps., 230 volts & 2 Nos. SP, MCB ,20 Amps.,<br />
230 volts as out going feeders enclosed in a sheet<br />
steel enclosure and the D.B shall be mounted on<br />
Switch Board. Type-IV - 6 Units and 12 units Type-<br />
III.( Make: Havell's, Havell's, Standard, MDS<br />
Legrand, C&S, G.E, Crompton Greaves, ABB,<br />
Siemens & approved list of CEE/CLW)<br />
18 Each<br />
f) Piano Switch 6A,230 volts ( flush mounting type) (<br />
Ty. II - 14 Nos. x 26units + Ty. III- 18 nos. x 12 units<br />
+ Ty. IV-22 nos. x 6units (Make :-Anchor/<br />
SSK/Pritty/Pritam)<br />
g) Wall socket 5pin 6A, 230 volts ( flush mounting<br />
type)(Ty. II- 3 Nos. x 26units + Ty. III- 4 nos. x 12<br />
units + Ty. IV- 5 nos. x 6 Units)<br />
(Make :- Anchor/SSK/Pritty/Pritam)<br />
712 Each<br />
156 Each<br />
Signature of the Tenderer with seal & date Page 46
h) Poly carbonate Angular/ Flat lamp holder with PVC<br />
square box/ PVC round block 100mm. dia.x 37mm.<br />
deep. (Ty. II- 6 Nos. x 26units + Ty. III- 9nos. x 12<br />
units + Ty. IV-9 nos. x 6 units<br />
.(Make :- Anchor/SSK/Pritty/ Pritam)<br />
i) Ceiling rose 3 plate type,6A, 230 volts with PVC<br />
square box/ PVC round block 100mm. dia.x 37mm.<br />
deep and connections to ceiling fan & F.L. tube fitting<br />
with PVC insulated twin twisted flexible copper<br />
conductor cable size 24/0.20mm<br />
(Make :- Anchor/SSK/ Pritty/Pritam)<br />
(Type –II- 5 nos.x 26 units + Ty. III- 6nos. x 12 units<br />
+ Ty. IV- 10 nos. x 6units ).<br />
318 Each<br />
262 Each<br />
j) Call bell ding dong type to be operated on AC 230<br />
volts (Ty.IV- 1No X 6 Units)<br />
(Make :- Anchor/SSK/ Pritty/Pritam)<br />
6 Each<br />
Description Qty. Unit Unit rate in Rs<br />
Sl.no. Supply Erection<br />
k) Bell push switch to be operated on AC, 230 volts, 6A(<br />
D Ty.-1 No. x 20 Units,Ty.Iv 1 No. x 10 Units,Ty.V- 2<br />
Nos. x 10 Nos.) (Make :- Anchor/SSK/ Pritty/Pritam)<br />
6 Each<br />
l) MCB operated power plug & socket 20A, 230Volts,<br />
with SP MCB 20A ,enclosed in a sheet steel<br />
enclosure. Type - IV - 1no. x 6 units )<br />
(MAKE: Havell's, MDS Legrand, C&S, G.E,<br />
Crompton Greaves, ABB, Siemens & approved list of<br />
CEE/CLW)<br />
m) Power wall socket 5 in 1, 20/10A socket, switch,<br />
fuse, indication lamp combination unit flush mounting<br />
type (Type -III-2 No. X 12 Units +Type - IV - 1Nos. x<br />
6 units ) (Make :- Anchor/SSK/Pritty/Pritam)<br />
n) Supply and connection of CFL lamp 23 watt, suitable<br />
for BC lamp holder<br />
6 Each<br />
30 Each<br />
318 Each<br />
Signature of the Tenderer with seal & date Page 47
10 Supply, erection, connection, testing and<br />
commissioning of Energy efficient Ceiling fan<br />
1200mm. sweep,AC, single phase, 230 volt, 50 Hz.<br />
with double ball bearing with capacitor, 300mm. Long<br />
down rod and canopies, three number blades made<br />
of alluminium alloy with speed regulator suitable for<br />
1ø, 230 volts, 50 Hz. as per IS: 374 of latest edition,<br />
similar to Havell's Model No. ES-50.<br />
118 Each<br />
11 Supply,Installation, connection, testing and<br />
commissioning of Decorative ultra slim extruded<br />
aluminium box fixture with diffuser & domestic<br />
electronic ballast suitable for single TL-5 lamp, 28<br />
watt nominal voltage 240 volt, 50 Hz. Complete with<br />
all accessories and TL-5 lamp 28 watt tubular lamp<br />
including supply of M.s fixing clamps, fixing<br />
hardwares and flexible copper cable twin twisted size<br />
24/0.20mm , 1 mtr. Long for each fitting.<br />
144 Each<br />
B-III<br />
EARTHING OF QUARTERS<br />
Description Qty. Unit Unit rate in Rs<br />
Sl.no. Supply Erection<br />
1 Digging of earth pit in semi rocky soil and earthing<br />
complete with G.I. perforated pipe 50mm. Dia.<br />
(Medium gauge) with salt, charcoal, nuts, bolts and<br />
washers etc. as per Technical Specn. & Drg. No.<br />
CLW/E/1158(B)Type II - 7 Nos. + Type III - 3 Nos. +<br />
Type -IV- 3 Nos.<br />
2 Provision including fitment of earth terminal bar made<br />
of G.I. flat size 50 x 6 mm. thick with tapped holes for<br />
screwed terminals galvanized M6 x 25 mm.<br />
hexagonal screws, spring and plain washers.<br />
Type II - 7 Nos. + Type III - 3 Nos. + Type -IV- 3<br />
Nos.)<br />
3 Supply, erection, connection, testing and<br />
commissioning of 8 SWG G.I. wire from Earth pit to<br />
earth terminal bar<br />
13 Each<br />
block<br />
13 Each<br />
block<br />
130 M<br />
Signature of the Tenderer with seal & date Page 48
4 Supply, erection of 8 SWG G.I. wire from earthing pit<br />
to earth terminal bar through 13 mm. dia. G.I.<br />
pipe(Medium gauge) with 2nos. bend including<br />
supply of G.I. pipe , bends& G.I.earth wire.(The<br />
earth wire shall be continuous up to earth terminal<br />
bar).<br />
33 M<br />
5 Supply, erection, connection, testing and<br />
commissioning of rest length of 12 SWG G.I. earth<br />
wire.<br />
476 M<br />
E<br />
PROVISION OF H.T.O.H LINE, 500 KVA<br />
TRANSFORMER, L.T. PANEL & L.T.<br />
CABLE<br />
1.1(a) Rail pole 85lbs./ yd. 36'-0" long 26 CLW Supply<br />
1.1(b) Rail pole 85lbs./ yd. 18'-0" long 2 CLW Supply<br />
1.1<br />
(c)<br />
Collection of Rail pole(85 lbs./yd. 36'-0" long from<br />
PWI yard) erection and foundation of rail poles<br />
including supply of all materials like cement, sand<br />
and stone chips as per Technical specification and<br />
Drg. No. CLW/E/1785 & CLW/E/ 1732.<br />
26 nos<br />
1.1(d) Collection of Rail pole(85 lbs./yd. 18'-0" long from<br />
PWI yard) erection and foundation of rail poles<br />
including supply of all materials like cement, sand<br />
and stone chips as per Technical specification and<br />
Drg. No. CLW/E/1785 & CLW/E/ 1732.<br />
2 nos<br />
Description Qty. Unit Unit rate in Rs<br />
Sl.no. Supply Erection<br />
2.1 Supply and fixing of M.S. channel cross<br />
arm(100 mm. X 50 mm., 9.2 Kg./m 1.65 M to<br />
1.7 M.long) and fixing of M.S. clamps with<br />
nuts, bolts and washers etc. including cutting,<br />
bending, straighting, drilling, bolting, fixing in<br />
position and applying a priming coat of<br />
approved steel primer for 11KV. H.T. line as<br />
per Tech. Specn. and Drg. No. CLW/E/1785 &<br />
CLW/E/ 1732.<br />
a) For Three phase line (Single pole structure) 20 Set<br />
Signature of the Tenderer with seal & date Page 49
) For Three phase line (Double pole structure) 1 Set<br />
c) For Three phase line (Tri pole structure) 2 Set<br />
2.1 Supply and fixing of M.S. channel cross arm(100<br />
mm. X 50 mm., 9.2 Kg./m 1.65 M to 1.7 M.long) and<br />
fixing of M.S. clamps with nuts, bolts and washers<br />
etc. including cutting, bending, straightening, drilling,<br />
bolting, fixing in position, and applying a priming coat<br />
of approved steel primer for 11KV. H.T. line as per<br />
Tech. Specn. and Drg. No. CLW/E/1785 & CLW/E/<br />
1732.<br />
a) For Three phase line (Single pole structure) 20 Each set<br />
b) For Three phase line (Double pole structure) 1 Each set<br />
c) For Three phase line (Tri pole structure) 2 Each set<br />
3.1 Supply and erection of M.S. angle Tie bracing size<br />
50 mm. X 50 mm. X 6 mm. for strengthening of H-<br />
pole/ Tri pole structure complete with M.S. fixing<br />
clamps, G.I. nuts, bolts and washers etc.including<br />
cutting, bending, straightening, drilling, bolting, fixing<br />
in position, and applying a priming coat of approved<br />
steel primer for 11KV. H.T. line as per Tech. Specn.<br />
and Drg. No. CLW/E/1785 & CLW/E/ 1732. (Note :-<br />
for Double pole structure 1 sets & for Tripole<br />
structure - 3 sets)<br />
7 Set<br />
Description Qty. Unit Unit rate in Rs<br />
Sl.no. Supply Erection<br />
4 Supply and fitmet of 11 KV Pin insulator, 'U' clamps,<br />
bolts, nuts and washers etc. complete with all<br />
accessories including testing and commissioning.<br />
60 Each set<br />
5 Supply and fitmet of 11 KV Disc insulator complete<br />
with all accessories including testing and<br />
commissioning.<br />
6.1 Procurement of ACSR conductor size 6/4.72 Al + 7/<br />
1.57 Steel<br />
18 Each Set<br />
3 KM CLW Supply<br />
Signature of the Tenderer with seal & date Page 50
6.2 Stringing, connection, testing and commissioning of<br />
ACSR conductor size 6/4.72 Al + 7/ 1.57 Steel<br />
7.1 Supply, stringing and connection of 6 SWG G.I. wire<br />
Cradle guard (i.e 2 run of G.I. wire and tie/ cross at 6<br />
feet horizontaly apart)<br />
8 Supply and foundation of Stay set complete with turn,<br />
buckle, thimble, egg insulator, twisted 11/14 strand<br />
G.I. wire and straining screw as per Tech. Specn.<br />
3 KM<br />
2.1 KM<br />
4 Each<br />
9 Supply and painting of poles and other steel<br />
members with 2 coats of Red Oxide and 1 coat of<br />
Aluminium paint as per Tech. Specn.<br />
a) Single pole structure 20 nos<br />
b) Double Pole structure 1 nos<br />
c) Tri- pole structure 2 nos<br />
10 Supply and fixing of 'Danger Board' fabricated from<br />
10 SWG M.S. sheet and marked as per I.E. Rules for<br />
H.T. lines.<br />
30 Each Set<br />
11 Supply and fixing of 'Anticlimbing Device' as per Drg.<br />
No. CLW/E/1101<br />
26 Each Set<br />
12 Supply and wraping of barbed wire as per Note No. 1<br />
of Drg. No. CLW/E/1792<br />
26 Each Set<br />
Description Qty. Unit Unit rate in Rs<br />
Sl.no. Supply Erection<br />
13 Supply, installation, connection, testing and<br />
commissioning of Triple Pole Air Break Gang<br />
Operating Switch 400 Amps, 3 insulator type<br />
complete with operating rod and handle and locking<br />
arrangement including supply and erection of M.S.<br />
channel, fixing clamps and hardwares as per Drg.<br />
No. CLW/E/1792.<br />
2 Each Set<br />
Signature of the Tenderer with seal & date Page 51
14.1 Supply, installation, connection and commissioning<br />
of 12 KV, 10KA rated (Discharge Class-I) single pole<br />
unit, Metal Oxide Gapless Surge Arrestor to be used<br />
on normal voltage of 11KV and maximum voltage of<br />
12 KV for an MCOV of 9.6 KV (RMS) for solidly<br />
earthed neutral system comprising of Metal Oxide<br />
elements, hermetically sealed in a porcelain<br />
container having pressure relieving arrangements at<br />
both ends with connector suitable for ACSR<br />
conductor as per IS: 3070(Pt.-III) of 1993 & IEC-99-4<br />
of 1991.Supply of connecting lead from lightning<br />
arrestor to phases shall be suitable cross section of<br />
multi strand PVC insulated Cu. conductor cable of<br />
suitable voltage grade along with the complete set of<br />
lightning arrestor 3 nos in each set. Make : OBLUM,<br />
CGL<br />
2 Each Set<br />
14.2 Supply of M.S. Channel size 100mm. X 50mm. (9.2<br />
Kg./ metre) 1.65 M. to 1.7 M. long including supply of<br />
G.I. fixing clamps at both ends with nuts, bolts and<br />
washers etc. and M.S. plate size 300mm. width x 356<br />
mm. length X 4 mm. thick 3Nos. shall be seperately<br />
welded and drilled as per requirements (Continuous ,<br />
not tagged) with the M.S. channel for fitment of Metal<br />
Oxide gapless surge arrestor as per CLW's Drg. No.<br />
CLW/E/1980.<br />
2 Each Set<br />
14.3 Supply, erection, connection, testing and<br />
commissioning of G.I. flat strip size 50 x 6mm. Thick<br />
from lightning arrestor to the earthing pit continious in<br />
one length including supply of fixing hardwares along<br />
the pole. Approximate 15 M. G.I. strip for each<br />
earthing pit for lightening arrestor.<br />
30 M<br />
Description Qty. Unit Unit rate in Rs<br />
Sl.no. Supply Erection<br />
Signature of the Tenderer with seal & date Page 52
14.4 Supply, erection and connection of annealed Copper<br />
strip size 50 x 6 mm. thick (for 3 Nos. lightning<br />
arrestor in a set) and shall be provided with holes of<br />
suitable size as per dimension of lightning arrestor in<br />
the shorting link of suitable length.<br />
2 M<br />
14.5 End connection of Lightning arrestor by P.G. clamp<br />
at O.H. ACSR conductor.<br />
2 Each Set<br />
15 Supply, erection, connection, testing and<br />
commissioning of Drop out Expulsion type fuse unit<br />
rated for 50/100 Amps. As per specn. Including<br />
supporting M.S. channel and fixing clamps and<br />
hardwares as per Drg. No. CLW/E/1792(3 Nos. in a<br />
set)<br />
2 Complete<br />
set<br />
16.1 Digging of earth pit in semi rocky soil and earthing<br />
complete with G.I. perforated pipe 50mm. Dia.<br />
(Medium gauge) with salt, charcoal, nuts, bolts and<br />
washers etc. as per Technical Specn. & Drg. No.<br />
CLW/E/1978<br />
17 Supply, erection, connection, testing and<br />
commissioning of 8 SWG G.I. wire run along the pole<br />
18.1<br />
(a)<br />
Procurement of of out door type Distribution<br />
Transformer 500KVA, 11000V/433V, 3 phase, DY-<br />
11, 50 Hz. Bushing type.<br />
5 Each<br />
45 M<br />
1 nos CLW Supply<br />
18(b)<br />
Installation, connection, testing and commissioning of<br />
transformer including supply of fixing hardwares.<br />
1 Each<br />
19.1 Supply, installation, connection, testing and<br />
commissioning of L.T Distribution panel (Out door<br />
type)floor mounted comprising of One No. 630A,50<br />
KA, 4 Pole, 415 V TP & N, Microprocessor based<br />
MCCB as incoming and 2 Nos. 250A & 3 Nos. 100 A<br />
& 5 Nos. 63 A 4 Pole, 35 KA, 415V, TP&N MCCB as<br />
out going feeder with electrolytic copper bus bar for<br />
phases and neutral and aluminium bus bar for<br />
earthing(40 X 6 mm.) complete with digital<br />
multifunctional meter for obtaining current, voltage,<br />
power factor, energy etc. for incoming and ammeter,<br />
voltmeter, ammeter selector switch, voltmeter<br />
selector switch, suitable CT, neon lamp phase<br />
indicator as per Tech. Specn. The panel shall be<br />
kiosk type with double door and provided with locking<br />
arrangement and making foundation of L.T. Panel.<br />
1 Each<br />
Signature of the Tenderer with seal & date Page 53
Description Qty. Unit Unit rate in Rs<br />
Sl.no. Supply Erection<br />
23.1 Supply, erection, connection and testing of hard<br />
drawn All Aluminium stranded conductor 100 Sq.<br />
mm.(Size 7/4.39) as per Drg. No. CLW/E/1792<br />
25 M<br />
24 Supply and installation of following items with all<br />
fixing accessories as per Drg. No. CLW/E/1792 for<br />
Pole mounted type transformer and switching yard.<br />
24.1 Painting of the XPM enclosure with two coats<br />
Aluminium paints conforming to IS: 2339<br />
25 Formation of earth pit and earthing by 100Mm. Dia.<br />
G.I. pipe and G.I. plate size 1.2 M x 1.2 M x 6.3mm.<br />
Including digging of soil and plastering of earthing<br />
arrangement and interconnection of plate and pipe<br />
by 4 x 8 SWG G.I. wire and R.C.C. slab covering as<br />
per IS: 3043 and connected to the body of the<br />
transformer , transformer neutral, L.T. panel and<br />
lightning arrestor by 7/14 strand G.I. wire<br />
1 Complete<br />
set<br />
54 Sq.m<br />
4 Each Set<br />
26 Supply, erection, connection testing and<br />
commissioning of 7/14 strand G.I earth continuity<br />
wire from Earth pit to Transformer body, Transformer<br />
Neutral , L.T. panel , Lightning arestor.<br />
40 M<br />
End of Document<br />
Signature of the Tenderer with seal & date Page 54