Echocardiography Machine with 2 Probe Cardiac, Pediatric

More documents

Recommendations

Info

CMC:-a. After completion of the warranty period of five years, the prices of CMC for next fiveyears will remain fixed as per rates mentioned in the price bid, no increases in CMCcharges will be entertained at latter stage. However it is the responsibility of the bidder toinform the purchaser, the Head of the concerned department and Principal, S.N. MedicalCollege, Agra to start the CMC contract. This written information must be given by thebidder once at one year and again at six months prior to the date of expiry of warrantyperiod.b. Payment of CMC amount shall be made on half yearly basis after completion of each sixmonths. No advance payment of CMC will be done in any and every cases.c. However, the Head of the concerned department and Principal, S.N. Medical College,Agra shall have right to terminate the CMC at any given point of time if he deemsnecessary.33. Packing cases, container gunny packages etc. used for the packing of goods supplied to thepurchaser shall be the property of the purchaser without any payment thereof.34. The supplier shall not submit or assign this contract to any sub contractor without the priorpermission in writing of the Principal.35. In case non-performance in any form or shape of all or any of the conditions of this contract, thePrincipal shall have the power to annul, rescind or cancel this contract and upon his notifying inwriting to the supplier that he has so done this contract shall absolve and the agreement shall beterminated and security for the due performance of this contract will be forfeited by him and uponhis doing so the same shall become the property of the purchaser. The Principal may also debarthe supplier from tendering for the contracts for such period as he may think fit.36. In the event of dispute arising out of or concerning this agreement (except as to any matters thedecision of which is specifically provided for this agreement), shall be referred to a singlearbitrator, in case the parties agree upon one, otherwise two arbitrators, one nominated by thePrincipal, S.N. Medical College, Agra, and other arbitrator nominated by the contractor, or incase the contractor or the Principal fails to nominate an arbitrator within the time fixed in thenotice to be served on him by the said Principal or the contractor, as the case may be by thearbitrator nominated by the said Principal and the contractor, or in case of disagreement betweenthe said arbitrator an umpire appointed by them and the decision of such arbitrators or arbitratoror umpire as the case may be, shall be final and binding upon the parties. The arbitrators/arbitrator/umpire may from time to time with the consent of the parties extend the time formaking and publishing the award.37. Without prejudice to any other remedy provided by Law any amount due from the supplier to theGovernment will be recoverable as arrears of land revenue and may be recovered by deductionfrom any amount due from the Governor to the supplier on any account under any othertransaction.38. Tenderers are requested to sign on each and every sheet of the tender form along with designationand stamp.39. Number of quantity mentioned in the tender form may be increased or decreased.40. If any working day as due date of submission of tender observed as holiday, the next working daywill be treated as due date.41. Late/Delayed tenders due to any reason, postal delay or otherwise shall in no case be accepted.42. Principal has sole discretion of accepting/rejecting any tender and reserves his right to post-poneor refuse the purchase of any item notified in the tender.PRINCIPAL,S. N. MEDICAL COLLEGE,AGRA
ANNEXURE - BTENDERERS SHOULD FURNISH SPECIFIC ANSWER WITH DOCUMENTARY PROOF TOALL QUESTIONS GIVEN BELOW. TENDERERS MAY PLEASE NOTE THAT IF THEANSWER SO FURNISHED NOT CLEAR AND/OR NOT SUPPORTED BY DOCUMENTARYPROOF THE TENDER WILL BE LIABLE TO BE IGNORED.Category: -1. Whether the stores offered fully confirm to thetechnical particulars and specifications/drawingspecified by the purchaser in the schedule totender. If/not, mention here the details of deviations.2. Brand of store offered3. Name & address of manufacturer4. Place of Manufacturing5. Please confirm that you haveoffered packing as per requirements.If not indicate deviations.6. What is your or your Indian Agent’spermanent Income Tax A/C No (PAN)?7. Confirm whether you have attachedyour latest current ITCC or photocopythere of.8. Please indicate: Financial/Solvency Status(a)(b)Name & full address of your bankerOthers9. Please furnish your performance statement.On prescribed format attached with tender form10. Business name & constitution of theFirm. Is the firm registered under: -(i) The Indian Companies Act. 1956 ?(ii) The Indian partnership Act, 1932 ?(iii) Any other Act, if not, who are theOwners. (please give full names & Address).11. Whether the tendering firm is/are: -(i) Manufacturer.(ii) Manufacturer’s authorized agents.(iii) Holders in stock of the stores tendered for.12. If manufacturer’s agents, please enclosedwith tender the copy of manufacturer’sauthorization on prescribed format (Form No)attached with the tender document.
Page 1: OFFICE OF THE PRINCIPAL, S.N. MEDIC
Page 6 and 7: LETTER OF SUBMISSIONTender Notice N
Page 8 and 9: OFFICE OF THE PRINCIPAL, S.N. MEDIC
Page 10 and 11: mentioned in the bid. No variation
Page 12: (i)(ii)(iii)(iv)Sales tax, inter st
Page 15 and 16: For items on order which require an
Page 17 and 18: any Medical Institution of repute i
Page 19 and 20: MUST BE TYPED IN COURT STAMP PAPER
Page 21: 25. If during the validity period o
Page 25 and 26: 20. Are you agreeable to give guara
Page 27 and 28: ANNEXURE - FDETAILS OF SUCH EQUIPME
Page 29 and 30: Proforma for Performance Statement(
Page 31: Manufacturer’s Authorization Form

Echocardiography Machine with 2 Probe Cardiac, Pediatric

Create successful ePaper yourself

Delete template?

Save as template?