WILLIAMSON COUNTY ROAD BOND PROGRAM REVISED May 3 ...

PRECINCT 1 - COMMISSIONER LISA BIRKMAN 

WILLIAMSON COUNTY ROAD BOND PROGRAM 

REVISED May 3, 2013 

CONSTRUCTION 

2000/2006 ROAD BOND COMPLETED PROJECTS PROJECT NO. 

ENGINEER / CONTRACTOR 

SUBSTANTIAL FINAL 

PROGRESS - ACTION ITEMS - REMARKS 

START 

COMPLETION* COMPLETION 

Pond Springs Road/Turtle Rock Road Signal 02WC405 WHM & Huggins / Austin Bridge & Road 

01/03/02 04/30/02 07/26/02 Project complete. 

McNeil Road 

Phase I (SH 45 to north of CR 172) 

03WC527 Gray-Jansing & Associates / RGM 


Avery Ranch Blvd. 

(183A to Parmer Lane) 

N/A By Developer 

11/01/06 - 05/10/07 Project complete. 

McNeil Road 

Phase II (SH 45 to Howard Lane) 

05WC318 Gray-Jansing & Associates / Ranger 


RM 620 Interim Improvements Phase I 

(Turn Lanes at Wyoming Springs, Oaklands & Deep 

08WC605 Halff Associates / Aaron Concrete 

06/02/08 01/26/09 01/27/09 Project complete. The Contract close-out package will be prepared for transmittal to the County. 

Wood; Pedestrian Improvements) 

Pond Springs Road 

(McNeil Rd to US 183) 

09WC710 URS / RGM Constructors 


Wyoming Springs Drive 

(RM 620 to Brightwater Blvd) 

N/A Klotz Associates / RGM Constructors 

11/2009 11/2010 Winter 2010 Project complete - managed by the City of Round Rock. 

CR 174 (Hairy Man Rd) at Brushy Creek 

Bridge Rail Replacement 

11WC911 HNTB / Patin Construction 


O'Connor Extension (RM 620 to just north of SH 45) 

(Includes O'Connor and Great Oaks Intersection 

Improvements at RM 620) 

11WC906 Klotz Associates / Dan Williams / HDR & Atkins 

04/06/11 04/30/12 Pending 

King of Kings Crossing 12IFB00025 HNTB / Smith Contracting 

06/25/12 08/24/12 11/09/12 

Vegetation establishment is not yet complete and the pavers in the O'Connor median north of RM 620 still need to be reset. PE 

Structural is finalizing the Final Report regarding the bridge deck sealing at Lake Creek. A WA for PS&E for the deck sealing and 

construction inspection is being prepared. 

Project complete. The Contract close-out package will be prepared for transmittal to the County. 

South Great Oaks Extension (to O'Connor) N/A HD Engineering / Ross Construction 

Jul 2012 Oct 2012 Dec 2012 

ROAD BOND PROJECTS UNDER CONSTRUCTION ENGINEER CONTRACTOR OBSERVER BID AWARD 

O'Connor Overpass (at SH 45) 

CSJ: 0683-06-027 

12IFB00036 

RM 620 Safety Improvements 

(Cornerwood to Wyoming Springs) 

CSJ: 0683-01-079 

Atkins 

2006 ROAD BOND PROJECTS IN DESIGN ENGINEER 

IH 35 Corridor Operational Analysis 

(SH 45 to RM 1431) 

Ballenger / 

Zachary 

Pearson Ranch Underpass @ SH 45 / RM 620 Brown & Gay Dec 2013 Jul 2013 

Pearson Ranch Road 

(South of Avery Ranch Blvd to SH 45 ROW) 

2006 ROAD BOND PROJECTS 

Managed by Round Rock 

RM 620 at Railroad/Chisholm Trail - Environmental, 

Schematic and PS&E 

(IH 35 Frontage Road to Lake Creek Drive) 

TxDOT Aug 2011 Oct 2011 Nov 2011 

CONSTRUCTION 

START 

FINISH 

Due Nov 2013 

'Anticipated 

Spring 2014 

Halff Associates CF Jordan Atkins 12/04/12 02/04/13 02/19/13 09/29/14 

HDR 

DESIGN 

BID 

ESTIMATED CONST. SCHEDULE 

BID LETTING 

START FINISH ADVERTISEMENT 

START FINISH 

TBD 

TBD 

N/A 

Cunningham Allen Jul 2012 Spring 2013 TBD 

ENGINEER 

NOTICE TO 

PROCEED 

DESIGN 

BID 


BID LETTING 


START FINISH 

Halff Associates Mar 2012 Late 2013 

TBD 

City of Round Rock 

TBD 

Project complete and opened to traffic. A recommendation of acceptance has been sent to the County Engineer. 

Zachary is setting MSE walls for Wall #9 and continues to set MSE walls for Walls #1, 7, 8, and 10B. The Contractor is also forming 

footing for Wall #1, embanking roadway on O’Connor Drive from station 82+50 to 86+00, forming and pouring the Bent 4 column on 

the WBFR Bridge, forming and pouring the Bent 5 bent cap on the WBFR Bridge, and began forming the Bent 4 Cap. On the EBFR 

Bridge, Zachary formed poured the Bent 9 footing and the columns for Bents 6, 8, and 10. Ballenger's last day on the project was 

Monday, 12/3/12. On 3/13/13, Robinson provided an indemnification agreement to Zachary, and it was executed by both parties on 

4/9/13. 

CF Jordan continued excavating for Water Quality Ponds A and B and continued roadway excavation for the eastbound lanes 

between O’Connor and the water quality ponds. The Contractor continues crushing rock from the excavated areas and placing the 

material as embankment from O’Connor to the west end of the project. CF Jordan began stripping topsoil from south ROW between 

Wyoming Springs and the east end of the project. The Contractor began installation of Culvert 2, just east of Cornerwood, and 

continued installation of Culvert 3, just east of Great Oaks Blvd, including excavating and pouring the footing for the wingwalls at 

Culvert 3. CF Jordan poured the concrete wingwalls headwalls of Culverts 1, 2, and 3 located on the west end of the project. The 

temporary drainage pipe at Culvert 1 has been installed. The Contractor also continues to install storm sewer pipe and Inlets on 

Lines E and D, between Cornerwood and Great Oaks Blvd. Subcontractor Austin Traffic Signal installed the temporary traffic signals 

at the Great Oaks and Cornerwood intersections. Oncor relocations are complete, except for pole removal. Atmos and Time 

Warner Cable relocations are complete. AT&T relocations are complete except removal of attachments to Oncor’s poles and 

facilities along the north side of RM 620 west of Wyoming Springs. 

ENVIRONMENTAL 


CLEARANCE 

N/A 

State Categorical 

Exclusion: Approval 

Anticipated Summer 

2012 

Due Diligence 

Investigations To Be 

Completed: 

TBD 

ENVIRONMENTAL 

CLEARANCE 

Categorical Exclusion 

To Be Completed: 

Summer 2013 

Open House: 

1/23/2013 


Letters of Interest were received from engineering firms on 8/29/12, and interviews were held on 10/11/12. 

HDR was selected, and has submitted a scope of work to the County for review. 

A coordination meeting between Brown & Gay and Cunningham Allen was held on 3/27/13. A project 

update meeting was held on 3/8/13. Brown and Gay submitted the 30% design package on 2/26/13 and it 

is currently under review. TxDOT concurred with the proposed intersection improvements on 4/23/12. 

SWCA has begun the biological evaluation. HNTB is coordinating with TxDOT regarding environmental 

scoping and the AFA. 

Cunningham Allen is preparing 30% PS&E for submittal. A coordination meeting between Cunningham 

Allen and Brown & Gay was held on 3/27/13. The Round Rock ISD Development Agreement was 

approved by the Court on 3/19/13. A kickoff meeting for PS&E was held with Cunningham Allen on 

2/11/13. Cunningham Allen submitted field notes for RRISD/England land swap to accommodate the new 

alignment, on 11/12/12. 


The City of Round Rock has awarded the engineering services for the design and PS&E to Halff 

Associates. The City of Round Rock and TxDOT held an Open house on 1/23/13. Environmental 

determination is now anticipated by June. An ILA with the City of Round Rock was approved by the Court 

on 11/20/12. The City is managing the planning, environmental and design for this project. 

* Substantial Completion = Open to Traffic, Minor Construction Items Remain to be Completed Page 1 of 8

PRECINCT 2 - COMMISSIONER CYNTHIA LONG 

2000/2006 ROAD BOND COMPLETED PROJECTS 

PROJECT NO. 




START 

CONSTRUCTION 

SUBSTANTIAL 

COMPLETION* 

FINAL 

COMPLETION 

CR 175 (FM 1431 to Regional Park) 02WC425 Baker-Aicklen / Garey Construction 

06/07/02 06/16/03 10/09/03 

Project complete. 


River Bend Oaks Subdivision 02WC417 Haynie Consulting / Ellis-McGinnis 

05/30/02 - 02/28/03 

SH 29 at FM 1869 (Traffic Signal) N/A WHM / 

05/01/02 - 08/20/02 

CR 200 (CR 201 to Lackey Creek) 02WC440 KC Engineering / Joe Bland 

03/17/03 09/22/03 09/22/03 

CR 214 (SH 29 to Rolling Hills Rd.) 03WC518 Carter & Burgess / Capital Excavation 

02/23/04 02/21/05 05/11/05 

Ronald W. Reagan Blvd. South 

Phase I (FM 1431 to FM 2243) 

02WC433 TC&B / Capital Excavation 

10/14/02 01/01/05 6/8/2005 

CR 258 (US 183 to Sunset Ridge) 05WC323 Haynie Consulting / Austin Bridge & Road 

01/09/06 09/23/06 11/02/06 

San Gabriel Parkway Phase I (Halsey Dr. to CR 273) 05WC321 Malone Wheeler / J.C. Evans 

05/08/06 02/15/07 03/08/10 

Ronald W. Reagan Blvd. North 

Phase I (SH 29 to FM 3405) 

04WC214 PBS&J / Chasco 

04/22/05 03/08/07 06/14/07 

Lakeline Blvd. 

(Lyndhurst to Parmer Lane) 

05WC325 Carter & Burgess / J.C. Evans 

10/25/06 07/20/07 08/25/07 

Ronald W. Reagan Blvd. South 

Phase II (FM 2243 to SH 29) 

05WC324 TC&B / Ranger 

01/23/06 02/13/08 09/17/08 

US 183 Widening at CR 274 (Turn Lane Improvements) 07WC507 Malone Wheeler / Austin Bridge & Road 

07/09/07 02/18/08 04/28/08 

Kauffman Loop 

(S. of SH 29, East and West of Reagan) 

N/A TC&B and Randall Jones / Williamson County 

Jan 2008 Sep 2008 June 2009 

CR 175 Phase 2A Extension 

(Regional Park to Creekside Meadows) 

09WC707 Haynie Consulting / RGM Constructors 

04/20/09 01/28/10 02/03/10 

Signal at US 183 and FM 3405 09WC713 Brown & Gay / Republic ITS 

11/19/09 03/09/10 04/08/10 

Left Turn Lanes on US 183 at FM 3405 10WC805 Brown & Gay / Aaron Concrete 

03/11/10 05/25/10 12/17/10 

CR 214 Ph 2A 

(Rolling Hills Rd to San Gabriel Ranch Rd.) 

09WC723 Rogers Design Services / FTWoods 

06/25/10 01/07/11 01/31/11 

RM 1431 (183A to Cottonwood Creek Trail) N/A CP&Y / Hunter 

Feb 2010 Feb 2010 Aug 2011 

San Gabriel Parkway, Phase 2 (183A to CR 270) 11WC903 Malone/Wheeler / Ranger Excavating 

04/15/11 10/26/11 03/14/12 

Brushy Creek Road (Parmer Ln. to Arrowhead Trail) N/A LAN / Chasco 

05/06/11 Mar 2012 Apr 2012 

SH 29 TWLTL at Liberty Hill (SH 29 Safety 

Improvements) 

11WC915 Chiang Patel & Yerby, Inc. / Joe Bland 

12/02/11 12/03/12 Pending 

San Gabriel Parkway West (Halsey Dr to Bagdad Rd) N/A Malone/Wheeler / Cash 

Jun 2011 Feb 2013 Pending 

Hero Way (US 183 to CR 269) 

(formerly Reveille Blvd) 

10WC823 Pape Dawson / DNT Construction 

02/07/11 02/15/13 Pending 

CR 260/266 Intersection Improvements at SH 29 

(SH 29 Safety Improvements) 

12IFB00005 CP&Y, Inc. / 'Patin Construction 

10/05/12 04/09/13 Pending 


NOTICE TO 

CONSTRUCTION 

PROCEED 

START 

FINISH 

Cottonwood Creek Trail (CR 185) 

(and New Hope) 

CR 179 (Ronald Reagan Blvd. to CR 175) 

Klotz Capital Excavation City of Cedar Park 05/24/12 Jun 2012 Jul 2012 Due Sep 2013 

Karen Friese & 

Associates 

Chasco 

Constructors 

City of Leander 12/06/12 Jan 2013 Jan 2013 Oct 2013 









Project complete. Contract close-out package is ready for transmittal to the County. 

Project complete. Close-out is resuming. Waiting on Ranger to submit lien waivers or final affidavit of all bills paid to issue Final 

Acceptance. 


Project constructed by County forces. 

Project complete. The Contract close-out package will be prepared for transmittal to the County. Certificate of Acceptance has been 

issued. 

Project complete. The Contract close-out package will be prepared for transmittal to the County. Certificate of Acceptance has been 

issued. 


Project complete. The Contract close-out package will be prepared for transmittal to the County. Notice of Warranty has been sent 

to FTWoods for final warranty work prior to expiration. 

Project complete. Managed by TxDOT. 

Ranger has provided the remaining close-out documentation and the final pay estimate for retainage release is being released. The 

Certificate of Acceptance is being prepared. Warranty expires 03/13/14. 

Project complete. Managed by Cedar Park. 

The Ribbon Cutting Ceremony was held on 12/13/12. Joe Bland and their subcontractors are watering for vegetative establishment, 

as needed. GEC is preparing the QCQA HMAC production & placement bonus/penalty CO. 

A Ribbon Cutting Ceremony was held on 2/14/13 at 10 am. Cash continued spreading topsoil, seeding and working on punchlist 

items. 

The Ribbon Cutting Ceremony was held on 3/1/13. DNT has completed all punch list items except for establishing vegetation 

throughout the project. The Railcom12 controller was installed Friday, 4/26/13. 

Patin requested substantial completion as of 4/9/13. The Contractor has completed punchlist items except vegetative establishment. 

The Ribbon Cutting Ceremony was held on 5/3/2013. 


Capital is currently processing flex base on New Hope from west of Cottonwood Creek Trail to the east end of New Hope. The 

Contractor is also processing subgrade from west of Cottonwood Creek Trail to the west tie-in on New Hope. Capital has completed 

the installation of the storm sewer boxes under the proposed northbound lanes of Cottonwood Creek Trail from the cross culvert at 

Cottonwood Creek to the north side of New Hope and is hauling off the spoils from the box installation on the Cottonwood Creek 

Trail. 

Chasco completed fine grading the flex base from Ronald Reagan to the west side of Brushy Creek on the proposed eastbound 

lanes of CR 179. The Contractor has also slipped ribbon curb from Ronald Reagan to just west of Brushy Creek along the south side 

of the roadway. The asphalt subcontractor primed the flex base from Ronald Reagan to Bull Nettle Dr. Chasco installed the north 

half of Culvert C (triple barrel 6’x4’ boxes and is setting forms for the downstream headwalls on Culverts A and B. The Contractor 

poured curb and gutter at the intersections with Ronald Reagan and Republic Trails Blvd. Chasco is also forming for the curb and 

gutter at the intersections of Ronald Reagan and Republic Trails Blvd. Utility work is ongoing east of Brushy Creek (Setting new 

poles along the ROW). 


PRECINCT 2 - COMMISSIONER CYNTHIA LONG 



DESIGN 

BID 


2006 ROAD BOND PROJECTS IN DESIGN ENGINEER 

BID LETTING 


START FINISH 

ENVIRONMENTAL 

CLEARANCE 


Lakeline Blvd. Phase 2 

(Old Quarry Rd to Old 2243) - County 

Baker-Aicklen 

Jan 2012 May 2013 

TBD 

(Pending ROW Acquisition) 

Due Diligence 

Investigations 

Completed: 

Fall 2012 

Easements have been acquired for the Gilpin property, and Baker-Aicklen is beginning design adjustments 

to eliminate retaining walls. TCEQ approval of the CZP was received on 11/13/12. One ROW parcel 

(Spring/Summer tract) remains to be closed. 

Lakeline Blvd. Phase 3 

(Crystal Falls Pkwy to Old Quarry Rd) - Developer 

Baker-Aicklen 

Jan 2012 

May 2013 

Late Spring 2013 

Early Summer 

2013 

Early 2014 

Due Diligence 


Completed: 

Fall 2012 

Baker-Aicklen received draft plans for Developer phase from subconsultant RPS-Espey and is preparing to 

submit 100% PS&E next week. The bidding procedure was provided to KB Home on 4/15/13. The 

developer agreement with KB Home was approved by the Court on 2/5/13. 

Seward Junction Improvements Study 

(CR 213, CR 259, CR 260, CR 263, CR 266) 

Loomis Partners 

Aug 2011 

Feb 2013 

N/A 

Due Diligence 

Investigations To Be 

Completed: 

TBD 

Loomis is finalizing their work authorization for schematic development. Loomis submitted the revised 

Krause Farm Historical Research Report on 3/1/13, in response to the 2/13/13 GEC comments. A project 

update meeting was held on 1/7/13 to discuss archeological constraints and a final recommended 

alignment in the northeast quadrant. 

US 183 at RM 1869 

Gonzalez-De La 

Garza & 

Associates 

Oct 2011 

Spring 2013 

TBD 

Categorical Exclusion 

Anticipated Approval: 

Spring 2013 

Walker has completed survey field work and submitted draft topo files on 4/30/13. Gonzalez-De La Garza 

has begun work on the 30% PS&E. TxDOT is preparing an AFA for the project. TxDOT approved the 

signal location, and provided traffic comments on the preliminary signal plans on 12/19/12. Cox-McLain 

has begun environmental investigations. 

Lakeline Blvd. at US 183 

Kimley Horn 

Nov 2011 

Feb 2013 

TBD 

N/A 

Kimley-Horn submitted the 90% design submittal on 2/26/13 and it is currently under review. A meeting 

with TxDOT to discuss future plans for US 183 was held on 8/10/12, and a weaving analysis was submitted 

on 9/4/12. TxDOT provided comments on the weaving analysis on 9/6/12. Kimley-Horn submitted the 

final report on 1/18/12, and it was transmitted to TxDOT and the City of Austin on 1/18/12. 

CR 258 (Sunset Ridge to Reagan Blvd) 

CEC 


Mar 2013 

TBD 

Due Diligence 


Completed: 

Fall 2012 

A project update meeting to discuss potential alignments and project issues was held on 2/14/13. CEC is 

moving forward with 60% PS&E. Comments on 30% PS&E were returned on 9/14/12, and a comment 

review meeting was held on 9/14/12. Blanton received the archeological permit from THC on 9/11/12. 


PRECINCT 3 - COMMISSIONER VALERIE COVEY 



CONSTRUCTION 

2000/2006 ROAD BOND COMPLETED PROJECTS PROJECT NO. 


SUBSTANTIAL FINAL 


START 

COMPLETION* COMPLETION 

Cedar Hollow at SH 29 Signal N/A Haynie Consulting / 

- - - 


Georgetown Inner Loop - Project 2 

(Middle Fork to SH 29) D.B. Wood 

N/A PBS&J / Austin Bridge & Road 

01/23/02 - 08/04/03 Project complete. 

Georgetown Inner Loop - (CO to Project 2) 

(Middle Fork to SH 29) D.B. Wood 

N/A Steger Bizzell / Austin Bridge & Road 

- - 08/04/03 Project complete. 


(FM 2243 to IH-35) 

N/A HDR / N/A 

- - - 


CR 152 Bridge 04WC207 Steger & Bizzell / Chasco 



(FM 2338 to D.B. Woods) Cedar Breaks 

PBS&J / Austin Bridge & Road 


Georgetown Inner Loop East 

(SH 29 to FM 971) 

Steger Bizzell / Chasco 


Georgetown Inner Loop East Extension 

(CR 151 to I-35 BUS) 

05WC311 Steger Bizzell / Joe Bland 



Phase II (FM 3405 to FM 2338) 

07WC502 PBS&J / J.C. Evans 

03/12/07 05/23/08 05/04/09 Project complete. Final Project Close-out package to the County is being prepared. 

12" Water Main Relocation for SH 29 Widening 08WC604 Steger Bizzell / Herschap 


SH 29/CR 104, Phase 1 

(At New High School and CR 104 Intersection) 

08WC602 Steger Bizzell / Cash Construction 


SE Inner Loop @ FM 1460 

Processing balancing Change Order with Bonding Company for closure of construction contract. TxDOT has accepted the ditches 

09WC708 LAN / JO'B Site Construction 

06/01/09 11/06/09 01/28/10 

(Intersection Improvements) 

along FM 1460 in the current conditions. 

CR 111 / Westinghouse Rd. 

Received documentation from the Bonding Company that all claims have been settled and the pay application for release of 

08WC608 Huggins Seiler & Associates / J.C. Evans 

06/16/08 06/16/10 Pending 

(From Hewlett Loop to FM 1460) 

retainage has been paid. The Certificate of Acceptance is being prepared. 

CR 104, Phase 2 

(From SH 130 to South of New School property) 

10WC812 Steger Bizzell / Chasco 

09/02/10 05/26/11 12/14/11 TxDOT issued project acceptance. Certificate of Acceptance has been sent out for signature. 

CSJ: 0914-05-141 

SH 29 Intersection Improvements at Park Place & Jack 

Nicklaus 

11WC916 CP&Y / Wolff Construction 


Williams Drive (D.B Wood to FM 3405) 

The Ribbon Cutting Ceremony was held on 12/16/10. Punchlist items are complete and the Certificate of Completion is being 

09WC706 KBR / JC Evans / Atkins 

03/16/12 04/13/11 Pending 

CSJ: 2211-01-016 

prepared. GEC is finalizing the balancing change order & final pay estimates, and preparing the files for close out. 


NOTICE TO 

CONSTRUCTION 

PROCEED START 

FINISH 


11WC902 

Ronald W. Reagan Blvd. North Phase III 

(FM 2338 - SH 195) 

SH 195 Project 1 

(Bell County Line to 3.4 mi south of SH 138) 

12IFB00010 


Phase IV (SH 195 to CR 237) 

Stanley (Design) 

Cobb Fendley 

(Construction) 

ARCADIS 

AECOM (TCB) 

Ranger 

(for American 

States Insurance 

Company) 

James 

Construction 

Ranger 

Excavating 

Huitt-Zollars 

GEC / CP&Y 

01/11/11 

03/30/11 Limited 

05/23/11 Full NTP 

04/04/11 

TxDOT 01/27/11 Mar 2011 Mar 2011 

Anticipated 


Anticipated 

Mar 2014 

CP&Y 03/29/12 05/15/12 05/25/12 Due 11/14/2013 

Time was suspended as of 2/9/2013. Ranger began excavating for the pavement widening near the intersection of CR 245 for the 

addition of left turn lanes. Subcontractor BMP watered for vegetation establishment. 

James Construction removed forms from box culverts and pipe end treatments. Subcontractor Ranger excavated material from area 

of project between CR 228 and CR 229 and hauled material to the east header of mainlane bridge east of Florence. The 

Subcontractor processed flex base on the mainlanes south of CR 228 and south of FM 487 and processed subgrade on CR 138 

from existing SH 195 to new SH 195. Ranger excavated ditchlines at CR 138 intersection with existing SH 195 and placed topsoil on 

completed slopes along roadway at various locations on the project. Subcontractor Ramming paved all the ramps and areas of 

finished flex base east of Florence. James is placing topsoil on the south end of the project to shoulder up the edge of the roadway. 

From FM 487 to the south, Subcontractor Ranger is placing flex base for the entrance ramp to the new mainlanes. North of FM 487, 

the contractor has rough cut the turnaround under the bridge, built the ramps from the new FM 138 bridge to SH195 and is placing 

topsoil on the sides. Ranger is placing flex base from the bridge to SH 195 on the existing roadway section out of Florence. The 

Subcontractor has excavated down to subgrade in the area for the new bridge at SH 195 and CR 228. 

Ranger Excavating completed flex base for tie-ins from the new roadway to CR 239 and finished final flex base ahead of priming and 

paving operations on the new Reagan roadway along CR 239. The Contractor placed topsoil along the newly paved roadway from 

SH 195 to one mile north and completed flex base and tie-ins to Reagan for the driveways south of the Yearwood tunnel. 

Subcontractor Greater Austin completed formwork for bridge deck slab on the Dry Berry Creek Bridge located near CR 234 and 

completed placing forms and poured concrete for Safety End Treatments on various driveway culverts located between CR 239 and 

CR 234. GAD also began forming & pouring concrete mow strip for the guardrails at the Smalley Branch Bridge. Subcontractor JKB 

installed culvert pipe for the driveways south of the Yearwood tunnel. Subcontractor Ramming paved Type B asphalt from one half 

mile north of SH 195 to north of the intersection with CR 239. The first layer of asphalt pavement has been placed from SH 195 to 

approximately 2 miles north of SH 195. Subcontractor BMP continued to install metal beam guardrail on all four corners of Smalley 

Branch Bridge and the Yearwood tunnel. 


PRECINCT 3 - COMMISSIONER VALERIE COVEY 

ROAD BOND PROJECTS UNDER CONSTRUCTION 

(CONT'D) 


(South of Ronald Reagan to IH 35) 

2006 ROAD BOND PROJECTS IN DESIGN 

CR 245 

(RM 2338 to 0.223 miles east of RM 2338) 

ENGINEER CONTRACTOR OBSERVER BID AWARD 

ARCADIS 

ENGINEER 

SEMA 

Construction 



CONSTRUCTION 

START 

FINISH 

TxDOT 09/27/12 Jan 2013 Jan 2013 Feb 2015 

DESIGN 

BID 


BID LETTING 


START FINISH 

Steger Bizzell Jul 2010 Aug 2012 

NOTICE TO 

PROCEED 

TBD 

SEMA placed flex base on southbound roadway from east end of project to near Shell Road and placed embankment to subgrade 

from Shell Road to Sun City Blvd. Subcontractor Royal Vista formed and poured end treatments on drainage culverts at various 

locations on the project. Brazos River Authority’s contractor is boring for installation of steel encasement pipe under existing SH 195 

at Shell Road for their waterline relocation. Utility relocation is ongoing from Shell Road to IH 35, with Verizon relocations pending 

execution of the utility agreement (waiting on TxDOT approval of the determination of eligibility). PEC utility agreement was 

approved by Court on 3/19/13. CTSUD, LCRA and Georgetown Electric relocations are complete. Brazos Valley River Authority 

(BRA) relocations began on 2/18/13 and are anticipated to be complete in early May. 

ENVIRONMENTAL 


CLEARANCE 

Due Diligence 


Completed: 

Fall 2011 


The Court tabled a request to authorize advertisement for construction bids, pending discussions on 

funding. Verizon and PEC relocations are complete. ROW and temporary construction easement 

acquisition is complete. 

Southwest Bypass (RM 2243 to IH 35) 

HDR 

TBD 

TBD 

TBD 

TBD 

The City of Georgetown has HDR under contract to begin the planning process. An ILA between the City 

and County was approved by Georgetown's City Council on 1/25/11, and by the Court on 2/15/11. 

CR 110/Arterial A Area Study 

(US 79 to Inner Loop, FM 1460 to SH 130) 

(Preliminary Alternatives and Constraints Mapping) 

Kennedy 

Feb 2012 June 2013 

TBD 

Due Diligence 


Completion Date: TBD 

Final alignments to be determined by the cities. A coordination meeting with the City of Round Rock and 

City of Georgetown was held on 1/16/13. Coordination meetings with elected officials and stakeholders 

are ongoing. A project update meeting was held on 10/4/12. A coordination meeting with staff from the 

Cities of Georgetown, Round Rock, and Hutto was held on 8/2/12. Constraints maps have been 

completed and preliminary alignments are being finalized. 

CR 110 North Schematic 

(North of CR 107 to SH 130) 

Kennedy / 

Hejl Lee 

Feb 2013 July 2013 

N/A 

Due Diligence 



Kennedy submitted a list of property owners for Right of Entry requests on 4/11/13, and ROE letters were 

sent out on 4/16/13. 14 of 39 ROEs have been received to date. A scoping meeting was held on 11/19/12. 

CR 111/CR 105 Study 

(FM 1460 to SH 130) 

(Constraints Mapping and Alternatives Analysis) 

Steger Bizzell 

Mar 2012 

Sep 2012 

TBD 

Due Diligence 



Final alignments to be determined by the City. A coordination meeting with the City of Round Rock and 

City of Georgetown was held on 1/16/13. A project update meeting was held on 10/4/12. Coordination 

meetings with major landowners are underway. Coordination meetings with the City of Georgetown were 

held on 8/17/12 and 8/28/12. Steger Bizzell submitted a constraints and preliminary alignments exhibit on 

7/5/12. A coordination meeting was held with the City of Georgetown and TxDOT on 4/27/12, to discuss 

the study area and typical section. 


(3.4 mi south of SH 138 to south of Ronald Reagan) 

ROW Acquisition and Utility Coordination 

ARCADIS 

TxDOT Managing Design, Letting & Construction of SH 195 

Letting is Scheduled for June 2013 

EA approved (FONSI 

re-validated) 12/13/11 

A ROW update meeting was held on 4/18/13. All but 3 parcels have been acquired or have PUA. Utility 

Agreement forms and plans were distributed to CenturyLink (formerly Embarq), Oncor Electric, PEC, 

CTSUD, LCRA, and SBA. CTSUD's contractor began work on the waterline relocations on 5/1/13. The 

Court approved PEC's Utility Agreement on 3/19/13 and PEC began clearing for installation of the new 

wood poles on 5/1/13. Oncor relocations are underway. Centurylink is working on redesign of their 

relocations. 

2006 ROAD BOND PROJECTS 

Managed by Georgetown 

FM 1460 North 

(North of University/Chandler to Quail Valley Drive) 

ENGINEER 

Brown & Gay 

DESIGN 

BID 


BID LETTING 


START FINISH 

Winter 2012 

Dec 2013 

By TxDOT 

TBD, Anticipated in 2015 

ENVIRONMENTAL 

CLEARANCE 

Due Diligence 




An Interlocal Agreement was approved on 10/9/12 with the City of Georgetown for the development and 

construction of FM1460 from University Blvd to Quail Valley Dr. The County will provide $4.5M within 60 

days of execution of the revised funding agreement between TxDOT and the City and will provide notice to 

CAMPO & TxDOT that the 2014 CAMPO STP-MM allocation for CSJ 2211-02-026 in the amount of 

$3,367,580 with a non-Federal share provided by TxDOT of $841,895 to the FM 1460 project will be 

administered by the City. The City of Georgetown agreed to amend the current AFAs to complete the FM 

1460 improvements described above with the City completing PS&E by December 31, 2014 and TxDOT 

bidding, constructing & inspecting the project. The City will provide all right-of-way & easements, 

environmental mitigation, and utility conflict resolution for the FM 1460 project to enable a 2015 bidding 

schedule. The City will provide all construction funding not secured by agreement from other sources for 

the FM 1460 project to enable a 2015 bidding schedule, and will work with the City of Round Rock and 

other parties for additional funding through interlocal agreements, developer participation, and other 

financing methods. 


PRECINCT 4 - COMMISSIONER RON MORRISON 

2000/2006 ROAD BOND COMPLETED PROJECTS 

PROJECT NO. 




START 

CONSTRUCTION 

SUBSTANTIAL 

COMPLETION* 

FINAL 

COMPLETION 

Bridge Replacements 

Package I (CR 406, CR 390 & CR 427) 

02WC426 HDR / Ellis-McGinnis 

06/25/02 11/22/02 12/05/02 

CR 412 (FM 619 to CR 421) N/A Inland Civil / RGM 

10/31/02 - 08/27/03 




CR 368/369 (CR 101 to CR 366) 02WC418 Haynie Consulting / Camp Excavation and Contracting 06/03/02 - Apr 2003 

CR 300/CR 301 (FM 972 to FM 971) 03WC517 Pate Engineers / Capital Excavation 

08/04/03 01/10/04 10/05/04 



Bridge Replacements 

Package IIA (CR 424) 

03WC520 HDR / FT Woods 

11/03/03 - 01/06/04 


Chandler Road (West of FM 1460 to CR110) 03WC516 Denmon Engineering / J.C. Evans 

08/04/03 03/16/05 03/14/06 

CR 137 (County Line to FM 1660) 05WC304 Pate Engineers / J.C. Evans 

01/24/05 10/20/05 04/12/06 

CR 112 - Phase I (Chandler Rd to FM 1460) 05WC310 Baker-Aicklen / J.C. Evans 

03/05/05 08/31/05 09/07/06 

Limmer Loop Phase 1A (CR 136, CR 164 & CR 119) 04WC216 Pate Engineers / Chasco 

11/15/04 07/07/06 02/08/07 

US 79 Section 3A: CR 402 to Mustang Creek N/A Carter & Burgess / Joe Bland 

Jan 2005 - Nov 2006 

Chandler Road - Phase II (CR110 to FM 1660) 06WC407A Reynolds Smith & Hills / Rodman 

09/18/06 12/10/07 05/23/08 

Limmer Loop Phase 1B (Haybarn Lane to CR 119) 06WC420 Pate Engineers / Cash 

03/12/07 03/05/08 04/07/08 

US 79 Section 1: McNutt Creek to FM 685 N/A Jacobs Carter Burgess 

- Summer 2008 

Limmer Loop Phase 1C (CR 110 to SH 130) 08WC603 Pate Engineers / JC Evans 

04/30/08 10/02/08 05/11/09 

Gattis School Rd (Red Bud Ln. to east of Winterfield Dr.) N/A Halff Associates / Cash 

02/09/09 June 2010 Fall 2010 

Chandler Road - Phase 3B (CR 368/369 to SH 95) 09WC717 Jacobs Carter Burgess / Chasco 

10/01/09 10/14/10 07/23/11 

FM 1660 @ CR 128 (Landfill Road) 

CSJ: 1566-01-012 

11WC913 HNTB / Aaron Concrete 

07/25/11 09/14/11 07/02/12 

FM 1460 (Old Settler's Blvd. to North of University) N/A Huggins Seiler & Associates / Hunter Industries 

Oct 2009 - Oct 2011 

Second Street Drainage Improvements 

(Various Locations in Taylor) 

09WC712 Halff Associates / Austin Engineering 

03/26/10 12/23/11 02/21/12 

Chandler Road - Phase 3A 

(FM 1660 to CR 368/369) 

CR 351 @ Donahoe Creek 

CSJ# 0914-05-172 

Second Street Roadway Improvements 

(US 79 west of Taylor to SH 95) 


10WC822 

09/08/11 Limited 

11/07/11 Full NTP 

12/14/12 Pending 

N/A Brown & Gay / James Construction 

Aug 2012 Dec 2012 Dec 2012 

Halff Associates / FTWoods / GEC & 

10WC821 02/17/11 02/07/13 Pending 

City of Taylor 

ENGINEER 

CONTRACTOR 

SD Kallman / Chasco 

OBSERVER 

BID AWARD 

NOTICE TO 

PROCEED 

CONSTRUCTION 

START 

FINISH 





TxDOT project complete. 

Project complete. Contract close-out package was sent to the County on 3/30/10. 

Project complete. Final Project Close-out package to the County is under review. 

TxDOT Project complete. 

Project complete. Final Project Close-out package to the County is being prepared. 

Project complete. Managed by Travis County. 

Project complete. Certificate of Acceptance has been issued. Warranty expires 07/22/13. 

Project complete. Received TxDOT concurrence as of October 25, 2012. 

TxDOT Project complete. 

Project complete. Final Project Close-out package to the County is being prepared. 

The Ribbon Cutting Ceremony was held on 12/20/12. Substantial Completion was granted effective 12/14/12. Chasco completed all 

concrete erosion controls as directed. Subcontractor Matoka has completed about 70% of the rock rip rap controls. No work has 

begun on the erosion control blanket. 

TxDOT project complete. 

Subcontractor, Joe Bland, finished flex base placement on Vance Street, Talbot Street, Victoria Street, and Sloan Street as part of 

Change Order #16. FTWoods is watering for vegetative establishment. A Ribbon Cutting Ceremony was held on 3/7/13 at the 

Howard Theater in Taylor, TX. 


Kenney Fort Boulevard (formerly Arterial A Ph 1) 

(Joe DiMaggio Blvd. to Forest Creek Dr.) 

SD Kallman / 

Dannenbaum / 

HDR 

Chasco 

City of Round 

Rock 

06/23/11 Sep 2011 Sep 2011 

Anticipated 

Sep 2013 

Chasco continued to form sidewalk south of US 79, resumed rubbing/patching handrail on the Brushy Creek Bridge, pumped 

concrete rip rap underneath both the US 79 and UPRR bridges, and formed rip rap and flumes for various area inlets north of US 79. 

The Contractor continues spreading topsoil north and south of US 79, and started placing cement treated base underneath US 79. 

Subcontractor ATS is installing illumination conduit south of US 79. Subcontractor Ramming finished paving the remaining portion of 

the project with 4” of Ty B asphalt. 

12IFB00004 

CR 138 

(SH 130 to CR 137) 

Baker-Aicklen Aaron Concrete GEC 07/24/12 09/21/12 10/01/12 Due 6/28/13 

Subcontractor Chandler Concrete continues forming and pouring mow strip at Culverts C & D. Aaron Concrete is excavating and 

placing flex base for various driveways throughout the project. Subcontractor RSI completed the MBGF at Culvert D. 


PRECINCT 4 - COMMISSIONER RON MORRISON 


(CONT'D) 

ENGINEER CONTRACTOR OBSERVER BID AWARD 



NOTICE TO 

PROCEED 

CONSTRUCTION 

START 

FINISH 


13IFB00118 

CR 108 

(US 79 to Limmer Loop) 

Karen Friese & 

Associates 

DNT GEC 02/05/13 02/22/13 03/04/13 Due 11/29/13 

DNT continued to excavate to subgrade and is hauling off roadway excavation spoils. The Contractor set CTB along Limmer Loop 

for the Culvert H extension, began setting 24” and 30” RCP on Storm Line E, and set 2-24” RCP for Culvert D. 

PROJECTS BIDDING / CONTRACTING 

ENGINEER 

ADVERTISEMENT 

BEGINS 

BID LETTING 

BID AWARD 

ANTICIPATED 

N.T.P. 


START 

FINISH 


13IFB00119 

CR 170 

(South of SH 45 to North of Pflugerville Parkway) 

Baker-Aicklen 12/30/12 01/23/13 03/04/13 Jun 2013 Jun 2013 Mar 2014 

PreConstruction Meeting is scheduled for 5/10/13. AT&T relocation is anticipated to be complete by the end of May. Construction 

contracts have been executed with BPI. The Notice of Award was issued to BPI on 3/13/13. The Commissioners Court approved 

the award of the construction contract to BPI Environmental on the 3/5/13. Manville relocations continue and are nearing 

completion. Atmos and Oncor relocations are complete. AT&T Metro is moving forward with design, and will be relocating to 

Oncor's poles. All ROW parcels have been acquired or have Possession and Use agreements. 

2006 ROAD BOND PROJECTS IN DESIGN 

CR 119 

(Limmer Loop to Chandler Rd) 

ENGINEER 

Bury & Partners 

DESIGN 

BID 


BID LETTING 


START FINISH 

Jan 2011 May 2013 

TBD 

ENVIRONMENTAL 

CLEARANCE 

Due Diligence 


Completion Date: Winter 

2011/2012 


Bury & Partners submitted 100% PS&E on 4/11/13, and it is currently under review. The additional SUE 

investigation of gas lines has been completed and analyzed for potential conflicts, and review comments 

on the 90% PS&E were returned on 3/8/13. 

Chandler Road Expansion 

(FM 1460 to SH 130) 

Seiler Lankes May 2012 June 2013 TBD 

Due Diligence 



Comments were received from the City of Round Rock on 3/22/13, and a meeting with Seiler Lankes to 

discuss was held on 3/26/13. Seiler Lankes submitted the 60% design package on 2/19/13 and it is 

currently under review. An update meeting with the City of Round Rock was held on 12/10/12. Seiler 

Lankes is coordinating with Baker-Aicklen regarding developer planned median openings and future 

intersections. 

CR 110 Middle 

(North of Limmer Loop to CR 107) 

Kimley Horn Jan 2013 June 2013 

TBD 

Due Diligence 



A meeting to review alternatives was held on 4/16/13, and a meeting with Atmos to discuss potential 

impacts to their facilities was held on 4/26/13. Kimley Horn submitted an alternatives layout on 3/5/13. 

Kimley Horn submitted a data collection request on 1/31/13. Right of Entry requests were sent out on 

2/12/13, and ROE has been received for all but one parcel. 

CR 110 South 

(US 79 to Limmer Loop) 

RW Armstrong Jan 2013 June 2013 

TBD 

Due Diligence 



A design meeting was held with RWA on 4/30/13. Notified RWA on 3/12/13 that ROE has been received 

for all parcels. RW Armstrong submitted a property owner list for Right of Entry requests on 2/1/13, and 

Right of Entry requests were sent out on 2/8/13. A design kick-off meeting was held on 2/6/13, and RW 

Armstrong is proceeding with preliminary design. 


WILLIAMSON COUNTY PASS THROUGH FINANCING PROGRAM 


COMPLETED PROJECTS 

PROJECT NO. 

ENGINEER / CEI / CONTRACTOR 

START 

CONSTRUCTION 

SUBSTANTIAL 

COMPLETION* 

FINAL 

COMPLETION 


IH-35 @ SH 29 Turnarounds 

CSJ: 0015-08-122 

07WC513 HNTB Corporation / PBS&J / Austin Bridge & Road 10/29/07 08/26/08 06/02/09 

Project Complete. All necessary documentation has been submitted to TxDOT. Preparing closeout package for County. 

US 79 Section 5b (FM 1063 to Milam County Line) 

CSJ: 0204-04-042 

08WC607 LAN / Huitt-Zollars / JC Evans 

01/27/09 08/07/10 07/11/11 

TxDOT has issued their letter of Final Completion. Preparing to issue the Certificate of Acceptance now that the bonding company 

has submitted the final invoice for the remaining mobilization payment. GEC preparing final documentation for submittal to TxDOT 

and closing out the project files. 

US 79, Section 5a (E. Taylor to FM 1063) 

CSJ: 0204-04-040 

08WC619 Jacobs Carter Burgess / Huitt-Zollars / Hunter 

01/27/09 05/02/11 05/29/12 

TxDOT approved a driveway permit for Jacobs to hire a contractor to replace culvert pipes under five driveways. GEC requested 

quantity summary and sealed plan sheets to obtain change order pricing from Ramming. GEC preparing to submit final 

documentation to TxDOT. Final files have been uploaded to ProjectWise and placed in storage. 

US 183 (San Gabriel River to SH 29) 

CSJ: 0151-04-063 

09WC720 Dannenbaum / HDR / Dan Williams 

12/21/09 04/06/12 03/19/13 

The CEI is negotiating the final change orders and closing out the project files. All punchlist items are complete and CEI has 

recommended issuance of Final Completion. Received TxDOT's acceptance on 4/17/13, effective as of 3/19/13. 

RM 2338 (FM 3405 to Reagan Blvd.) 

CSJ: 2211-01-023 

09WC722A Steger Bizzell / Atkins / Joe Bland 

09/28/10 07/12/11 02/25/13 

Received TxDOT acceptance on 3/6/13, effective as of 2/25/13. The Certificate of Completion is being routed for signatures. The 

GEC is working to close out the project including final pay estimate. 

US 79, Section 3 (E. Hutto to CR 402) 

CSJ: 0204-02-027 

PROJECTS UNDER CONSTRUCTION 

13IFB00108 

IH-35 Northbound Ramps and Frontage Road 

(Westinghouse Rd to SH 29) 

CSJ: 0015-08-128, etc. 

PROJECTS IN DESIGN 

FM 1660 (CR 134 to CR 101) Schematic & ENV Clearance 

CSJ: 1566-01-009 

10WC817 Klotz / JD Ramming / Raba Kistner 

09/13/10 07/11/12 01/04/13 

ENGINEER 

HNTB Hunter Industries HDR 12/18/12 02/11/13 4/1/13 

ENGINEER 

Cobb, Fendley & 

Assoc. 

CONTRACTOR 

CONSTRUCTION 

START 

FINISH 

Anticipated 

November 2014 

DESIGN 

BID 


BID LETTING 


START FINISH 

12/13/05 

CEI Firm 

Dec 2010 

BID AWARD 

NOTICE TO 

PROCEED 

TBD 

GEC is working to close out the project. Final balancing change order was approved by the Court on 4/2/13 and the final pay 

estimate is being processed. Received TxDOT's acceptance on 4/17/13, effective as of 1/4/13. 

Hunter is excavating to subgrade from Inner Loop to the tie-in at the northbound frontage road south of Inner Loop. The Contractor is 

placing this material in the fill section south of 2243 for the proposed NBFR. Traffic continues to be one-way on the south side of 

Inner Loop. Subcontractor HL Chapman continues the milling to subgrade south of SH 29 and Hunter is placing this material in the 

fill section north of the San Gabriel River. Subcontractor McKinney Drilling has completed drilling for drill shafts on the north side of 

W. Fork Smith and Hunter has poured all of the shafts for the abutment on the north side of W. Fork Smith. Subcontractor Royal 

Vista is installing the 18in RCP on System A north of Inner Loop. TxDOT environmental determined that adding the City of 

Georgetown Electric's multi-utility bored crossing south of FM 2243 would require additional environmental clearance if it is in the 

construction contract. The Standard Utility Agreement with PAETEC (Windstream) was approved by the Court on 3/19/13 and the 

utility is scheduled to begin relocations south of Inner Loop on 4/10/13. Utility agreements with Suddenlink and the City of 

Georgetown Electric were approved by the Court on 4/2/13. Verizon relocations are underway. Coordination is ongoing regarding 

Atmos’ utility agreement and their contractor is ready to begin relocations as soon as the agreement is executed. PAETEC has 

begun design of additional utilities in conflict between Inner Loop and FM 2243 and is anticipated to have a design ready for Hunter 

to price installation of the conduit next week. A Temporary Railroad Crossing Agreement was executed between Hunter and 

Georgetown Railroad on 3/19/13. 

ENVIRONMENTAL 

CLEARANCE 

Env Assessment 

FONSI Approval 

Date: Spring 2013 

Public Hearing 

Date: Early 2013 



Received comments from FHWA on 11/8/12. The revised environmental document was submitted 

TxDOT on 9/7/12, and TxDOT submitted to FHWA on 10/4/12. The EA has been approved by SHPO and 

on 5/16/12 written notification was received of THC clearance of the archeology. Tribal clearance was 

received on 2/9/12. Received TxDOT Division approval of the schematic for further processing on 

12/15/10.

WILLIAMSON COUNTY ROAD BOND PROGRAM REVISED May 3 ...

Create successful ePaper yourself

Delete template?

Save as template?