- Page 1 and 2: STANDARD FORM OF BIDDING DOCUMENTS
- Page 3 and 4: PREFACE 1. Pakistan Engineering Cou
- Page 6 and 7: (6) INSTRUCTIONS TO USERS OF THIS D
- Page 8 and 9: (vii) (viii) (ix) Schedule G: Speci
- Page 10 and 11: 3. If the Works are not financed fr
- Page 12 and 13: that for the liquidated damages. To
- Page 14 and 15: (14)
- Page 17 and 18: INVITATION FOR BIDS 17
- Page 19 and 20: INSTRUCTIONS TO BIDDERS & APPENDICE
- Page 21 and 22: Clause No Description Page No. (F)
- Page 23 and 24: commercially recognized product res
- Page 25 and 26: IB.9 Documents Comprising the Bid 9
- Page 27 and 28: 13.2 The documentary evidence of th
- Page 29 and 30: (c) (ii) (iii) The approximate weig
- Page 31 and 32: (D) SUBMISSION OF BIDS IB.18 Sealin
- Page 33 and 34: quoted prices, shall only be consid
- Page 35 and 36: (c) A bid will not be considered, i
- Page 37 and 38: (d) (e) Commercial Evaluation It wi
- Page 39 and 40: (b) (c) In the case of Goods of for
- Page 41 and 42: 34.1 The successful Bidder shall fu
- Page 43 and 44: 44.1 The Bidder shall sign and stam
- Page 45 and 46: Appendix B to Instructions to Bidde
- Page 47: Sr.No. Information to be Supplied B
- Page 51 and 52: LETTER OF TECHNICAL BID Bid Referen
- Page 53 and 54: SCHEDULE - A TO BID SPECIFIC WORKS
- Page 55 and 56: SCHEDULE - C TO BID Sheet 1 of 2 ME
- Page 57 and 58: SCHEDULE - D TO BID PROPOSED PROGRA
- Page 59 and 60: SCHEDULE - F-1 TO BID DEVIATIONS FR
- Page 61 and 62: SCHEDULE - G TO BID SPECIFIC OPERAT
- Page 63 and 64: PAST PERFORMANCE AND PRESENT COMMIT
- Page 65 and 66: LETTER OF PRICE BID AND SCHEDULES T
- Page 67 and 68: Dated this ………. day of ……
- Page 69 and 70: SCHEDULE - K TO BID ESTIMATED PROGR
- Page 71 and 72: SCHEDULE OF PRICES 71
- Page 73 and 74: 1. PREAMBLE TO SCHEDULE OF PRICES 1
- Page 75 and 76: 4.5 The Bidder shall be deemed to h
- Page 77 and 78: The Bidder shall recognize such ele
- Page 79 and 80: SCHEDULE OF PRICES Schedule of Pric
- Page 81 and 82: PREAMBLE TO CONDITIONS OF CONTRACT
- Page 83 and 84: Certificate. Programme to be Furnis
- Page 85 and 86: GENERAL CONDITIONS OF CONTRACT 85
- Page 87 and 88: CONTENTS PART I: GENERAL CONDITIONS
- Page 89 and 90: 22.1 Permission to Deliver 95 Suspe
- Page 91 and 92: Care of the Works and Passing of Ri
- Page 93 and 94: PART-I: GENERAL CONDITIONS OF CONTR
- Page 95 and 96: 1.1.27 "Schedule of Prices" means t
- Page 97 and 98: Any decision, instruction or approv
- Page 99 and 100:
4. The Conditions of Contract, Part
- Page 101 and 102:
The Contractor shall be responsible
- Page 103 and 104:
or the Engineer has made available
- Page 105 and 106:
(b) when the Engineer has given his
- Page 107 and 108:
Contractor, unless such association
- Page 109 and 110:
(c) the Engineer gives his consent.
- Page 111 and 112:
The Contractor shall apply in writi
- Page 113 and 114:
(b) (c) (d) (e) (f) (g) (h) (i) (j)
- Page 115 and 116:
28.2 Time for Tests If the Engineer
- Page 117 and 118:
If nevertheless the Employer uses a
- Page 119 and 120:
30.7 Further Tests on Completion If
- Page 121 and 122:
(b) (c) (d) the cost of making nece
- Page 123 and 124:
(a) (b) the Engineer fails to issue
- Page 125 and 126:
The Employer shall reimburse the Co
- Page 127 and 128:
(h) (i) (j) (k) the use or occupati
- Page 129 and 130:
The Contractor shall be liable for
- Page 131 and 132:
Such insurance shall be effected be
- Page 133 and 134:
If in consequence of Force Majeure
- Page 135 and 136:
The Contractor's liability under Cl
- Page 137 and 138:
Disputes and Arbitration 50.1 Dispu
- Page 139 and 140:
INDEX Clause Access, authority for
- Page 141 and 142:
Definitions 1.1 Delayed payment 33.
- Page 143 and 144:
Liability for Damage to Property an
- Page 145 and 146:
Subcontracting 4.1 Subcontractors,
- Page 147 and 148:
Item 5 The remaining text of the or
- Page 149 and 150:
Part-II: Particular Conditions of C
- Page 151 and 152:
45.4 Payment after Termination 162
- Page 153 and 154:
Sub-Clause 1.1.16 The term “Engin
- Page 155 and 156:
The Project Manager/Engineer may ex
- Page 157 and 158:
“The Technical Specifications are
- Page 159 and 160:
Sub-Clause 10.1 Performance Securit
- Page 161 and 162:
“During the period of the Contrac
- Page 163 and 164:
the Site or on the Contractor’s p
- Page 165 and 166:
The Contractor shall, so far as is
- Page 167 and 168:
to do. Provided that if any steps,
- Page 169 and 170:
……………………………
- Page 171 and 172:
Deduction shall be made from the ne
- Page 173 and 174:
(f) (g) (h) (i) (j) (k) use or occu
- Page 175 and 176:
(a) (b) (c) (d) (e) (f) (g) (h) Ins
- Page 177 and 178:
At the end of the Sub-Clause 44.6 t
- Page 179 and 180:
Clause 50 is deleted and in its pla
- Page 181 and 182:
Additional Conditions 52. Liens Eac
- Page 183 and 184:
STANDARD FORMS 183
- Page 185 and 186:
FORM OF BID SECURITY (Bank Guarante
- Page 187 and 188:
FORM OF CONTRACT AGREEMENT THIS CON
- Page 189 and 190:
FORM OF PERFORMANCE SECURITY (Bank
- Page 191 and 192:
FORM OF BANK GUARANTEE FOR ADVANCE
- Page 193 and 194:
INDEMNITY BOND FOR SECURED ADVANCE
- Page 195 and 196:
SPECIFICATIONS SPECIAL PROVISIONS 1
- Page 197 and 198:
DRAWINGS 197
- Page 199 and 200:
Sr. No. Name of the Document LIST O