Draft Contract GSA-OP-06-07 - European GNSS Agency

More documents

Recommendations

Info

imposed where there is provision for interest for late completion. GSA and theContractor expressly acknowledge and agree that any sums payable under this Articleare in the nature of liquidated damages and not penalties, and represent a reasonableestimate of fair compensation for the losses that may be reasonably anticipated fromsuch failure to perform obligations.ARTICLE II.17 – CHECKS AND AUDITSII.17.1. Pursuant to Article 142 of the Financial Regulation applicable to the generalbudget of the European Communities, the European Court of Auditors shall beempowered to audit the documents held by the natural or legal personsreceiving payments from the budget of the European Communities fromsignature of the Contract up to five years after payment of the balance.II.17.2. GSA or an outside body of its choice shall have the same rights as the EuropeanCourt of Auditors for the purpose of checks and audits limited to compliancewith contractual obligations from signature of the Contract up to five years afterpayment of the balance.II.17.3. In addition, the European Anti Fraud Office may carry out on-the-spot checksand inspections in accordance with Council Regulation (Euratom, EC)No 2185/96 and Parliament and Council Regulation (EC) No 1073/1999 fromsignature of the Contract up to five years after payment of the balance.ARTICLE II.18 – AMENDMENTSAny amendment to the Contract shall be the subject of a written agreement concluded bythe contracting parties. An oral agreement shall not be binding on the contractingparties.ARTICLE II.19 – SUSPENSION OF THE CONTRACTWithout prejudice to GSA's right to terminate the Contract, GSA may at any time and forany reason suspend execution of the tasks under the Contract or any part thereof.Suspension shall take effect on the day the Contractor receives notification by registeredletter with acknowledgment of receipt or equivalent, or at a later date where thenotification so provides. GSA may at any time following suspension give notice to theContractor to resume the work suspended. The Contractor shall not be entitled to claimcompensation on account of suspension of the Contract or of part thereof.SIGNATURESFor the Contractor,[Companyname/forename/surname/function]signature[s]: _______________________Done at [Brussels], [date]For GSA,[forename/surname/function]signature[s]:_____________________Done at [Brussels], [date]In duplicate in English.16
ANNEX ITender Specifications and Monitoring17
Page 1 and 2: ANNEX 5 - DRAFT SERVICE CONTRACTCON
Page 3 and 4: I - SPECIAL CONDITIONSARTICLE I.1 -
Page 5 and 6: GSA shall have 30 days from receipt
Page 7 and 8: II - GENERAL CONDITIONSARTICLE II.1
Page 9 and 10: II.3.3.The Contractor declares:- th
Page 11 and 12: calendar day following expiry of th
Page 13 and 14: II.10.4. The use of information obt
Page 15: (i) where execution of the tasks ha
Page 19 and 20: Annex IIIDaily allowancesDaily allo
Page 21 and 22: Burkina Faso Burkina Faso 55 90Buru
Page 23 and 24: Liban Lebanon 70 190Liberia Liberia
Page 25 and 26: Swaziland Swaziland 50 90SyrieSyria

Draft Contract GSA-OP-06-07 - European GNSS Agency

Create successful ePaper yourself

Delete template?

Save as template?