Specifications - Huryn Justice General Contractors

Repairs to Covered Storage Building AS-4171 05110173SECTION 01 32 16CONSTRUCTION PROGRESS DOCUMENTATION04/12PART 1GENERAL1.1 SUBMITTALSSubmit the following in accordance with Section 01 33 00, "SubmittalProcedures."SD-01 Preconstruction SubmittalsConstruction scheduleEquipment delivery schedule1.2 CONSTRUCTION SCHEDULEWithin 21 days after receipt of the Notice of Award, prepare and submit tothe Contracting Officer for approval a Critical Path Method (CPM), NetworkSchedule in accordance with the terms in Contract Clause "FAR 52.236-15,Schedules for Construction Contracts," except as modified in thiscontract. Primavera P6 will be utilized to produce and update all progressschedules.1.3 EQUIPMENT DELIVERY SCHEDULE1.3.1 Initial ScheduleWithin 30 calendar days after approval of the proposed constructionschedule, submit for Contracting Officer approval a schedule showingprocurement plans for materials, plant, and equipment. Submit in theformat and content as prescribed by the Contracting Officer, and include asa minimum the following information:a. Description.b. Date of the purchase order.c. Promised shipping date.d. Name of the manufacturer or supplier.e. Date delivery is expected.f. Date the material or equipment is required, according to thecurrent construction schedule.1.4 NETWORK ANALYSIS SYSTEM (NAS)The Contractor shall use the critical path method (CPM) to schedule andcontrol construction activities. The Network shall have a minimum of 25activities and a maximum of 35 activities. The schedule shall identify asa minimum:SECTION 01 32 16 Page 1