Versar, Inc. - Armed Services Board of Contract Appeals
Versar, Inc. - Armed Services Board of Contract Appeals
Versar, Inc. - Armed Services Board of Contract Appeals
Create successful ePaper yourself
Turn your PDF publications into a flip-book with our unique Google optimized e-Paper software.
'<br />
duty <strong>of</strong>good faith and fair dealing by acting to frustrate, delay and harass <strong>Versar</strong> and by Its<br />
FCU and seismic directives, which were inconsistent with its effective acceptance <strong>of</strong>the<br />
work. <strong>Versar</strong> did not allege any violation <strong>of</strong>any duty to it asa small business. (R4, tabs<br />
561, 562, 1004 at 12359, ~ 64; tr. 12/82-83) Although the claim essentially alleged<br />
compensable and excusable delay, and <strong>Versar</strong> and JJKcalculated certain damages based<br />
upon daily labor costs (e.g., tr. 13/11-14, 91-93, 97; app. br. at 72-73; gov't br. af 104-05),<br />
the claim, and <strong>Versar</strong>'s hearing presentation, did not include any delay analysis,<br />
recognizing and segregating concurrent or other contractor delays, and showing how a<br />
particular alleged delay delayed project completion as a whole.<br />
115. <strong>Versar</strong>'s alleged damages included (1) $734,445.80-about $657,456.00 the<br />
Air Force withheld plus $76,999.80 interest penalty under the ProinptPayment Act<br />
(PPA), 31 U.S.C. §§ 3901-3907; (2) $1,402,715.40 in subcontractor costs, which included<br />
mold removal (said to be an undisputed change); AHU-l work; corridor C-114 work; ro<strong>of</strong><br />
bundle removal costs; costs to replace mini-blinds, textbooks, equipment and cabinets<br />
damaged by the leaking ro<strong>of</strong> or otherwise; extra work after the March 2008 inspection;<br />
and extra work largely related to FCU and seismic restraints, <strong>of</strong>which over $626,936.29<br />
pertained to seismic work; (3) $651,501.43 for extra project management and oversight,<br />
including, inter alia, $84,976.89 for 'maintaining a dedicated <strong>Versar</strong> site superintendent<br />
from March-August 2007; (4) $115,593.00 per the controls REA; and (5) $12,195.66 in<br />
proposal preparation for changes converted into <strong>Versar</strong>'s claim. (R4, tab 562 at 6922)<br />
<strong>Versar</strong> did not specify separate damages for the government's alleged breach <strong>of</strong> its duties<br />
<strong>of</strong>good faith and fair dealing and to cooperate.<br />
116. In May 2009 Mr. Chaney sent Ms. Harvill a message from COR Shrove to<br />
keep a possible fraud investigation against <strong>Versar</strong> secret. Mr. Chaney stated:<br />
Just when you think there's no hope in ,this world .....<br />
Get rid <strong>of</strong> [a DDESS employee] and ruin <strong>Versar</strong> discussion all<br />
in one day!<br />
(Ex. A-82 at 1; tr. 1/196) There has been no allegation <strong>of</strong>fraud in these appeals.'<br />
117. Appellant's allegation that the government breached its duty <strong>of</strong>good faith and<br />
fair dealing now focuses upon Mr. Chaney. As reflected to some extent above, although he<br />
acknowledged that he and the customer, DDESS, had no contracting authority, he assumed<br />
a very active role in the project on behalf <strong>of</strong>DDESS, which considered it critical and<br />
urgent.. As he also acknowledged, he had become adverse to <strong>Versar</strong> as <strong>of</strong>January 2007.<br />
He was frustrated with what he perceived as its lack <strong>of</strong>project management and failure to<br />
submit timely, accurate schedules, and quality issues. He was also frustrated with the<br />
46