Versar, Inc. - Armed Services Board of Contract Appeals
Versar, Inc. - Armed Services Board of Contract Appeals
Versar, Inc. - Armed Services Board of Contract Appeals
Create successful ePaper yourself
Turn your PDF publications into a flip-book with our unique Google optimized e-Paper software.
did not include a delay analysis and it did not present one at the hearing. The <strong>Board</strong><br />
docketed <strong>Versar</strong>'s protectiv~ 7 October 2009 appeal as ASBCA No. 56962.<br />
121. With input fronl Stephanie HaIT <strong>of</strong> Portage, <strong>Inc</strong>., an environmental<br />
engineering firm serving as a GEITA contractor, the COR prepared a 23 November 2009<br />
<strong>Contract</strong> Performance Assessment Report, which is not <strong>of</strong>record (tr. 15/5-6, 92-96).<br />
122. Pre-hearing, on 18 June 2010, the government moved to exclude <strong>Versar</strong>'s<br />
expert's report and related testimony, alleging that it introduced new facts and legal<br />
theories on seismic restraint issues and was a new claim not submitted to the CO.<br />
<strong>Versar</strong> then filed a protective claim dated 8 July 2010, in effect alleging that the<br />
government's defective specifications omitted analysis <strong>of</strong>the building and ro<strong>of</strong>structure;<br />
submittal No. 36 met specifications; and the government's direction to double seismic<br />
restraints on the piping loop was a compensable change. <strong>Versar</strong> incorporated the<br />
damages from its 29 October 2008 claim. On 5 August 2010 the government agreed that<br />
its motion was moot and the <strong>Board</strong>'s order <strong>of</strong>that date stated that, ifthe issue <strong>of</strong>whether<br />
the ~xpert's report contained a new claim became relevant for CDA interest purposes, the<br />
<strong>Board</strong> would address it in its merits decision. CO Sharon Mendez denied the 8 July 2010<br />
claim on 24 September 2010. The <strong>Board</strong> docketed appellant's 27 September 2010 appeal<br />
as ASBCA No. 57386. The four appeals are consolidated for disposition.<br />
Evidence on Seismic and Related Issues by Appellant's Expert<br />
123. Allyn E. Kilsheimer, a registered pr<strong>of</strong>essional structural engineer and chief<br />
executive <strong>of</strong>ficer <strong>of</strong>KCE Structural Engineers, P.C., with considerable experience in<br />
building structural design and emergency structural and .related work, is accepted as an<br />
expert in seismic and structural engineering. 5 He submitted an expert report dated 7 June<br />
2010. (Ex. A-I09 at 2,331 <strong>of</strong>344; tr. 11/13-14,23-24; Bd. COIT. file, app. witness list at<br />
5) Mr. Kilsheimer opined that PSC had not met its responsibility as structural engineer <strong>of</strong><br />
record (SER), and under its design contract with the government, to perform calculations<br />
or analyze the Pinckney structure's ability to resist loads imposed by seismic lateral sway<br />
bracing, including new loads reSUlting from the project. The contract lacked adequate<br />
information and <strong>Versar</strong> was not required to perform the seismic design analysis the<br />
government imposed upon it. (Ex. A-I09 at 4-13 <strong>of</strong>344 and attachs. 1, 13, 14 at 180 <strong>of</strong><br />
344, ~ 9-4c., attach. 20; tr. 11/26-28, 70, 141-42)<br />
5<br />
At the hearing the <strong>Board</strong> accepted Mr. Kilsheimer as an expert in structural<br />
engineering (tr. 11/24). It appears from appellant's expert witness list and a close<br />
reading <strong>of</strong>the transcript that appellant meant to qualify him as an expert in both<br />
structural and seismic engineering and the <strong>Board</strong> accepts· him as such.<br />
48