public sector standard conditions of contract for design and build 2008

More documents

Recommendations

Info

3.7 Confidentiality of Information Supplied to Contractor(1) All information issued to the Contractor shall be used by the Contractor solely for thepurpose of carrying out his duties, obligations and responsibilities under this Contractand not otherwise.(2) The Contractor acknowledges that all official information acquired in the course ofthe carrying out of his duties, obligations and responsibilities under the Contract arecovered by the Official Secrets Act and are strictly confidential. Such informationshall not be published or communicated by the Contractor to any unauthorised personin any form at any time without the prior express sanction of the Employer. Anybreach of or neglect of this responsibility may render the Contractor liable toprosecution under the said Act.3.8 Delay and TimeIf the Contractor shall have duly given notice pursuant to Clause 3.4 and if the SuperintendingOfficer shall not have complied with any of its requirements and if thereby the progress orcompletion of the Works or any part of the Works has been materially affected then, subject tocompliance by the Contractor with Clauses 14, 23 and 32, the Superintending Officer maygrant an extension of time pursuant to Clause 14 and may certify pursuant to Clause 32 suchsum as may be reasonable in respect of any Loss and Expense incurred by the Contractor.4 GENERAL OBLIGATIONS OF THE CONTRACTOR4.1 Contractor's General Responsibilities(1) The Contractor shall, with due care and diligence, design, execute and complete theWorks and remedy any Defects to the satisfaction of the Superintending Officer. TheContractor shall provide all superintendence, labour, Plant, Construction Equipment,materials, goods and all other things, whether of a temporary or permanent naturerequired in and for such design, execution and completion of the Works andremedying of any Defects. Nothing in this Clause shall affect the Contractor'sresponsibilities under common law to complete the Works.(2) Without prejudice to the generality of paragraph (1) of this sub-clause, and to theContractor's obligations under the Contract,(a)(b)(c)the Contractor shall be fully responsible for the design of the Works, andshall complete the design in accordance with the Employer’s Requirements;the Contractor shall be fully responsible for the choice of materials, goods,plants, workmanship to enable the Works to be constructed and completedand/or be fully operational in accordance with the Employer’s Requirements;the Contractor shall be fully responsible for the preparation, developmentand coordinating of all design works and construction at all stages of theWorks from design stage to completion and use of the Works, including theobtaining of all necessary licenses and approvals as may be required by theauthorities or under any enactment, order, ruling or regulation;___________________________________________________________________________________Public Sector Standard Conditions of Contract for Design and Build (Fifth edition December 2008) 8
(d)(e)the Contractor shall be fully responsible for the adequacy, stability andsafety of all site operations and methods of construction, and for theremoval, if so required under the Contract or by the Superintending Officer,of all Temporary Works;the Contractor shall be fully responsible for the adequacy and integrity of thedesign and the Works, and for the Works being suitable or fit in all respectsfor the purpose for which the Works are constructed, and in accordance withthe Employer’s Requirements.4.2 Employment of Qualified Personnel(1) (a) The Contractor shall engage suitably qualified personnel as required byrelevant applicable laws. All fees, costs and expenses so incurred by theContractor shall be deemed to be included in the Contract Sum.(b)Where an Accredited Checker or Registered Inspector is required for theWorks, they shall be engaged by the Employer.(2) No person shall be engaged by the Contractor under Clause 4.2(1) if theSuperintending Officer objects to the engagement of such qualified personnel, inwhich event the Contractor shall promptly nominate and engage other suitablyqualified personnel.(3) In addition, the Superintending Officer shall have the authority to object to thecontinued engagement of any qualified personnel under Clause 4.2(1) at any time.The Contractor shall, upon receiving notice in writing of such objection, cease toengage or allow the qualified personnel from carrying out any work or undertakingany duties in any capacity with respect to the Contract and shall promptly replace himwith other suitably qualified personnel.(4) Upon the engagement of the qualified personnel under Clauses 4.2(1), (2) or (3), theContractor shall not replace such persons as the qualified personnel without the priorwritten concurrence of the Superintending Officer.4.3 Responsibility for Identifying Ambiguities, Discrepancies, etc(1) The Contractor shall forthwith notify the Superintending Officer in writing of anyambiguity, discrepancy, conflict, inconsistency or omission in or between any of theContract documents that may at any time be found. The Superintending Officerinsofar as it may affect the execution or completion of the Works shall then explainand adjust it and may issue to the Contractor an instruction so as to resolve theambiguity, discrepancy, conflict, inconsistency or omission. If, in the opinion of theContractor, compliance with any such instruction is likely to or has involved theContractor in any Loss and Expense which could not have been reasonably foreseenby an experienced contractor (assuming a diligent perusal of the documents submittedprior to Contract), the Contractor shall forthwith notify the Superintending Officer inwriting and subject to compliance by the Contractor with Clauses 14, 23 and 32, theSuperintending Officer may grant an extension of time pursuant to Clause 14 and maycertify pursuant to Clause 32 such sum as may be reasonable in respect of such Lossand Expense.___________________________________________________________________________________Public Sector Standard Conditions of Contract for Design and Build (Fifth edition December 2008) 9
Page 1 and 2: PUBLIC SECTORSTANDARD CONDITIONS OF
Page 3 and 4: CONTENTSPage1 Definitions and Inter
Page 5 and 6: Page11 Administration11.1 Days and
Page 7 and 8: Page24 Construction Equipment, Temp
Page 9 and 10: PUBLIC SECTORSTANDARD CONDITIONS OF
Page 11 and 12: (iii)(u)(v)(w)(x)(y)(z)(aa)(ab)(ac)
Page 13 and 14: the same effect as though it had be
Page 15: 3.3 Drawings to be Kept on SiteOne
Page 19 and 20: 4.5 Sufficiency of Tender(1) The Co
Page 21 and 22: 6 WORKS DESIGNED BY THE CONTRACTOR6
Page 23 and 24: 7.3 Cost of ComplianceThe Contracto
Page 25 and 26: 10 QUALITY IN CONSTRUCTION10.1 Plan
Page 27 and 28: (c)To remove from the Site any Plan
Page 30: subject to Clause 14, may grant the
Page 33 and 34: Superintending Officer at the time
Page 35 and 36: Provided that the Superintending Of
Page 37 and 38: 18.4 Contractor to SearchIf any Def
Page 39 and 40: 20.2 Agreement on Valuation(1) The
Page 41 and 42: 21 MEASUREMENT21.1 Contractor to At
Page 43 and 44: (2) The fact that the Contractor do
Page 45 and 46: 24.3 Employer not Liable for Damage
Page 47 and 48: 26 INDEMNITY PROVISIONS26.1 Injury
Page 50 and 51: Employer's interest is endorsed the
Page 52 and 53: (e)(f)has acted in breach of Clause
Page 54 and 55: 31.3 Liquidated Damages after Termi
Page 56 and 57: 32.2 Payment Certificates(1) Within
Page 58 and 59: (3) The Superintending Officer shal
Page 60 and 61: (5) If any dispute, difference or q
Page 62 and 63: 35.2 Reference to ArbitrationIf eit
Page 64 and 65: (3) Except as provided in Clause 37
Page 66:
OPTION MODULE AUNUSED MATERIALS OR
show all

public sector standard conditions of contract for design and build 2008

You also want an ePaper? Increase the reach of your titles

Delete template?

Save as template?