Information Doc RFPWTE - Petroleum Corporation Of Jamaica

More documents

Recommendations

Info

Insurance, Workmen's Compensation Insurance, Comprehensive Third Party Liability Insurance, Comprehensive Automobile Liability Insurance, Excess Umbrella Liability Insurance, Government Approvals The Project Company shall be solely responsible for securing all requisite approvals such as planning, environmental, developmental, etc from the relevant Government and statutory organizations. Principles of Engineering Procurement & Construction Agreement The Project Company shall enter into Engineering Procurement & Construction (EPC) Agreement with a reputable construction contractor to complete the design and construction of the Project at a fixed price, in accordance with the Project Milestone Schedule and to the specifications agreed in the PPA Information for WTE RFP PCJ’s Centre of Excellence for Renewable Energy Page 37 of 56
The following are some of the terms and conditions that shall be included in the Construction Contract The Contractor to abide by all applicable laws in Jamaica. The Contract shall reflect the applicable provisions from the Project Agreements for which the Company is responsible. The Contract shall contain Plant performance guarantees by the Contractor. If construction is completed but the Plant fails to meet performance guarantees, the Contractor will be required to pay damages in an amount sufficient to cover at a minimum the liquidated damages that will be assessed under the PP A. The Contractor will undertake to complete the Project in accordance with an agreed schedule consistent with the Project Milestone Schedule. In the event of failure to complete construction by the scheduled date, the Contractor will be required to pay damages in an amount at a minimum sufficient to cover the liquidated damages that will be assessed under the PPA. The performance of the Contractor shall be assured by a Performance Bond. The amount of the Performance Bond should not be less than 10% of the total contract price. The Performance Bond shall cover the warranty period for the facilities. If the Contractor were to abandon construction or to fail to pursue construction with due diligence, the Project Company would have the right to replace the Contractor and require the Contractor to pay any additional costs resulting from its default. The Contractor shall provide an unlimited completion guarantee for the Project facilities which is assignable without the Contractor's consent to JPS. Information for WTE RFP PCJ’s Centre of Excellence for Renewable Energy Page 38 of 56
Page 1 and 2: INFORMATION in support of REQUEST F
Page 3 and 4: TABLE OF CONTENTS Page Disclaimer 1
Page 5 and 6: LIST OF ACRONYMS & ABBREVIATIONS $
Page 7 and 8: 1.2 Jamaica’s Energy Sector Polic
Page 9 and 10: 1.3 Jamaica’s Electricity Sector
Page 11 and 12: Waste Characterization 1990 Norcons
Page 13 and 14: Table 3. National Solid Waste Manag
Page 15 and 16: Staff The staff complement at the m
Page 17 and 18: Waste Intake Table 5.1 Waste Intake
Page 19 and 20: RIVERTON Geology and Hydro-Geology
Page 21 and 22: WPM Region - Retirement Disposal Si
Page 23 and 24: NEPM Region - Hadden, Tobolski and
Page 25 and 26: Accessibility of Water & Electricit
Page 27 and 28: The NSWMA will provide :- land for
Page 29 and 30: 1.9 Procurement Process The Request
Page 31 and 32: 1.11 Key Stakeholders Petroleum Cor
Page 33 and 34: Ministry of Energy The mission of t
Page 35 and 36: Jamaica Trade & Invest (JAMPRO) Jam
Page 37: 1. The Fixed Payment will be based
Page 41 and 42: FINANCING STRUCTURE The Project Com
Page 43 and 44: estimated quantities of Acceptable
Page 45 and 46: them (the "Indemnified Persons") fr
Page 47 and 48: Agreement shall survive expiration
Page 49 and 50: No provision of this Agreement shal
Page 51 and 52: 3. will not conflict with, constitu
Page 53 and 54: the satisfaction of all conditions
Page 55 and 56: judgment, order or consent decree w

Information Doc RFPWTE - Petroleum Corporation Of Jamaica

You also want an ePaper? Increase the reach of your titles

Delete template?

Save as template?