ESTIMATED COST RS.31.50 LAKH (RUPEES THIRTY-ONE ... - IDCO

More documents

Recommendations

Info

20 6. The Contractor shall make good any defects, shrinkage or other faults that may appear in the works within six months after their completion. 7. In-case the Contractor shall commit the break of any covenants herein contained the Corporation shall be at liberty to terminate this Agreement giving 15 days notice. 8. The Contractor shall indemnify to the Corporation from all claims for injury, death, caused to any person under workmen Compensation Act. 1938. Besides the contractor shall comply all the provisions of prevailing Labour laws during execution of work. 9. Both the parties agree by mutual consent that any dispute relating to this Agreement is barred from Arbitration. All problems shall be mutually settled and the decision of <strong>IDCO</strong> shall be final and binding on the contractor. 10. In the event of any dispute that may arise out of this assessment the competent Courts situated at Bhubaneswar shall have the jurisdiction to decide such disputes / litigations between parties hereto. IN WITNESS WHERE OF the parties have caused their respective common seals to be herein to affixed (or have here into set their respective hands & seals) the day and year first written above. Witness : 1. Signature of the Party of the one part 2. Witness : 1. Signature of the Party of the other part 2.
21 SPECIAL CONDITIONS. 1. Notwithstanding any other condition in DTCN; Corporation will normally supply no water. The Contractor is to arrange water for the work at his own cost The Contractor will lay the pipe line net work required for the construction purpose at his own cost No delay in construction is permissible on the ground of paucity of water. If the water is availed from the Corporation source, water charges will be levied as per the cost of purchase and the amount will be recovered from Contractor bill. Service roads are to be constructed by contractor at his own cost. 2. No time extension will be granted on the ground of scarcity of water, communication, material and machinery etc. 3. The responsibility to locate Govt. approved quarry and borrow area lies with the Contractor. 4. Wherever levels are to be taken, it will be the responsibility of Contractor to get the same done through concerned Junior Engineer and checked by the Deputy Manager (Civil). The instrument is to be arranged by the contractor. 5. The Contractor will submit a detailed programme of completion of work with methodology for execution of each item of work at the time of execution of agreement preferably in PERT chart. 6. All machineries will be arranged by the Contractor at his own cost in proper time. 7. The Contractor is to abide by the Contract Labour Act and E.P.F. & ESI Act as the sole employer of the labour staff. The Contractor is to maintain the wage register and deposit the provident fund dues of all labourers and workers, In case the Contractor fails to deposit the provident fund dues of the Labourers/workers. 10% of each running bill of the Contractor will be kept withheld which can only be released after getting clearance from the Area Enforcement Officer of the Office of the R.P.F.C., Orissa. The Contractor is required to register his name and get individual code numbers from the office of the R.P.F.C.,Orissa, Bhubaneswar 8. For any bad quality of work the amount of award given by any consumer court/judicial court will be recovered from the executing Contractor. 9. No extra quantity beyond the agreement quantity should be executed without the prior written approval of competent authority of <strong>IDCO</strong>. 10. Wherever the agreement rates are less than 2(two)% or more the differential amount between agreement cost and estimated cost shall be deposited by the contractor along with ISD which will be released only after successful completion of the work. 11. For any additional quantities up to 25% on any item, the contractor will be paid at the approved tender rate.
Page 1 and 2: 1 BID DOCUMENT FOR THE WORK DESIGN,
Page 3 and 4: ORISSA INDUSTRIAL INFRASTRUCTURE DE
Page 5 and 6: 5 Orissa Industrial Infrastructure
Page 7 and 8: 7 TENDER CALL NOTICE No.IDCO/WS &EC
Page 9 and 10: 9 Date.___________________________
Page 11 and 12: 11 6. I/We understands that you are
Page 13 and 14: 13 EARNEST MONEY DEPOSIT Ref. No.__
Page 15 and 16: 15 SECURITY DEPOSIT BANK GUARANTEE
Page 17 and 18: 17 PERFORMANCE GUARANTEE FORMAT PRO
Page 19: 19 A G R E E M E N T The Agreement
Page 23 and 24: 23 GENERAL INFORMATION 1. SCOPE OF
Page 25 and 26: 25 7. TENDER PRICES 7.1 The contrac
Page 27 and 28: 27 copy of registration document. T
Page 29 and 30: 29 or part thereof of delay subject
Page 31 and 32: 31 Chairman-Cum-Managing Director o
Page 33 and 34: 33 extension of time if any, as may
Page 35 and 36: 35 within one month from the date o
Page 37 and 38: 37 Contractor shall on demand in wr
Page 39 and 40: 39 contract and the security deposi
Page 41 and 42: 41 original , altered or substitute
Page 43 and 44: 43 (i) (ii) (iii) When there is dif
Page 45 and 46: 45 PREAMBLE TO THE SCHEDULE OF QUAN
Page 47 and 48: 47 14. All the fittings of external
Page 49 and 50: 49 5. Any person who submits a tend
Page 51 and 52: 51 organization chart, details of k
Page 53 and 54: 53 (b) (c) (d) (e) No wage period s
Page 55 and 56: 55 of these regulations. He shall i
Page 57 and 58: 57 4. WATER AND POWER SUPPLY: IDCO
Page 59 and 60: 59 SPECIAL TERMS & CONDITIONS FOR S
Page 61 and 62: 61 beyond a given speed limit so as
Page 63 and 64: 63 5. The Contractor shall provide
Page 65 and 66: 65 10. It is the Contractor’s res
Page 67 and 68: 67 26. The tenderer shall have to a
Page 69 and 70: 69 Corporation’s property and wil
Page 71 and 72:
71 TECHNICAL SPECIFICATION 1. Any l
Page 73 and 74:
73 TECHNICAL SPEFICATION FOR ELEVAT
Page 75 and 76:
75 2.8.6.a All G.I. pipes shall be
Page 77 and 78:
77 1.0 Site Clearance : TECHNICAL I
Page 79 and 80:
79 5.4.8 All the members of the res
Page 81 and 82:
81 Sl.No. Description of the item (
Page 83 and 84:
ANNEXURE-III Declaration of Tendere
Page 85 and 86:
ANNEXURE-V 85 (To be filled by the
Page 87 and 88:
87 ANNEXURE-VII BASIC INFORMATION O
show all

ESTIMATED COST RS.31.50 LAKH (RUPEES THIRTY-ONE ... - IDCO

You also want an ePaper? Increase the reach of your titles

Delete template?

Save as template?