Bid Document for Hawkers Rehab Centre in Digha.pdf - Integrated ...

More documents

Recommendations

Info

Conditions of ContractA. General1. Definitions1.1 Terms which are defined in the Contract Data are not also defined in the Conditions of Contract but keeptheir defined meanings. Capital initials are used to identify defined terms.The Adjudicator is the person appointed jointly by the Employer and the Contractor to resolve disputesin the first instance, as provided for in Clauses 24 and 25. The name of the Adjudicator is defined in theContract Data.Bill of Quantities means the priced and completed Bill of Quantities forming part of the Bid.Compensation Events are those defined in Clause 44 hereunder.The Completion Date is the date of completion of the Works as certified by the Engineer in accordancewith Sub Clause 55.1.The Contract is the contract between the Employer and the Contractor to execute, complete andmaintain the Works. It consists of the documents listed in Clause 2.3 below.The Contract Data defines the documents and other information which comprise the Contract.The Contractor is a person or corporate body whose Bid to carry out the Works has been accepted bythe Employer.The Contractor's Bid is the completed Bidding document submitted by the Contractor to the Employer.The Contract Price is the price stated in the Letter of Acceptance and thereafter as adjusted inaccordance with the provisions of the Contract..Days are calendar days; months are calendar months.A Defect is any part of the Works not completed in accordance with the Contract.The Defects Liability Period is the period named in the Contract Data and calculated from theCompletion Date.The Employer is the party who will employ the Contractor to carry out the Works.The Engineer is the person named in the Contract Data (or any other competent person appointed andnotified to the contractor to act in replacement of the Engineer) who is responsible for supervising theexecution of the works and administering the Contract.Equipment is the Contractor's machinery and vehicles brought temporarily to the Site to construct theWorks.The Initial Contract Price is the Contract Price listed in the Employer's Letter of Acceptance36
The Intended Completion Date is the date on which it is intended that the Contractor shall complete theWorks. The Intended Completion Date is specified in the Contract Data. The Intended Completion Datemay be revised only by the Engineer by issuing an extension of time.Materials are all supplies, including consumables, used by the contractor for incorporation in theWorks.Plant is any integral part of the Works which is to have a mechanical, electrical, electronic or chemicalor biological function.The Site is the area defined as such in the Contract Data.Site Investigation Reports are those which were included in the Bidding documents and are factualinterpretative reports about the surface and sub-surface conditions at the site.Specification means the Specification of the Works included in the Contract and any modification oraddition made or approved by the Engineer.The Start Date is given in the Contract Data. It is the date when the Contractor shall commenceexecution of the works. It does not necessarily coincide with any of the Site Possession Dates.A Subcontractor is a person or corporate body who has a Contract with the Contractor to carry out apart of the work in the Contract which includes work on the Site.Temporary Works are works designed, constructed, installed, and removed by the Contractor which areneeded for construction or installation of the Works.A Variation is an instruction given by the Engineer which varies the Works.The Works are what the Contract requires the Contractor to construct, install, and turn over to theEmployer, as defined in the Contract Data.2. Interpretation2.1 In interpreting these Conditions of Contract, singular also means plural, male also means female orneuter, and the other way around. Headings have no significance. Words have their normal meaningunder the language of the Contract unless specifically defined. The Engineer will provide instructionsclarifying queries about the Conditions of Contract.2.2 If sectional completion is specified in the Contract Data, references in the Conditions of Contract to theWorks, the Completion Date, and the Intended Completion Date apply to any Section of the Works(other than references to the Completion Date and Intended Completion date for the whole of theWorks).2.3 The documents forming the Contract shall be interpreted in the following order of priority:(1) Agreement(2) Letter of Acceptance, notice to proceed with the works(3) Contractor’s Bid(4) Contract Data37
Page 2 and 3: INVITATION FOR BID(IFB)2
Page 4 and 5: TABLE______________________________
Page 6: Section 1: Instructions to BiddersT
Page 9 and 10: (d)(e)The contractor or his identif
Page 11 and 12: B. Bidding Documents8. Content of B
Page 13 and 14: 15.2 In exceptional circumstances,
Page 15 and 16: 20.2 The Employer may extend the de
Page 17 and 18: 29.1 The Employer will evaluate and
Page 19 and 20: 37.1 It is the Bank’s policy to r
Page 21 and 22: SECTION 2:FORMS OF BID, QUALIFICATI
Page 23 and 24: We hereby confirm that this Bid com
Page 25 and 26: ** immediately preceding the financ
Page 27 and 28: 1.12 Statement of compliance under
Page 29 and 30: Letter of Acceptance(letterhead pap
Page 31 and 32: Issue of Notice to proceed with the
Page 33 and 34: In witness whereof the parties ther
Page 35: Conditions of ContractTable of Cont
Page 39 and 40: 10. Employer’s and Contractor's R
Page 41 and 42: 24. DisputesThe Contractor’s atte
Page 43 and 44: 34.1 If the Engineer-in-charge r in
Page 45 and 46: 44. Compensation Events44.1 The fol
Page 47 and 48: 51.1 The Employer shall make advanc
Page 49 and 50: 60. Payment upon Termination60.1 If
Page 51 and 52: F. Special Conditions of Contract1.
Page 53 and 54: measures, such as Canteens, First-A
Page 55 and 56: discharge of any sewage or trade ef
Page 57 and 58: S.No.ActivityMeasures to be Impleme
Page 59 and 60: SECTION 4: CONTRACT DATA59
Page 61 and 62: ___________________________________
Page 63 and 64: Nature of Advance Amount (Rs.) Cond
Page 65 and 66: SECTION 5: SPECIFICATIONS65
Page 67 and 68: The contractor shall take adequate
Page 69 and 70: 40 IS-814: 1991 Electrodes for manu
Page 71 and 72: 123 IS-1868: 1983 Code of practice
Page 73 and 74: specification. The damp proof cours
Page 75 and 76: The water cement ratio is to be det
Page 77 and 78: 9.1 Frequency of sampling:9.1.1 Sam
Page 79 and 80: to maintain thinner plaster layer.
Page 81 and 82: materials. Filling with sand should
Page 83 and 84: 7.5 R.C.C. NP3 pipe:All R.C.C. NP3
Page 87 and 88:
At points where the contour of the
Page 89:
Jointing of D.I. specials with the
Page 93 and 94:
SECTION 7: BILL OF QUANTITIES93
Page 95 and 96:
Chlorophyrofos emulsifiable concent
Page 97 and 98:
contact surface of the frame exclud
Page 99 and 100:
thick sand & cement plaster (1:4) a
Page 101:
) 20 mm dia medium duty Mtrs 40c) 2
Page 105 and 106:
necessary fittings and jointing mat
Page 107 and 108:
RATESL.NO.DESCRIPTION UNIT IN FIGUR
Page 109 and 110:
position and binding with 16 gauge
Page 111 and 112:
222324F25262728293031Anodised alumi
Page 113 and 114:
Supplying & Fixing sheet metal insp
Page 115 and 116:
23 Schedule of rates for installati
Page 117 and 118:
mm. including watering and ramming
Page 119 and 120:
(1:4) cement plaster to inside wall
Page 121 and 122:
Supplying and testing of following
Page 123 and 124:
mm including watering and ramming e
Page 125 and 126:
12 125 mm thick brick work with 1st
Page 127 and 128:
2425G262728Anodised aluminium tower
Page 129 and 130:
89Supplying , fitting & fixing 25mm
Page 131 and 132:
252627E28fixing in position and pai
Page 133 and 134:
On Board Point 568Fixing only fan r
Page 135 and 136:
end of 7/10 SWG GI (Hot Dip) strand
Page 137 and 138:
4142with all necessary accessories
Page 139 and 140:
d) Above 1st Roof Sqm 249.5310Reinf
Page 141 and 142:
232425G262728arrangement both insid
Page 143 and 144:
dia. approved quality PVC waste pip
Page 145 and 146:
75 mm dia each 5.00v) Door Bend (T.
Page 147 and 148:
) Average run 8 mtr Point 60Distn.
Page 149 and 150:
equipments with bolts, nuts, washer
Page 151 and 152:
500W with 300W Halgen )39 Supply of
Page 153 and 154:
filling the space between the brick
Page 155 and 156:
18Supply and installation of local
Page 157 and 158:
slope and jointing with stiff mixtu
Page 159 and 160:
23456(Trench shall be kept dry by d
Page 161 and 162:
5.1 For 2 coreupto 4 sqmm Each 4.00
Page 163 and 164:
34H123if needed (the good earth sha
Page 165 and 166:
245Depth of foundation upto 1500mmE
Page 167 and 168:
direction of the Engineer In Charge
Page 169 and 170:
clearance of 6 mm from wall includi
Page 171 and 172:
Eucalyptus / Jhou bulla pilling shu
Page 173 and 174:
polymerised adhesive (6mm thick lay
Page 175 and 176:
32333435H36coatsSolvent based inter
Page 177 and 178:
a) 300 mm long Each 5b) 450 mm long
Page 179 and 180:
2930E31(A) Above ground(i) 75 mm di
Page 181 and 182:
a)Laying of one no. cable upto 35 s
Page 183 and 184:
28Supplying & Fixing bulkhead light
Page 185 and 186:
c) 1st Floor Cum 3.14d) 2nd Floor C
Page 187 and 188:
181920finish anodised (15 - 18 micr
Page 189 and 190:
cutting pipes, making threads, fitt
Page 191 and 192:
35.56 cm with locking arrangement,
Page 193 and 194:
SL.IN WORDDESCRIPTION UNIT IN FIGUR
Page 195 and 196:
D LANDSCAPING AND PATHWAYS1Earth wo
Page 197 and 198:
all respect with all costs of labou
Page 199 and 200:
15 Supplying and fixing single pole
Page 201 and 202:
5678I123pipes with minimum thicknes
Page 203 and 204:
cement with Super plasticiser per c
Page 205 and 206:
242526quality including smoothening
Page 207 and 208:
CP Pillar cock - 15 mm.13Supplying,
Page 209 and 210:
27work, if necessary, but including
Page 211 and 212:
Schedule of Quantities for Electric
Page 213 and 214:
213
Page 215 and 216:
ANEXURE-DSECTION 8: FORMS OF SECURI
Page 217 and 218:
Annex ABID SECURITY (BANK GUARANTEE
Page 219 and 220:
PERFORMANCE BANK GUARANTEE (for unb
Page 221:
221
show all

Bid Document for Hawkers Rehab Centre in Digha.pdf - Integrated ...

Create successful ePaper yourself

Delete template?

Save as template?