General Index - National Roofing Contractors Association

17. Ineligible structure or building use Single-family residence, patio, plaza deck, roofs outside of U.S. andCanada.Single-family residence, patio, plaza deck, roofs outside of U.S. andCanadaSingle-family residence, patio, plaza deck, roofs outsideof U.S. and Canada18. Pre-construction notice andapproval requirements19. Approved, authorized, or licensedrequirementsNone required. Preinstallation notice must be submitted 14 days prior to job start. Preinstallation notice must be submitted 14 days prior tojob start and must be approved by Firestone technicalservice.No Yes Yes20. Job inspection policy No on-site inspections No on-site inspections Firestone field technical representative makes on-site inspectionafter job completion prior to issuance of warranty; no charge.21. Contractor’s post-installationobligationNone required.Contractor obligated to make repairs to workmanship deficiencies fortwo years.Contractor is obligated to make repairs to workmanshipdeficiencies for two years.22. Backed by named insurance orsurety23. Issuing entity manufactures and/orsells products24. Conditions for renewal orextensionNo; Firestone indicates that it is self-insured. No; Firestone indicates that it is self-insured. No; Firestone indicates that it is self-insured.Firestone manufactures and sells the product. Firestone manufactures and sells the product. Firestone manufactures and sells the product.No renewal provision No renewal provision No renewal provision25. Assignability Warranty is transferable subject to Firestone inspection, written approval,and payment of current transfer fee.26. Special features/conditions If Firestone's investigation reveals that the cause of a leak isoutside the scope of the warranty, investigation costs shall be paidby purchaser; failure of purchaser to pay these costs shall renderthe warranty null and void. Any dispute, controversy, or claimbetween the purchaser and Firestone concerning warranty shall besettled by final and binding arbitration in accordance with theAmerican Arbitration Association's rules for the constructionindustry. Warranty shall be governed and construed in accordancewith the laws of the state of Ind. without regard to conflict of laws.Firestone does not undertake any analysis of the architecture orengineering required to evaluate what type of roof system isappropriate. Warranty cannot be amended, altered, or modified inany way except in writing signed by the president of Firestone or aperson to whom his authority has been delegated in writing.Warranty requires purchaser compliance with Firestone roofingcare and maintenance requirements stated on reverse side ofwarranty document, including at least twice yearly inspections;ponding water not be allowed; drain areas remain clear; noexposure to acids, solvents, greases, oil, fats, chemicals, and thelike; protective walkways for roof traffic; maintenance of counterflashings, metal work, drains, skylights, equipment curbs andsupports, other rooftop accessories, and roof coatings andsealants.In the event the roof access is limited due to security or otherrestrictions, purchaser shall reimburse Firestone for all reasonablecosts incurred during inspection and/or repair of the system whichare due to delays associated with said restrictions. Purchaser shallbe responsible for the removal and replacement of anyoverburdens, superstrata or overlays, either permanent ortemporary, as necessary to expose the surface of the membrane forinspection and/or repair.Warranty is transferable subject to Firestone inspection, written approval, and payment ofcurrent transfer fee.If Firestone's investigation reveals that the cause of a leak is outside the scope ofthe warranty, investigation costs shall be paid by owner; failure of owner to paythese costs shall render the warranty null and void. Any dispute, controversy, orclaim between the owner and Firestone concerning warranty shall be settled byfinal and binding arbitration in accordance with the American ArbitrationAssociation's rules for the construction industry. Warranty shall be governed andconstrued in accordance with the laws of the state of Indiana without regard toconflict of laws.Firestone does not undertake any analysis of the architecture or engineeringrequired to evaluate what type of roof system is appropriate. Warranty cannot beamended, altered, or modified in any way except in writing signed by the presidentof Firestone or a person to whom his authority has been delegated in writing.Warranty requires owner compliance with Fire stone roofing care andmaintenance requirements stated on reverse side of warranty document, includingat least twice yearly inspections; ponding water not be allowed; drain areas remainclear; no exposure to acids, solvents, greases, oil, fats, chemicals and the like;protective walkways for roof traffic; maintenance of counter flashings, metal work,drains, skylights, equipment curbs and supports, other rooftop accessories, androof coatings and sealants.In the event the roof access is limited due to security or other restrictions, theowner shall reimburse Firestone for all reasonable costs incurred during inspectionand/or repair of the system which are due to delays associated with saidrestrictions. The owner shall be responsible for the removal and replacement ofany overburdens, superstrata or overlays, either permanent or temporary, asnecessary to expose the system for inspection and/or repair.Warranty is transferable subject to Firestone inspection, written approval,and payment of current transfer fee.If Firestone's investigation reveals that the cause of a leak is excludedunder the warranty, investigation costs shall be paid by owner; failure ofowner to pay these costs shall render the warranty null and void. Anydispute, controversy or claim between the owner and Firestoneconcerning warranty shall be settled by final and binding arbitration inaccordance with the American Arbitration Association's rules for theconstruction industry. Warranty shall be governed and construed inaccordance with the laws of the state of Indiana without regard to conflictof laws.Firestone does not undertake any analysis of the architecture orengineering required to evaluate what type of roof system is appropriate.Warranty cannot be amended, altered, or modified in any way except inwriting signed by the president of Firestone or a person to whom hisauthority has been delegated in writing.Warranty requires owners compliance with Firestone roofing careand maintenance requirements stated on reverse side of warrantydocument, including at least twice yearly inspections; ponding water notbe allowed; drain areas remain clear; no exposure to acids, solvents,greases, oil, fats, chemicals, and the like; protective walkways for rooftraffic; maintenance of counter flashings, metal work, drains, skylights,equipment curbs and supports, other rooftop accessories, and roofcoatings and sealants.In the event the roof access is limited due to security or otherrestrictions, the owner shall reimburse Firestone for all reasonable costsincurred during inspection and/or repair of the system which are due todelays associated with said restrictions. The owner shall be responsiblefor the removal and replacement of any overburdens, superstrata oroverlays, either permanent or temporary, as necessary to expose thesystem for inspection and/or repair.27. Executed by owner No No No603