Bid #01-1112 Library and Reprographics Roofing ... - Citrus College

approval of a Construction Schedule shall be for the sole and limited purpose of determining conformity
with the requirements of the Contract Documents. By the Approved Construction Schedule, the District
shall not be deemed to have exercised control over, or approval of, construction means, methods or
sequences, all of which remain the responsibility and obligation of the Contractor in accordance with the
terms of the Contract Documents. Further, the Approved Construction Schedule shall not operate to limit
or restrict any of Contractor's obligations under the Contract Documents nor relieve the Contractor from the
full, faithful and timely performance of such obligations in accordance with the terms of the Contract
Documents. The activities, commencement and completion dates of activities, and the sequencing of
activities depicted on the Approved Construction Schedule shall not be modified or revised by the
Contractor without the prior consent, or direction, of the District. Updates to the Approved Construction
Schedule pursuant to Article 7.3.5 below shall not be deemed revisions to the Approved Construction
Schedule. In the event that the Approved Construction Schedule shall depict completion of the Work in a
duration shorter than the Contract Time, the same shall not be a basis for an adjustment of the Contract
Time or the Contract Price in the event that actual completion of the Work shall occur after such the time
depicted in such Approved Construction Schedule. In such event, the Contract Price shall not be subject to
adjustment on account of any additional costs incurred by the Contractor to complete the Work prior to the
Contract Time, as adjusted in accordance with the terms of the Contract Documents. Any adjustment of
the Contract Time or the Contract Price shall be based upon the Contract Time set forth in the Contract
Documents and not any shorter duration which may depicted in the Approved Construction Schedule.
7.3.4 Revisions to Approved Construction Schedule. In the event that the progress of the
Work or the sequencing of the activities of the Work shall materially differ from that indicated in the
Approved Construction Schedule, as determined by the District in its reasonable discretion and judgment,
the District may direct the Contractor to revise the Approved Construction Schedule; within fifteen (15) days
of the District's direction, the Contractor shall prepare and submit a revised Approved Construction
Schedule, for review and approval by the District. The Contractor may request consent of the District to
revise the Approved Construction Schedule. Any such request shall be considered by the District only if in
writing setting forth the Contractor's proposed revision(s) to the Approved Construction Schedule and the
reason(s) therefore. The District may consent to, or deny, any such request of the Contractor to revise the
Approved Construction Schedule in its reasonable discretion.
7.3.5 Updates to Approved Construction Schedule. The Contractor shall monitor and update
the Approved Construction Schedule on a monthly basis, or more frequently as required by the conditions
or progress of the Work, or as may be requested by the District. Proper and complete updating of the
Approved Construction Schedule shall be a condition precedent to the issuance of progress payments
described in Article 8 of these General Conditions. The Contractor shall provide the District with updated
Approved Construction Schedules indicating progress achieved and activities commenced or completed
within the prior updated Approved Construction Schedule. Updates to the Approved Construction Schedule
shall not include any revisions to the activities, commencement and completion dates of activities or the
sequencing of activities depicted on the Approved Construction Schedule. Any such revisions to the
Approved Construction Schedule shall result in the District's rejection of such update and Contractor shall,
within seven (7) days of the District's rejection of such update, submit to the Architect and the Project
Manager an Updated Approved Construction Schedule which does not incorporate any such revisions. If
requested by the District, the Contractor shall also submit, with its updates to the Approved Construction
Schedule, a narrative statement including a description of current and anticipated problem areas of the
Work, delaying factors and their impact, and an explanation of corrective action taken or proposed by the
Contractor. If the progress of the Work is behind the Approved Construction Schedule, the Contractor shall
indicate what measures will be taken to place the Work back on schedule. The District may, from time to
time, and in the District's sole and exclusive discretion, transmit to the Contractor's Performance Bond
Surety the Approved Construction Schedule, any updates thereof and the narrative statement described
Citrus Community College District Bid Due Date: November 15, 2011 at 3:00: p.m.
Bid #01-1112 Library and Reprographics Roofing Project Page 68 of 96