Hiring of VPN Services for GAIL Agartala

More documents

Recommendations

Info

CERTIFICATE during which the CONTRACTOR stands responsible for rectifying all defects that may appear in the works executed by the CONTRACTOR in pursuance of the CONTRACT and includes warranties against Manufacturing/ Fabrication/ Erection/Construction defects covering all materials plants, equipment, components, and the like supplied by the CONTRACTOR, works executed against workmanship defects. 1.1.18 The "APPOINTING AUTHORITY" for the purpose of arbitration shall be the CHAIRMAN and MANAGING DIRECTOR or any other person so designated by the EMPLOYER. 1.1.19 "TEMPORARY WORKS" shall mean all temporary works of every kind required in or about the execution, completion or maintenance of works. 1.1.20 "PLANS" shall mean all maps, sketches and layouts as are incorporated in the CONTRACT in order to define broadly the scope and specifications of the work or works, and all reproductions thereof. 1.1.21 "SITE" shall mean the lands and other places on, under, in or through which the permanent works are to be carried out and any other lands or places provided by the EMPLOYER for the purpose of the CONTRACT. 1.1.22 "NOTICE IN WRITING OR WRITTEN NOTICE" shall mean a notice in written, typed or printed characters sent (unless delivered personally or otherwise proved to have been received by the addressee) by registered post to the latest known private or business address or registered office of the addressee and shall be deemed to have been received in the ordinary course of post it would have been delivered. 1.1.23 "APPROVED" shall mean approved in writing including subsequent written confirmation of previous verbal approval and "APPROVAL" means approval in writing including as aforesaid. 1.1.24 "LETTER OF INTENT/FAX OF INTENT” shall mean an intimation by a Fax/Letter/E-mail to Tenderer(s) that the tender has been accepted in accordance with the provisions contained in the letter. 1.1.25 "DAY" means a day of 24 hours from midnight to midnight irrespective of the number of hours worked in that day. 1.1.26 "WORKING DAY" means any day which is not declared to be holiday or rest day by the EMPLOYER. 1.1.27 "WEEK" means a period of any consecutive seven days. 44
1.1.28 "METRIC SYSTEM" - All technical documents regarding the construction of works are given in the metric system and all work in the project should be carried out according to the metric system. All documents concerning the work shall also be maintained in the metric system. 1.1.29 "VALUE OF CONTRACT” or “TOTAL CONTRACT PRICE” shall mean the sum accepted or the sum calculated in accordance with the prices accepted in tender and/or the CONTRACT rates as payable to the CONTRACTOR for the entire execution and full completion of the work, including change order. 1.1.30 "LANGUAGE FOR DRAWINGS AND INSTRUCTION" All the drawings, titles, notes, instruction, dimensions, etc. shall be in English Language. 1.1.31 "MOBILIZATION" shall mean establishment of sufficiently adequate infrastructure by the CONTRACTOR at "SITE" comprising of construction equipments, aids, tools tackles including setting of site offices with facilities such as power, water, communication etc. establishing manpower organisation comprising of Resident Engineers, Supervising personnel and an adequate strength of skilled, semi-skilled and un-skilled workers, who with the so established infrastructure shall be in a position to commence execution of work at site(s), in accordance with the agreed Time Schedule of Completion of Work. "MOBILISATION" shall be considered to have been achieved, if the CONTRACTOR is able to establish infrastructure as per Time Schedule, where so warranted in accordance with agreed schedule of work implementation to the satisfaction of ENGINEER-IN-CHARGE/ EMPLOYER. 1.1.32 "COMMISSIONING" shall mean pressing into service of the system including the plant(s), equipment(s), vessel(s), pipeline, machinery(ies), or any other section or sub-section of installation(s) pertaining to the work of the CONTRACTOR after successful testing and trial runs of the same. • "COMMISSIONING" can be either for a completed system or a part of system of a combination of systems or sub-systems and can be performed in any sequence as desired by EMPLOYER and in a manner established to be made suited according to availability of pre-requisites. Any such readjustments made by EMPLOYER in performance of "COMMISSIONING" activity will not be construed to be violating CONTRACT provisions and CONTRACTOR shall be deemed to have provided for the same. 45
Page 1 and 2: GAIL (India) Limited 16, Bhikaji Ca
Page 3 and 4: TENDER NO.: GAIL/ND/C&P-MKTG/GT/14/
Page 43: Company (other than the CONTRACTOR)
Page 47 and 48: than 500 m away from the CONTRACTOR
Page 49 and 50: CONTRACTOR shall fail to comply wit
Page 51 and 52: audited. x) Details of present comm
Page 53 and 54: 5. Transfer of Tender Documents: of
Page 55 and 56: 11 Tenderer’s Responsibility; 12
Page 57 and 58: Tenderer is in doubt about the comp
Page 59 and 60: 23 Contractor to obtain his own Inf
Page 61 and 62: Guarantee or through an irrevocable
Page 63 and 64: obligation of the party affected by
Page 65 and 66: a) TO DETERMINE THE CONTRACT in whi
Page 67 and 68: may give notice in writing to the C
Page 69 and 70: 36. Contractor's subordinate staff
Page 71 and 72: Notwithstanding any sub-letting wit
Page 73 and 74: 39. Contractor's responsibility wit
Page 75 and 76: EMPLOYER as a result such failure w
Page 77 and 78: 46. Payment if the contract is term
Page 79 and 80: advertising, publicity, sales relea
Page 81 and 82: 60. Alterations in specifications,
Page 83 and 84: 83 10% (ten percent) to cover all c
Page 85 and 86: ENGINEER-IN-CHARGE. "Certified true
Page 87 and 88: 66. Stores supplied by the employer
Page 89 and 90: 68. Material procured with assistan
Page 91 and 92: 73. Inspection of works: 73.1 The E
Page 93 and 94: 77. Suspension of works: 78. Employ
Page 95 and 96:
95 defective or not in accordance w
Page 97 and 98:
such time as may be reasonably nece
Page 99 and 100:
ENGINEER-IN-CHARGE as to the items
Page 101 and 102:
88.1.1 All measurements shall be re
Page 103 and 104:
such claim and no delay in dealing
Page 105 and 106:
CONTRACTOR after verifying from the
Page 107 and 108:
SECTION-VII Taxes and Insurance 98.
Page 109 and 110:
the insurance coverage risk and in
Page 111 and 112:
111 the Employership of such vehicl
Page 113 and 114:
113 the EMPLOYER harmless of all cl
Page 115 and 116:
104 Implementation of apprentices a
Page 117 and 118:
and binding as provided in the Agre
Page 119 and 120:
111 First aid and industrial injuri
Page 121 and 122:
115 Excavation and trenching: 116 D
Page 123 and 124:
iii) When the work is done near any
Page 125 and 126:
117 Care in handling inflammable ga
Page 127 and 128:
Section-6 Schedule of Rates 127
Page 129 and 130:
Section - 7 Forms & Formats 129
Page 131 and 132:
To M/S. GAIL(India) LTD. 16, Bhikai
Page 133 and 134:
Annual Turnover data for the last 3
Page 135 and 136:
F-4 PROFORMA FOR BANK GUARANTEE FOR
Page 137 and 138:
F-5 LETTER OF AUTHORITY PROFORMA FO
Page 139 and 140:
M/S. GAIL(India) LTD. 16, Bhikaiji
Page 141 and 142:
Full Postal Address and phone nos o
Page 143 and 144:
on demand, a penal interest of 18%
show all

Hiring of VPN Services for GAIL Agartala

Create successful ePaper yourself

Delete template?

Save as template?