Project Manual 11-210C - Ramapo College of New Jersey

More documents

Recommendations

Info

Ramapo College of New Jersey E-Wing Renovation for Teacher’s Education General Conditions Table of Contents Article 1 Contract Documents Pages 4-7 1.1 Definitions 1.2 Intent of the Contract Article 2 Contracting Officer Pages 8-10 2.1 Contracting Officer’s Right to Stop Work 2.2 Contracting Officer’s Right to Carry Out the Work 2.3 Contracting Officer’s Right to Terminate 2.4 Review of Contractor Claims and Disputes 2.5 College Representation 2.6 Ownership and Use of Documents Article 3 Construction Manager and Architect/Engineer Pages 11-12 3.1 Construction Manager and Architect/Engineer 3.2 Administration of the Contract 3.3 Substantial and Final Completion Inspections Article 4 The Contractor Pages 13-27 4.1 Review of Contract 4.2 New Jersey Prevailing Wage Act 4.3 Supervision and Construction Procedures 4.4 Responsibility for the Work 4.5 Permits-Laws-Regulations 4.6 Storage, Cleaning and Final Cleanup 4.7 Interruptions to Existing Services 4.8 Non-Regular Working Hours and Workdays 4.9 Record Documents 4.10 Shop Drawings, Product Data, Samples, and Coordination Drawings 4.11 Miscellaneous Drawings and Charts 4.12 Cutting and Patching 4.13 Tests and Inspections 4.14 Equipment-Material 4.15 Substitutions 4.16 Soil Borings 4.17 Protection of Contractor’s Property 4.18 Patents 4.19 Right to Audit 4.20 Photographs 4.21 Guarantee 4.22 Indemnification 4.23 Contractor’s Claims for Damages 4.24 Layout, Dimensional Control and Verification, Surveyor’s Certification 4.25 Inspection of Roadway Subgrades RCNJ Project No. 11-210C - 1 -
4.26 Maintenance of Construction Access Routes 4.27 Project Sign 4.28 Maintenance Bond 4.29 Use of Premises 4.30 Operation and Maintenance Manuals 4.31 Demonstration and Training Article 5 Subcontractors Page 28 5.1 Contractor-Subcontractor Relationship Article 6 Project Specific Conditions Page 29 6.1 Existing Finishes and Furniture 6.2 Storage of Materials and Equipment 6.3 Standby Personnel Article 7 Temporary Facilities, Utilities, and Services Pages 30-32 7.1 Field Offices 7.2 Storage Sheds, Tool Sheds, Shops, Employee Sheds 7.3 Site Logistics 7.4 Temporary Toilet Facilities 7.5 Temporary Drives and Walks 7.6 Temporary Water 7.7 Temporary Light and Power 7.8 Temporary Heat, Cooling, and Dehumidification 7.9 Temporary Enclosures and Partitions 7.10 Temporary Utility Capping Article 8 Relationship Between The Contractor and Other College Contractors Page 33 8.1 College’s Right to Perform Work 8.2 Mutual Responsibility Article 9 Time Pages 34-40 9.1 Notice to Proceed 9.2 Critical Path Method Scheduling 9.3 Adjustment of Contractor Completion Time 9.4 No Damage for Delay 9.5 Time of Completion – Liquidated Damages 9.6 Contractor Officer’s Right to Accelerate Article 10 Payments and Completion Pages 41-46 10.1 Contractor Payments from The College 10.2 Application for Payments 10.3 Interest 10.4 Substantial Completion 10.5 Use and Possession Prior to Completion (Beneficial Occupancy) 10.6 Final Completion and Payment Article 11 Uncovering and Construction of Work Pages 47-48 11.1 Uncovering of Work 11.2 Correction of Work 11.3 Acceptance of Defective or Nonconforming Work Article 12 Protection of Persons and Property Pages 49-50 12.1 Safety Precautions and Programs RCNJ Project No.: 09-270.1C - 2 -
Page 1 and 2:
E-WING RENOVATION FOR TEACHER’S E
Page 3 and 4:
18 - GENERAL CONDITIONS 19 - REQUES
Page 5 and 6:
BID REQUEST COVER SHEET (FOR CONSTR
Page 7 and 8:
***********************************
Page 9 and 10:
SUBCONTRACTORS AND THEIR REFERENCES
Page 11 and 12:
The Bidder agrees that this bid sha
Page 13 and 14:
RAMAPO COLLEGE OF NEW JERSEY STOCKH
Page 15 and 16:
CONTRACT FOR CONSTRUCTION Agreement
Page 17 and 18: Owner Contractor Agreement 11. CONT
Page 19 and 20: Owner Contractor Agreement ATTEST:
Page 21 and 22: RAMAPO COLLEGE OF NEW JERSEY BID SE
Page 23 and 24: RAMAPO COLLEGE OF NEW JERSEY PERFOR
Page 25 and 26: RAMAPO COLLEGE OF NEW JERSEY PAYMEN
Page 27 and 28: Ramapo College of New Jersey 505 Ra
Page 29 and 30: (1) To notify the Public Agency Com
Page 31 and 32: subcontractor agrees that, in imple
Page 33 and 34: 3. The executive head of each depar
Page 35 and 36: easonable suspicion that such cause
Page 37 and 38: E-Wing Renovation for Teacher’s E
Page 41 and 42: In the procurement process, our pub
Page 43 and 44: 13. The provisions of sections 1 th
Page 45 and 46: WHEREAS, robust competition for pub
Page 47 and 48: incorporate good faith effort requi
Page 49 and 50: APPENDIX A LIST OF REPORTING AGENCI
Page 51 and 52: APPENDIX C It is the policy of the
Page 56 and 57: Academic Complex Academic Wings Ang
Page 58 and 59: • Using Route 208: Follow 208 Nor
Page 60 and 61: THE PUBLIC WORKS CONTRACTOR REGISTR
Page 62 and 63: (8) NJ Business Registration Certif
Page 64 and 65: e. The Contracting Officer reserves
Page 66 and 67: IB9.2 Every request for an interpre
Page 70 and 71: 12.2 Safety of Persons and Property
Page 72 and 73: epresenting the College personally
Page 74 and 75: 1.2.8 The sequence of precedence pe
Page 76 and 77: expeditiously commences to prosecut
Page 78 and 79: ARTICLE 3 CONSTRUCTION MANAGER AND
Page 80 and 81: ARTICLE 4 THE CONTRACTOR 4.1 Review
Page 82 and 83: shall be provided and accomplished
Page 84 and 85: d. Removal of spots, paint and soil
Page 86 and 87: Drawings, Product Data, Samples or
Page 88 and 89: 4.12.3 Replace, fit, patch and repa
Page 90 and 91: 4.18.2 License and/or Royalty Fees
Page 92 and 93: employed by any of them or anyone f
Page 94 and 95: 3. Arrange content by systems under
Page 96 and 97: ARTICLE 6 PROJECT SPECIFIC CONDITIO
Page 98 and 99: 7.5.2 Should the Contractor elect t
Page 100 and 101: ARTICLE 8 RELATIONSHIP BETWEEN THE
Page 102 and 103: epresentative shall meet with the C
Page 104 and 105: Consultant's analysis, would have b
Page 106 and 107: did not affect the project critical
Page 108 and 109: 10.1 Contractor Payments from the C
Page 110 and 111: (4) reasonable evidence that the Wo
Page 112 and 113: Payment Act and by the 30th day aft
Page 114 and 115: 11.1 Uncovering of Work ARTICLE 11
Page 116 and 117: 12.1 Safety Precautions and Program
Page 118 and 119:
13.1 Contractor Insurance Requireme
Page 120 and 121:
ARTICLE 14 CHANGES IN THE WORK 14.1
Page 122 and 123:
14.2.8 Where the cost of property m
Page 124 and 125:
ARTICLE 16 AFFIRMATIVE ACTION REQUI
Page 126 and 127:
(2) To notify any minority and fema
Page 128 and 129:
(E) The contractor and its subcontr
Page 130 and 131:
SECTION 01 11 00 - SUMMARY OF WORK
Page 132 and 133:
SECTION 01 11 05 - TIME OF COMPLETI
Page 134 and 135:
SECTION 01 29 00 - PAYMENT PROCEDUR
Page 136 and 137:
Page 138 and 139:
Page 140 and 141:
SECTION 01 31 19 - PROJECT MEETINGS
Page 142 and 143:
SECTION 01 31 19 - PROJECT MEETINGS
Page 144 and 145:
SECTION 01 33 00 - SUBMITTAL PROCED
Page 146 and 147:
Page 148 and 149:
Page 150 and 151:
SECTION 01 40 00 - QUALITY REQUIREM
Page 152 and 153:
SECTION 01 40 00 - QUALITY REQUIREM
Page 154 and 155:
SECTION 01 42 19 - REFERENCE STANDA
Page 156 and 157:
SECTION 01 42 19 - REFERENCE STANDA
Page 158 and 159:
SECTION 01 70 00 - CLOSEOUT 2. Resu
Page 160 and 161:
SECTION 01 70 00 - CLOSEOUT 1.5 FIN
Page 162 and 163:
SECTION 01 70 00 - CLOSEOUT Partial
Page 164 and 165:
RAMAPO COLLEGE OF NEW JERSEY TEACHE
Page 166 and 167:
Page 168 and 169:
Page 170 and 171:
Page 172 and 173:
show all

Project Manual 11-210C - Ramapo College of New Jersey

You also want an ePaper? Increase the reach of your titles

Delete template?

Save as template?