Project Manual 11-210C - Ramapo College of New Jersey

More documents

Recommendations

Info

expeditiously commences to prosecute the same to completion, the Contracting Officer shall permit him to do so under the following terms and conditions: a. Evidence of the Surety's intention to take over and complete the Contract shall be in writing over the signature of an authorized representative and served upon the Contracting Officer within three (3) days after receipt by the Surety of Notice of Termination. b. The execution of a written Agreement between the College, by the Contracting Officer, and the Surety whereby the latter undertakes and assumes the obligation to complete the balance of the Work of its defaulting Contractor in accordance with the terms and conditions of the College Contractor Agreement, to be performed by a substituted Contractor satisfactory to the Contracting Officer, at the Surety's sole cost and expense, and providing for payments to the Surety or to the Substituted Contractor of unpaid Contract balances, if any, then in hands of the College. c. The said Agreement shall also expressly provide that the Surety shall not be relieved thereby from any of its obligations under the Performance and Payment Bonds and that it furnish the College with an additional Performance and Payment Bond to secure the faithful performance of the Substituted Contractor. d. That all current obligations for labor and materials incurred and outstanding by the defaulting Contractor on this Project be paid without delay, subject to allowance of a reasonable time within which to verify such claims by the Surety; and e. That the parties expressly understand and agree that this Agreement is without prejudice and is subject to such rights and remedies as either party (including the Contractor) may elect to assert after final completion and acceptance of the Work. 2.4 Review of Contractor Claims and Disputes 2.4.1 Upon presentation by the Contractor of a request in writing, the Contracting Officer may review any decision or determination of the College or any authorized representative as to any claim, dispute or any other matter or question relating to the execution or progress of the Work or the interpretation of the Contract documents. Consistent with the intent of this contract, the Contracting Officer may schedule a conference for the purpose of settling or resolving such claims, disputes or other matters. Where such a conference is conducted, the Contractor shall be afforded the opportunity to be heard on the matter in question. Following review of the Contractor's request, the College and the Contractor may settle or resolve the disputed matter, provided however that any such settlement or resolution shall be subject to all requirements imposed by law, including where applicable, the New Jersey Contractual Liability Act, N.J.S.A. 59:13-1 et seq. 2.5 College Representation 2.5.1 The College will be represented by a Construction Manager and its staff or other designated representative. The Construction Manager or other designated representative will routinely conduct on-site observations, maintain logs of construction progress and problems encountered; approve Contractor's requisition for payments subject to final approval by the Contracting Officer; conduct job meetings; carry out liaison with the Architect/Engineer and the Contractor; prepare and submit reports on special problems associated with the job; evaluate and process Change Order Requests, and generally remain fully cognizant and be kept informed by the Contractor of RCNJ Project No.: 09-270.1C - 9 -
every aspect of ongoing construction. The College's representatives, including the Construction Manager and its staff, have only those duties which are required of an College; responsibility for completion of this project, pursuant to the Contract Documents, remains with the Contractor. 2.6 Ownership and Use of Documents 2.6.1 All Drawings, Specifications and copies thereof furnished by the Architect/Engineer are and shall remain the property of the College. They are reserved to this Project only and are not to be used on any other Project. Submission or distribution of Documents to meet official regulatory requirements, or for any other purposes in connection with the Project shall not be construed as derogation of the Architect/Engineer's copyright or other reserved rights. RCNJ Project No.: 09-270.1C - 10 -
Page 1 and 2:
E-WING RENOVATION FOR TEACHER’S E
Page 3 and 4:
18 - GENERAL CONDITIONS 19 - REQUES
Page 5 and 6:
BID REQUEST COVER SHEET (FOR CONSTR
Page 7 and 8:
***********************************
Page 9 and 10:
SUBCONTRACTORS AND THEIR REFERENCES
Page 11 and 12:
The Bidder agrees that this bid sha
Page 13 and 14:
RAMAPO COLLEGE OF NEW JERSEY STOCKH
Page 15 and 16:
CONTRACT FOR CONSTRUCTION Agreement
Page 17 and 18:
Owner Contractor Agreement 11. CONT
Page 19 and 20:
Owner Contractor Agreement ATTEST:
Page 21 and 22:
RAMAPO COLLEGE OF NEW JERSEY BID SE
Page 23 and 24:
RAMAPO COLLEGE OF NEW JERSEY PERFOR
Page 25 and 26: RAMAPO COLLEGE OF NEW JERSEY PAYMEN
Page 27 and 28: Ramapo College of New Jersey 505 Ra
Page 29 and 30: (1) To notify the Public Agency Com
Page 31 and 32: subcontractor agrees that, in imple
Page 33 and 34: 3. The executive head of each depar
Page 35 and 36: easonable suspicion that such cause
Page 37 and 38: E-Wing Renovation for Teacher’s E
Page 41 and 42: In the procurement process, our pub
Page 43 and 44: 13. The provisions of sections 1 th
Page 45 and 46: WHEREAS, robust competition for pub
Page 47 and 48: incorporate good faith effort requi
Page 49 and 50: APPENDIX A LIST OF REPORTING AGENCI
Page 51 and 52: APPENDIX C It is the policy of the
Page 56 and 57: Academic Complex Academic Wings Ang
Page 58 and 59: • Using Route 208: Follow 208 Nor
Page 60 and 61: THE PUBLIC WORKS CONTRACTOR REGISTR
Page 62 and 63: (8) NJ Business Registration Certif
Page 64 and 65: e. The Contracting Officer reserves
Page 66 and 67: IB9.2 Every request for an interpre
Page 68 and 69: Ramapo College of New Jersey E-Wing
Page 70 and 71: 12.2 Safety of Persons and Property
Page 72 and 73: epresenting the College personally
Page 74 and 75: 1.2.8 The sequence of precedence pe
Page 78 and 79: ARTICLE 3 CONSTRUCTION MANAGER AND
Page 80 and 81: ARTICLE 4 THE CONTRACTOR 4.1 Review
Page 82 and 83: shall be provided and accomplished
Page 84 and 85: d. Removal of spots, paint and soil
Page 86 and 87: Drawings, Product Data, Samples or
Page 88 and 89: 4.12.3 Replace, fit, patch and repa
Page 90 and 91: 4.18.2 License and/or Royalty Fees
Page 92 and 93: employed by any of them or anyone f
Page 94 and 95: 3. Arrange content by systems under
Page 96 and 97: ARTICLE 6 PROJECT SPECIFIC CONDITIO
Page 98 and 99: 7.5.2 Should the Contractor elect t
Page 100 and 101: ARTICLE 8 RELATIONSHIP BETWEEN THE
Page 102 and 103: epresentative shall meet with the C
Page 104 and 105: Consultant's analysis, would have b
Page 106 and 107: did not affect the project critical
Page 108 and 109: 10.1 Contractor Payments from the C
Page 110 and 111: (4) reasonable evidence that the Wo
Page 112 and 113: Payment Act and by the 30th day aft
Page 114 and 115: 11.1 Uncovering of Work ARTICLE 11
Page 116 and 117: 12.1 Safety Precautions and Program
Page 118 and 119: 13.1 Contractor Insurance Requireme
Page 120 and 121: ARTICLE 14 CHANGES IN THE WORK 14.1
Page 122 and 123: 14.2.8 Where the cost of property m
Page 124 and 125: ARTICLE 16 AFFIRMATIVE ACTION REQUI
Page 126 and 127:
(2) To notify any minority and fema
Page 128 and 129:
(E) The contractor and its subcontr
Page 130 and 131:
SECTION 01 11 00 - SUMMARY OF WORK
Page 132 and 133:
SECTION 01 11 05 - TIME OF COMPLETI
Page 134 and 135:
SECTION 01 29 00 - PAYMENT PROCEDUR
Page 136 and 137:
Page 138 and 139:
Page 140 and 141:
SECTION 01 31 19 - PROJECT MEETINGS
Page 142 and 143:
SECTION 01 31 19 - PROJECT MEETINGS
Page 144 and 145:
SECTION 01 33 00 - SUBMITTAL PROCED
Page 146 and 147:
Page 148 and 149:
Page 150 and 151:
SECTION 01 40 00 - QUALITY REQUIREM
Page 152 and 153:
SECTION 01 40 00 - QUALITY REQUIREM
Page 154 and 155:
SECTION 01 42 19 - REFERENCE STANDA
Page 156 and 157:
SECTION 01 42 19 - REFERENCE STANDA
Page 158 and 159:
SECTION 01 70 00 - CLOSEOUT 2. Resu
Page 160 and 161:
SECTION 01 70 00 - CLOSEOUT 1.5 FIN
Page 162 and 163:
SECTION 01 70 00 - CLOSEOUT Partial
Page 164 and 165:
RAMAPO COLLEGE OF NEW JERSEY TEACHE
Page 166 and 167:
Page 168 and 169:
Page 170 and 171:
Page 172 and 173:
show all

Project Manual 11-210C - Ramapo College of New Jersey

You also want an ePaper? Increase the reach of your titles

Delete template?

Save as template?