Project Manual 11-210C - Ramapo College of New Jersey

More documents

Recommendations

Info

1.2.8 The sequence of precedence pertaining to interpretation of Contract Documents is as follows: a. Executed Contract b. Addenda/Bulletin/Insurance c. General Conditions d. Specifications e. Drawings, in following order of precedence: (1) Notes on Drawings (2) Large scale details (3) Figured dimensions (4) Scaled dimensions Where there may be a conflict in the Specifications or Drawings not resolvable by application of the provisions of this paragraph, then the more expensive labor, materials, or equipment shall be assumed to be required and shall be provided by the Contractor. 1.2.9 Where certain of the work is shown in complete detail, but not repeated in similar detail in other areas of the Drawings, or there is an indication of continuation, the remainder being only shown in outline, the work shown in detail shall be understood to be required in other like portions of the project at no additional cost to the College. 1.2.10 The Contractor shall not, at any time after the execution of its Contract, make any claims whatsoever based upon insufficient data or its incorrectly assumed conditions, nor shall he claim any misunderstandings with regard to the nature, conditions or character of the work to be done under the Contract and he shall assume all risks resulting from any changes in conditions not under the control of the College which may occur during the progress of the Work. 1.2.11 On all Work involving alterations, remodeling, repairs or installation within existing buildings, it shall be the responsibility of the Contractor by personal inspection of the existing building, facility, plant or utility system, to satisfy himself as to the accuracy of any information given which may affect the quantity, size and/or quality of materials required for a satisfactorily completed Contract, whether or not such information is indicated on the Drawings or included in the Specifications. All contracts shall include the cost of all material and labor required to complete the work based on reasonably observable conditions. RCNJ Project No.: 09-270.1C - 7 -
2.1 Contracting Officer's Right to Stop the Work ARTICLE 2 CONTRACTING OFFICER 2.1.1 If the Contractor fails to correct defective Work or persistently fails to carry out the Work in accordance with the Contract Documents, the Contracting Officer or its authorized representative may order the Contractor to stop the work, or any portion thereof, until the cause for such order has been eliminated. Stoppage of the Work shall not render the College liable for claims of any kinds. 2.2 Contracting Officer’s Right to Carry Out the Work 2.2.1 If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten-calendar day period after receipt of written notice from the Contracting Officer or its authorized representatives to commence and continue correction of such default or neglect with diligence and promptness, the Contracting Officer may, without prejudice to other remedies the Contracting Officer may have, correct such deficiencies. In such case, an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including College’s expenses and compensation for the Construction Manager’s and Architect’s and their respective consultants’ additional services made necessary by such default, neglect or failure. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the College. Should work be performed by the Contracting Officer under this article, the Contractor will have no cause to void any guarantee on materials or systems installed under this Contract. 2.3 Contracting Officer's Right to Terminate 2.3.1 If the Contractor is adjudged a bankrupt, or if he makes a general assignment for the benefit of its creditors, if a receiver is appointed on account of its insolvency, or if he persistently or repeatedly refuses or fails, except in cases for which extension of time is provided, to supply enough properly skilled workmen or proper materials so as to avoid or eliminate delays in the orderly progress of the Work in accordance with the approved schedule, or if he fails to make prompt payment to Subcontractors or for materials or labor, or persistently disregards laws, ordinances, rules, regulations or orders of any public authority having jurisdiction, or if he or any of its Subcontractors is guilty of a substantial violation of a provision of the Contract Documents, or otherwise defaults or neglects to carry out the Work in accordance with the Contract Documents, then the Contracting Officer may, without prejudice to any right or remedy, and after giving the Contractor and its Surety three (3) working days written notice to forthwith commence and continue correction of such default or neglect with diligence and promptness, terminate the employment of the Contractor by the issuance of a written notice to that effect to the Contractor and its Surety at any time subsequent to three (3) working days thereafter, should they, or either of them, fail to comply with the demands of the original three (3) day notice, above mentioned. 2.3.2 Upon such termination the Contracting Officer may take possession of the site and of all the materials, equipment, and tools on the site, and may finish the Work by whatever method he may deem expedient. In such case the Contractor shall not be entitled to receive any further payment until the Work is finished. The person or firm designated to carry out such work will be paid as authorized by the Contracting Officer, without entailing any personal liability upon the officers of the College issuing certificates or making such payment. 2.3.3 If the unpaid balance of the Contract Sum exceeds the cost of finishing the Work, including Liquidated Damages for delays and all consequential damages sustained by the College flowing from such breach of Contract, such excess shall be paid to the Contractor. If such costs exceed the unpaid balance, the Contractor and/or its Surety shall pay the difference to the College, and this obligation shall survive the termination of the Contract. 2.3.4 If, within three (3) working days following receipt of Notice of Termination by the Contractor's Surety, the issuer of the Performance and Payment Bonds, the said Surety exercises its right to take over the Work and RCNJ Project No.: 09-270.1C - 8 -
Page 1 and 2:
E-WING RENOVATION FOR TEACHER’S E
Page 3 and 4:
18 - GENERAL CONDITIONS 19 - REQUES
Page 5 and 6:
BID REQUEST COVER SHEET (FOR CONSTR
Page 7 and 8:
***********************************
Page 9 and 10:
SUBCONTRACTORS AND THEIR REFERENCES
Page 11 and 12:
The Bidder agrees that this bid sha
Page 13 and 14:
RAMAPO COLLEGE OF NEW JERSEY STOCKH
Page 15 and 16:
CONTRACT FOR CONSTRUCTION Agreement
Page 17 and 18:
Owner Contractor Agreement 11. CONT
Page 19 and 20:
Owner Contractor Agreement ATTEST:
Page 21 and 22:
RAMAPO COLLEGE OF NEW JERSEY BID SE
Page 23 and 24: RAMAPO COLLEGE OF NEW JERSEY PERFOR
Page 25 and 26: RAMAPO COLLEGE OF NEW JERSEY PAYMEN
Page 27 and 28: Ramapo College of New Jersey 505 Ra
Page 29 and 30: (1) To notify the Public Agency Com
Page 31 and 32: subcontractor agrees that, in imple
Page 33 and 34: 3. The executive head of each depar
Page 35 and 36: easonable suspicion that such cause
Page 37 and 38: E-Wing Renovation for Teacher’s E
Page 41 and 42: In the procurement process, our pub
Page 43 and 44: 13. The provisions of sections 1 th
Page 45 and 46: WHEREAS, robust competition for pub
Page 47 and 48: incorporate good faith effort requi
Page 49 and 50: APPENDIX A LIST OF REPORTING AGENCI
Page 51 and 52: APPENDIX C It is the policy of the
Page 56 and 57: Academic Complex Academic Wings Ang
Page 58 and 59: • Using Route 208: Follow 208 Nor
Page 60 and 61: THE PUBLIC WORKS CONTRACTOR REGISTR
Page 62 and 63: (8) NJ Business Registration Certif
Page 64 and 65: e. The Contracting Officer reserves
Page 66 and 67: IB9.2 Every request for an interpre
Page 68 and 69: Ramapo College of New Jersey E-Wing
Page 70 and 71: 12.2 Safety of Persons and Property
Page 72 and 73: epresenting the College personally
Page 76 and 77: expeditiously commences to prosecut
Page 78 and 79: ARTICLE 3 CONSTRUCTION MANAGER AND
Page 80 and 81: ARTICLE 4 THE CONTRACTOR 4.1 Review
Page 82 and 83: shall be provided and accomplished
Page 84 and 85: d. Removal of spots, paint and soil
Page 86 and 87: Drawings, Product Data, Samples or
Page 88 and 89: 4.12.3 Replace, fit, patch and repa
Page 90 and 91: 4.18.2 License and/or Royalty Fees
Page 92 and 93: employed by any of them or anyone f
Page 94 and 95: 3. Arrange content by systems under
Page 96 and 97: ARTICLE 6 PROJECT SPECIFIC CONDITIO
Page 98 and 99: 7.5.2 Should the Contractor elect t
Page 100 and 101: ARTICLE 8 RELATIONSHIP BETWEEN THE
Page 102 and 103: epresentative shall meet with the C
Page 104 and 105: Consultant's analysis, would have b
Page 106 and 107: did not affect the project critical
Page 108 and 109: 10.1 Contractor Payments from the C
Page 110 and 111: (4) reasonable evidence that the Wo
Page 112 and 113: Payment Act and by the 30th day aft
Page 114 and 115: 11.1 Uncovering of Work ARTICLE 11
Page 116 and 117: 12.1 Safety Precautions and Program
Page 118 and 119: 13.1 Contractor Insurance Requireme
Page 120 and 121: ARTICLE 14 CHANGES IN THE WORK 14.1
Page 122 and 123: 14.2.8 Where the cost of property m
Page 124 and 125:
ARTICLE 16 AFFIRMATIVE ACTION REQUI
Page 126 and 127:
(2) To notify any minority and fema
Page 128 and 129:
(E) The contractor and its subcontr
Page 130 and 131:
SECTION 01 11 00 - SUMMARY OF WORK
Page 132 and 133:
SECTION 01 11 05 - TIME OF COMPLETI
Page 134 and 135:
SECTION 01 29 00 - PAYMENT PROCEDUR
Page 136 and 137:
Page 138 and 139:
Page 140 and 141:
SECTION 01 31 19 - PROJECT MEETINGS
Page 142 and 143:
SECTION 01 31 19 - PROJECT MEETINGS
Page 144 and 145:
SECTION 01 33 00 - SUBMITTAL PROCED
Page 146 and 147:
Page 148 and 149:
Page 150 and 151:
SECTION 01 40 00 - QUALITY REQUIREM
Page 152 and 153:
SECTION 01 40 00 - QUALITY REQUIREM
Page 154 and 155:
SECTION 01 42 19 - REFERENCE STANDA
Page 156 and 157:
SECTION 01 42 19 - REFERENCE STANDA
Page 158 and 159:
SECTION 01 70 00 - CLOSEOUT 2. Resu
Page 160 and 161:
SECTION 01 70 00 - CLOSEOUT 1.5 FIN
Page 162 and 163:
SECTION 01 70 00 - CLOSEOUT Partial
Page 164 and 165:
RAMAPO COLLEGE OF NEW JERSEY TEACHE
Page 166 and 167:
Page 168 and 169:
Page 170 and 171:
Page 172 and 173:
show all

Project Manual 11-210C - Ramapo College of New Jersey

Create successful ePaper yourself

Delete template?

Save as template?