AGREEMENT between BROWARD COUNTY and Cummings ...

DIVISION 1 SPECIFICATIONS
SECTION 01315 PROGRESS SCHEDULES (COMPUTERIZED CPM)
1.05 PREPARATION GUIDELINES
A. The Baseline Schedule shall represent a practical plan to complete the work
within the Contract Time.
1. A schedule extending beyond the Contract Time will not be acceptable.
2. A schedule showing the work completed in less than the Contract Time
may be found by the CPM to be impractical.
3. A schedule found by the CPM to be impractical for the preceding reason
or any other reason will be revised by the CONTRACTOR and
resubmitted.
4. A schedule showing the work completed in less than the Contract Time,
which is found to be practical by the CPM, will be considered to have
float. Float is the time between the scheduled completion of the work and
the contract Substantial Completion date.
B. The Updated Progress Schedule shall:
1. Be in sufficient detail to assure adequate planning and execution of the
work.
2. Be suitable, in the judgment of the CPM, to allow monitoring and
evaluation of progress in the performance of the Work.
3. Be a calendar time-scaled logic diagram with a graphical layout
illustrating logic ties with an accompanied activity listing identifying
detailed predecessors and successors.
4. Include time for the CPM and the CONSULTANT to review submittals or
inspect the work.
5. Identify the activities, which constitute the controlling items of work or
critical path.
C. COST CORRELATION - EARNED VALUE ANALYSIS (Not Used)
1.06 SCHEDULE SUBMITTALS
A. GENERAL SCHEDULE SUBMITTAL FORMAT:
1. Logic drawings shall be submitted flat (11” x 17”) and reproducible as
copies without loss of legibility. Size of plot and number of copies shall be
at the discretion of the CPM.
2. Hard copies of listings shall be prepared on separate sheets of 11” x 17”
or legal size paper; include three (3) copies of each report.
3. Electronic Format: All project files in original file format, as well as pdf file
format, shall be copied and submitted on a (CD) compact disk. A project
CD shall accompany all CONTRACTOR submissions.
B. PRELIMINARY BASELINE SCHEDULE
Exhibit 2
Page 262 of 379
1. Within twenty-one (21) calendar days after date of Contract Award
Notice-to-Proceed, CONTRACTOR shall provide a Preliminary Baseline
Schedule that shall be used to monitor the progress of Work during
Section 01315 Progress Schedule (Computerized CPM) Page 57